ࡱ> }  j k l m n o p q r s t u v w x y z { | ] rbjbj۷۷ z &\&\"[ - - - - -4T-T-T-h- :T-lSLnp(o(o(o\p02 x$d! -R\p\pRR! - -(o(o460R -(o -(oRh(o8,cf<sZ| " -p$ppp!!pppRRRRppppppppp> +: Building contract for new homes Contents  TOC \t "Heading 1,1,Heading 2,2" Contents  PAGEREF _Toc462057928 \h 1 About this contract  PAGEREF _Toc462057929 \h 3 What does this contract include?  PAGEREF _Toc462057930 \h 5 Cooling-off period notice  PAGEREF _Toc462057931 \h 7 Key points  PAGEREF _Toc462057932 \h 8 1. Domestic Building Consumer Guide and checklists  PAGEREF _Toc462057933 \h 8 2. Check the Builder is registered  PAGEREF _Toc462057934 \h 8 3. Foundations Data  PAGEREF _Toc462057935 \h 8 4. Be precise in requirements  PAGEREF _Toc462057936 \h 8 5. Get estimates when exact pricing is not possible  PAGEREF _Toc462057937 \h 9 6. Deposit  PAGEREF _Toc462057938 \h 9 7. Completing the document  PAGEREF _Toc462057939 \h 9 8. Permits and prescribed approvals  PAGEREF _Toc462057940 \h 9 9. Domestic Building Insurance  PAGEREF _Toc462057941 \h 9 10. Other insurance requirements  PAGEREF _Toc462057942 \h 10 11. Builders warranties  PAGEREF _Toc462057943 \h 10 12. Parties authorised representatives  PAGEREF _Toc462057944 \h 11 13. Termination of contract  PAGEREF _Toc462057945 \h 11 Part A: Check the following lists before signing the contract  PAGEREF _Toc462057946 \h 12 Director of Consumer Affairs ɫƵ  PAGEREF _Toc462057947 \h 12 Approved Domestic Building Contracts Checklist  PAGEREF _Toc462057948 \h 12 Is the contract complete and ready to be signed?  PAGEREF _Toc462057949 \h 14 Part B: Terms of the contract  PAGEREF _Toc462057950 \h 16 1. Definitions  PAGEREF _Toc462057951 \h 16 2. Interpretation  PAGEREF _Toc462057952 \h 18 3. Communication between the Building Owner and the Builder  PAGEREF _Toc462057953 \h 18 4. Contract Details  PAGEREF _Toc462057954 \h 20 5. Contract Price  PAGEREF _Toc462057955 \h 27 6. Deposit  PAGEREF _Toc462057956 \h 31 7. Progress payments  PAGEREF _Toc462057957 \h 31 8. Domestic Building Insurance  PAGEREF _Toc462057958 \h 34 9. Obligations of the Builder and the Building Owner  PAGEREF _Toc462057959 \h 34 10. Contract documents  PAGEREF _Toc462057960 \h 36 11. Signatures  PAGEREF _Toc462057961 \h 37 12. General conditions of contract  PAGEREF _Toc462057962 \h 38 13. Commencement of Work  PAGEREF _Toc462057963 \h 40 14. Finish Date  PAGEREF _Toc462057964 \h 40 15. Loss or damage incurred by Building Owner  PAGEREF _Toc462057965 \h 42 16. Purpose of Work  PAGEREF _Toc462057966 \h 43 17. Builders warranties  PAGEREF _Toc462057967 \h 44 18. Permits, prescribed approvals and third-party requirements  PAGEREF _Toc462057968 \h 47 19. Loan approvals  PAGEREF _Toc462057969 \h 48 20. Occupation of the Building Site  PAGEREF _Toc462057970 \h 48 21. Access to the Building Site  PAGEREF _Toc462057971 \h 49 22. Extension of Time  PAGEREF _Toc462057972 \h 49 23. Variations  PAGEREF _Toc462057973 \h 50 24. Provisional Sums  PAGEREF _Toc462057974 \h 51 25. Prime Cost Items  PAGEREF _Toc462057975 \h 52 26. Evidence of cost of Prime Cost Items and Provisional Sums  PAGEREF _Toc462057976 \h 52 27. Effect of payments and non-payments to the Builder  PAGEREF _Toc462057977 \h 52 28. Final Completion and final payment  PAGEREF _Toc462057978 \h 53 29. Building Owners recovery for delay, loss, expense or damage  PAGEREF _Toc462057979 \h 53 30. Lender payment  PAGEREF _Toc462057980 \h 54 31. Completion of Work  PAGEREF _Toc462057981 \h 54 32. Completion notifications Opinion Procedure  PAGEREF _Toc462057982 \h 54 33. Rectification period and maintenance  PAGEREF _Toc462057983 \h 55 34. Dispute Resolution Procedure  PAGEREF _Toc462057984 \h 55 35. Suspension of Work by the Builder  PAGEREF _Toc462057985 \h 56 36. Consequences of insolvency  PAGEREF _Toc462057986 \h 56 37. Termination after notice of default  PAGEREF _Toc462057987 \h 57 38. Termination other than after notice of default  PAGEREF _Toc462057988 \h 57 39. Builders entitlement at termination  PAGEREF _Toc462057989 \h 58 40. Consequences of termination by the Builder  PAGEREF _Toc462057990 \h 58 41. Consequences of termination by the Building Owner  PAGEREF _Toc462057991 \h 58 42. Insurance  PAGEREF _Toc462057992 \h 59 43. Copyright  PAGEREF _Toc462057993 \h 60 Document List Attachment  PAGEREF _Toc462057994 \h 61 General Attachment  PAGEREF _Toc462057995 \h 62 Provisional Sums Schedule  PAGEREF _Toc462057996 \h 63 Prime Cost Items Schedule  PAGEREF _Toc462057997 \h 64 Part C: Legislation Extracts  PAGEREF _Toc462057998 \h 66 Clause 1: Definitions  PAGEREF _Toc462057999 \h 66 Clause 7: Progress payments  PAGEREF _Toc462058000 \h 67 Clause 12: General conditions of contract  PAGEREF _Toc462058001 \h 69 Clause 18: Permits, prescribed approvals and third-party requirements  PAGEREF _Toc462058002 \h 70 Clause 23: Variations  PAGEREF _Toc462058003 \h 70 Clause 38: Termination other than after notice of default  PAGEREF _Toc462058004 \h 72 Part D: Forms  PAGEREF _Toc462058005 \h 73 Form A Notice of commencement of Work  PAGEREF _Toc462058006 \h 73 Form B Request for evidence of title and site dimensions  PAGEREF _Toc462058007 \h 75 Form C Notification of requirement for a boundary survey  PAGEREF _Toc462058008 \h 77 Form D Request for evidence of capacity to meet contract terms  PAGEREF _Toc462058009 \h 79 Form E Notification of new representative  PAGEREF _Toc462058010 \h 81 Form F Notification of whether loan has been approved  PAGEREF _Toc462058011 \h 84 Form G Notification of likely delay/claim for Extension of Time  PAGEREF _Toc462058012 \h 86 Form H Variation to plans and specifications  PAGEREF _Toc462058013 \h 90 Form I Notification of Provisional Sum or Prime Cost Item Work  PAGEREF _Toc462058014 \h 95 Form J Progress payments  PAGEREF _Toc462058015 \h 98 Form K Loss, expense or damage caused to the Building Owner  PAGEREF _Toc462058016 \h 101 Form L Completion of Work and Opinion Procedure  PAGEREF _Toc462058017 \h 104 Form M Rectification requirement  PAGEREF _Toc462058018 \h 112 Form N Notice of dispute  PAGEREF _Toc462058019 \h 115 Form O Suspension of Work  PAGEREF _Toc462058020 \h 117 Form P Termination of contract by Builder  PAGEREF _Toc462058021 \h 120 Form Q Termination of contract by Building Owner  PAGEREF _Toc462058022 \h 123 Form R Notice to Builder of appointment of private building surveyor or instructions to apply to municipal building surveyor for building permit  PAGEREF _Toc462058023 \h 126 [Form begins]  PAGEREF _Toc462058024 \h 127 Publisher information  PAGEREF _Toc462058025 \h 128  Published by Consumer Affairs ɫƵ Department of Justice & regulation 121 Exhibition Street Melbourne VIC 3000 About this contract Consumer Affairs ɫƵ (Department of Justice & Regulation) has developed this contract to assist Builders and Building Owners entering into a contract for the construction of a new home. This contract can be used where the Builder is registered in ɫƵ as a domestic builder by the ɫƵn Building Authority (or by the Building Practitioners Board for builders registered before 1 September 2016). This contract should not be used if the Building Owner intends to carry out the Work as an owner builder or if the building permit identifies the Builder as the owner. This contract satisfies the requirements of the Domestic Building Contracts Act 1995 (the Act) and other relevant legislation and provides a fair balance between the rights and obligations of the Builder and those of the Building Owner. As far as possible without losing legal intent, the contract has been drafted in plain English. The contract includes notes designed to help both parties understand their rights and their ɫƵ under the contract. These notes are advisory only and do not form part of the legal contract. To assist parties to this contract to communicate with each other about significant issues, the contract provides model forms (see  HYPERLINK \l "_Part_D:_Forms_1" Part D). The contract does not mandate the use of these forms but their use is highly recommended. The use of this model contract is voluntary. Builders and Building Owners are free to use a different contract, such as one prepared by the Builder, a solicitor, or purchased from an industry association provided it satisfies the provisions of the Act and other laws. Whether this model contract or a different contract is used, both the Builder and Building Owner should read and fully understand all the terms in the contract. When signed by all the parties, this contract will be legally binding in the same way as a contract drawn up by a solicitor. This contract is designed for use for a new home where plans and specifications for the Work have already been drawn up and where the Builder is engaged to complete the construction of the home. It can be used for any new home, regardless of its size or cost. If the Building Owner has any questions about this contract, its status, or how to complete it, they should: discuss the matter with the Builder seek advice, at the Building Owners cost, from a suitably qualified professional, such as a solicitor experienced in domestic building contracts. Consumer information on building and renovating is available at the  HYPERLINK "http://www.consumer.vic.gov.au" Consumer Affairs ɫƵ website or by calling 1300 557 559. Note: Words in italics appearing throughout this contract are defined in  HYPERLINK \l "_1._Definitions_3" Clause 1 of this contract ( HYPERLINK \l "_Part_B:_Terms" Part B). Legislation is also italicised but should not be read as a defined term. What does this contract include? ItemDescription HYPERLINK \l "_Cooling-off_period_notice_1" Cooling-off period noticeAfter signing a domestic building contract, the Building Owner enters into a cooling-off period under ɫƵs consumer protection laws. The cooling-off period is five Business Days. During the cooling-off period, the Building Owner can decide not to continue with the contract. If the Building Owner decides they do not wish to continue with the contract, the Building Owner must sign the  HYPERLINK \l "_Cooling-off_period_notice_2" cooling-off period notice in this contract and give it to the Builder in the manner detailed in the notice. Upon doing this, the contract is cancelled. HYPERLINK \l "_Part_A:_Check" Part A: Required checklists before signing the contractThere are two checklists in Part A of this contract that must be read and signed before the contract is signed. One checklist is for the Building Owner to complete. By law, this checklist must be completed before the contract is signed and entered into. The second checklist is a guide to assist both the Building Owner and the Builder to complete the contract. HYPERLINK \l "_Part_B:_Terms_1" Part B: Terms of the contract and related attachmentsThis is the legal contract that sets out the various rights and obligations of the Building Owner and the Builder. Notes are provided to assist in understanding and completing the contract. These notes are advisory notes only and do not form part of the contract. HYPERLINK \l "_Part_C:_Legislation_1" Part C: Legislation ExtractsPart C reproduces key sections of the Act to assist in understanding of the legal requirements of the contract. The terms of this contract require the Building Owner and the Builder to read and initial the copies of HYPERLINK \l "_Section_37__1"sections 37 and 38 (Variation to contract) and HYPERLINK \l "_Section_40_"sections40(1) and 40(2) (progress payments) of the Act, which are reproduced in the Legislation Extracts. HYPERLINK \l "_Document_List_Attachment_1" AttachmentsA number of other important documents also form part of the contract, and need to be included as attachments. These include copies of the plans and specifications and estimates of the cost of particular items. These are explained in the consecutive sections HYPERLINK \l "_Document_List_Attachment_2"Document List Attachment and  HYPERLINK \l "_General_Attachment_1" General Attachment.PlansPlans are detailed drawings that graphically describe the Work and how the Work will be undertaken. Plans will detail materials to be used including size, type, quantity, position and quality. Plans will also detail how the Work complies with the relevant legislation governing the construction of the building, such as the Planning and Environment Act 1987 and the Building Act 1993.SpecificationsSpecifications are a written description of the required quality of the Work. A specification prescribes specific details regarding the Work, including, for example, adherence to relevant Australian construction standards. Specifications will also detail particular items a Building Owner requires in a building and the schedule of finishes to be achieved in the buildings construction. Specifications also enable a clear understanding of the level of quality that is to be achieved in the buildings construction.Prime Cost ItemsPrime Cost Items are items (for example, a fixture or fitting) that either have not been selected, or whose price is not known, at the time the contract is entered into and for the cost of supply and delivery of which the Builder must make a reasonable allowance in the contract. A  HYPERLINK \l "_Prime_Cost_Items_1" Schedule individually identifying each Prime Cost Item is attached to this contract.Provisional SumA Provisional Sum is an estimate of the cost of carrying out particular work (including the cost of supplying any materials needed for the Work) under the contract for which a Builder, after making all reasonable inquiries, cannot give a definite amount at the time the contract is entered into. A  HYPERLINK \l "_Provisional_Sums_Schedule_1" Schedule individually identifying each Provisional Sum item is attached to this contract.Note: Words in italics are defined in  HYPERLINK \l "_1._Definitions_1" Clause 1 of this contract (Part B). Cooling-off period notice Domestic Building Contracts Act 1995 Director of Consumer Affairs ɫƵ Approved Notice The following notice is hereby approved by the Director of Consumer Affairs ɫƵ. This version of the notice replaces the version published in the ɫƵn Government Gazette of 16 May 1996. The notice must be included in major domestic building contracts in substantially the same form or to the same effect as follows: Notice pursuant to Section 31(1)(n) Cooling off period Notice to Building Owner: You may end this contract within five clear business days after receipt by you of a signed copy of the contract by filling in the notice below and giving it to the Builder in one of the following ways: (1) Personally (2) Leaving it at his or her address set out in the contract with a person who appears to be at least 16 years old (3) Sending it by pre-paid certified mail to the address set out in this contract (4) Sending it by facsimile to the facsimile number (if any) set out in this contract.  Detach along dotted line [Form begins] Notice that contract is ended A Building Owner cannot withdraw from a contract under the Act if: 1. The Builder and the Building Owner have previously entered into a major domestic building contract that is in substantially the same terms for the carrying out of the Work in relation to the same home or land; OR 2. The Building Owner received independent legal advice from an Australian legal practitioner concerning the contract before entering into the contract. To (Builder):I/We:give notice under our contract with you that the contract is ended. Please refund the deposit less $100 and any out of pocket expenses incurred by you which I have previously approved.Building Owners signature:Date:[Form ends] Key points 1. Domestic Building Consumer Guide and checklists The Builder is required by law to give the Building Owner a copy of the Domestic Building Consumer Guide published by Consumer Affairs ɫƵ before signing the contract. Reading the guide will help the Building Owners understand the roles, rights and ɫƵ of the Builder, the Building Owner and the building surveyor. A copy of the guide, and additional information about domestic building contracts and work, is available at  HYPERLINK "http://consumer.vic.gov.au/buildingguide" consumer.vic.gov.au/buildingguide. The  HYPERLINK \l "_Checklist_for_the_1" Checklist for the Building Owner, later in this document, is required by law and must be completed and signed by the Building Owner (and not by the Builder) before signing the contract. It ensures the Building Owner has considered important issues before signing the contract. It also helps the Building Owner to communicate with the Builder about those issues before finalising the contract. The  HYPERLINK \l "_Is_the_contract" checklist Is the contract complete and ready to be signed, later in this document, is a guide to assist both the Building Owner and the Builder before signing the contract. It ensures the Building Owner and the Builder have considered and understood important issues before signing the contract. It also helps the Building Owner and the Builder to communicate about those issues before finalizing the contract. This aims to reduce potential disputes and misunderstandings between the Building Owner and the Builder. 2. Check the Builder is registered The Building Owner should check with the ɫƵn Building Authority (visit the  HYPERLINK "http://www.vba.vic.gov.au/" ɫƵn Building Authority website) that the Builder holds a current registration with the ɫƵn Building Authority (or the Building Practitioners Board if registered before 1 September 2016) as a domestic builder. A simple check would be to view the Builders building practitioners registration card issued by the ɫƵn Building Authority (or the Building Practitioners Board if registered before 1 September 2016). For the purpose of construction of a new dwelling, the Builders registration number will be prefixed with either: DB-U- e.g. DB-U 1234 DB-M- e.g. DB-M 5678. In addition to viewing the Builders registration card, a Building Owner should also check that the Builders registration is current. This is a simple process. Visit the  HYPERLINK "http://www.vba.vic.gov.au/" ɫƵn Building Authority website and follow the links to find a practitioner, then enter the Builders registration number. The status of the Builders registration will then be confirmed. There are additional requirements when a building owner engages a builder with a registration number beginning with DB-M. The Building Owner should refer to the ɫƵn Building Authority website for further information. 3. Foundations Data The law requires that the soil is tested to assess the type and cost of footings suitable for the site. The Act defines this testing as Foundations Data. This testing is important because, for example, rock hidden beneath the surface will significantly increase the cost of excavating the site. The law requires the Builder to obtain the Foundations Data for the Building Site before signing the contract. The Building Owner should confirm that the Builder has done this. The cost of testing is not part of the Contract Price because the Builder needs this information before setting the Contract Price. 4. Be precise in requirements It is best that the Building Owner: specifies the type of finish, colour code and exact model of appliances, fixtures or fittings in the plans and specifications attached to this contract ensures exact pricing for as many items as possible is included in the contract. This will help to avoid misunderstandings or disputes. 5. Get estimates when exact pricing is not possible Sometimes a builder is unable to give an exact price for a particular item (for example, a fixture or fitting), or an exact price for carrying out a particular part of the Work. In this case (by law), the Builder is required to provide a written estimate in the Prime Cost Item or Provisional Sum Schedules. Any estimate must include a breakdown of the actual quantities of material and unit cost to the Builder. The Builder must also give the Building Owner or the Building Owners Representative a reasonable opportunity to be at the Building Site when the Work nominated in the Prime Cost Item or Provisional Sum Schedules is to be performed. 6. Deposit The law limits the amount of the deposit the Builder can receive as follows: 5% of any Contract Price that is $20,000 or more 10% of any Contract Price that is less than $20,000. It is an offence under the Act for a builder to seek a deposit in excess of the relevant amount above. 7. Completing the document Where the contract provides for details to be filled in but that part of the contract is not applicable, the area that would ordinarily be filled in should be crossed out with a diagonal line rather than leaving it blank. 8. Permits and prescribed approvals Work required to be carried out under this contract cannot commence until a building permit has been issued for the Work. It may also be necessary for a planning permit and other prescribed approvals to be issued before the building permit can be issued. The term Approval Work in this contract refers to the work necessary to be undertaken to get the building permit and other permits and approvals, but does not include the appointment of a private building surveyor or applying for and obtaining an occupancy permit. The Building Act 1993 prohibits the Builder from appointing a private building surveyor on behalf of the Building Owner. The default in this contract is for the Builder to undertake the Approval Work. However, the contract also provides an option for the Building Owner to release the Builder from any obligation to undertake the Approval Work. In that case, the Building Owner is responsible for undertaking the Approval Work. If the Builder is to complete the Approval Work, the Building Owner is authorising the Builder to make any application, appeal, referral or representation under the Building Act 1993 and any other authorisation required to complete the Approval Work on behalf of the Building Owner. Before a building permit can be obtained, the Building Owner must appoint a private building surveyor, or authorise the Builder to apply to a municipal building surveyor for a permit on the Building Owners behalf, or apply to the municipal building surveyor for a permit if the Building Owner releases the Builder from the obligation to apply for a permit. There are penalties for the Building Owner and the Builder if a building permit is not obtained. The Building Owner can search for a private building surveyor on the HYPERLINK "http://www.vba.vic.gov.au/consumers/building-for-consumers/building-surveyor" \l "appointing_a_building_surveyor" VBA website. For more information about municipal building surveyors contact the local council. 9. Domestic Building Insurance What is Domestic Building Insurance? Domestic Building Insurance is last resort insurance and provides insurance only in the event the Builder dies, disappears, becomes insolvent, or, for policies issued by the ɫƵn Managed Insurance Authority (VMIA) after 1 July 2015, fails to comply with a Tribunal or Court order after 28 days. This insurance does not provide warranty protection or general cover. Domestic Building Insurance requirements are set out in  HYPERLINK \l "_8._Domestic_Building_1" Clause 8 of this contract. When is Domestic Building Insurance required? Where the Contract Price for the carrying out of the Work is more than $16,000, the law requires the Builder to take out Domestic Building Insurance for an individual project. Domestic Building Insurance must be taken out before the: building permit for the Work can be issued Builder can enforce any term of this contract Work can commence. The Building Owner must make sure they get a copy of the Domestic Building Insurance documents identified in  HYPERLINK \l "Clause_8_4" Clause8.4 prior to the Work commencing. These documents are: a) a copy of the Domestic Building Insurance policy b) the certificate of insurance c) a summary of the insurance product. The Building Owner should check that the Contract Price matches the value stated in the Domestic Building Insurance policy. What does Domestic Building Insurance cover? If the Builder dies, disappears or becomes insolvent, Domestic Building Insurance may provide some compensation to the Building Owner for loss or damage resulting from: non-completion of the Work defective Work a breach of warranty implied into the domestic building contract by section 8 of the Act a failure to maintain a standard or quality of Work specified in the domestic building contract conduct by the Builder in connection with the domestic building contract that contravenes a trade practices provision. How long does Domestic Building Insurance cover last? For non-structural Defects, Domestic Building Insurance provides an indemnity for loss or damage occurring during the period starting on the commencement day of this contract and ending two years after the earlier of the: Completion of Work date of termination of the contract. For all other loss or damage, Domestic Building Insurance provides an indemnity for the period starting on the commencement day of this contract and ending six years after the earlier of the: Completion of Work date of termination of the contract. 10. Other insurance requirements General requirements for insurances to be provided by the Builder, other than Domestic Building Insurance, are set out in HYPERLINK \l "_42._Insurance"Clause 42 of this contract. 11. Builders warranties Under the Act the Builder gives warranties relating to the Work and these are identified in HYPERLINK \l "_17._Builders_warranties_1"Clause 17 of this contract. If the Builder has not died, disappeared, become insolvent, or, for policies issued by the VMIA after 1 July 2015, failed to comply with a Tribunal or Court order, and an issue arises about the standard of workmanship, either during the construction of the building, or during the 10 years after the Completion of Work, or whether the Builder has met the terms of the contract including completing the contract, the Builder and the Building Owner must resolve the dispute under the terms of the contract and at common law. If the Builder has not died, disappeared, become insolvent, or for policies issued by the VMIA after 1 July 2015, failed to comply with a Tribunal or Court order, the Building Owner cannot make a claim on the Domestic Building Insurance policy in respect of a warranty claim for the Work or the performance of the Builder. 12. Parties authorised representatives The Building Owner and the Builder must nominate their representative in the Contract Details in  HYPERLINK \l "_4._Contract_Details_17" Clause4, together with their contact details. The Building Owners Representative and the Builders Representative must be contactable during normal business hours. If the nominated representative for either party changes, the parties should notify each other as soon as possible in writing by the agreed service method stated in the Contract Details in  HYPERLINK \l "_4._Contract_Details_1" Clause 4. 13. Termination of contract The Building Act 1993 requires the Building Owner and the Builder each to notify the building surveyor for the Work within 14 days after the engagement of the Builder ends by termination of the contract. Failure to perform this notification can incur a maximum penalty of 10 penalty units. The Building Owner should discuss with the building surveyor the capacity to continue the Work once the contract with the Builder is terminated and the process required for notification of appointment of a subsequent builder. If the Building Owner does not intend to complete the Work, either by appointing another builder or completing the Work themselves, the Building Owner should discuss with the relevant building surveyor how this affects compliance with the requirements of the Building Act 1993 and any subsequent prescribed approval. Part A: Check the following lists before signing the contract Director of Consumer Affairs ɫƵ Approved Domestic Building Contracts Checklist Section 31(1)(r) of the Domestic Building Contracts Act 1995 This checklist must be included in major domestic building contracts entered into from 1 September 2016 in substantially the same form or to the same effect as follows. Before signing this legally binding contract, the Building Owner must check this list: If the cost of the building work is more than $16,000, has an insurance policy or certificate of currency for domestic building insurance covering your project been issued and provided to you? (Note: If not, the contract is conditional upon you receiving either an insurance policy or a certificate of currency for domestic building insurance.)YesNoIf this contract is conditional upon you receiving written approval for finance, have you obtained such approval?YesNoHave you appointed a private building surveyor or has a municipal building surveyor been engaged? (Note: If not, you will need to choose and engage a building surveyor before your building work starts so that a building permit can be issued for your building work.)YesNoIf you answer NO to any of the following questions that apply to your building project, you are not ready to sign the contract:*Have you had this contract long enough to read and understand it?YesNoHave you been provided with evidence that the builder named in this contract is registered with the ɫƵn Building Authority?YesNoAre the price and progress payments clearly stated?YesNoDo you understand how the price is calculated and may be varied?YesNoHas the builder assessed the suitability of the site for the proposed works? If tests are necessary, have they been carried out?YesNoIf a deposit is payable, is it within the legal limit? The maximum under the Domestic Building Contracts Act 1995 is: 10% if the price is less than $20,000, or 5% if the price is $20,000 or more.YesNoIs the work shown and described clearly in the contract, plans and specifications and any other relevant documents (such as engineering computations or soil report)?YesNoAre your special requirements or standards of finish included in the plans and specifications?YesNoAre the commencement date and completion date clearly stated or capable of being worked out?YesNoDo you understand the procedure for extensions of time?YesNoAre any provisional sums or prime cost items clearly stated in the schedules and understood by you?YesNoDo you understand the procedure for variations of plans and specifications?YesNoDo you understand the circumstances in which you can end the contract?YesNoDid your builder give you a copy of the Domestic Building Consumer Guide?YesNoIf yes, insert the date on which you were given a copy of this guide dd/mm/yyyy Have you read the Domestic Building Consumer Guide and the related information at consumer.vic.gov.au/buildingguide?YesNoThis checklist does not form part of the contract. I/we have read and completed this checklist: Signature/s of Building OwnerDate dd/mm/yyyy * Note: Not all of these questions will apply to a domestic building contract that covers a limited scope of work, for example, a contract that is limited to the preparation of building plans and specifications. Is the contract complete and ready to be signed? This checklist prompts the Builder to fill in all the required sections in this contract. Both the Builder and the Building Owner should go through this checklist before signing the contract. Note: This checklist does not form part of the contract. [Form begins] Checklist itemResponse (YesorNo)1. Have the Contract Details in  HYPERLINK \l "_4._Contract_Details_4" Clause 4 been filled in?2. Has the Finish Date or number of days required to finish the Work once it is commenced under  HYPERLINK \l "Clause_13_1" Clause 13.1 been calculated and filled-in in the Contract Details in  HYPERLINK \l "_4._Contract_Details_5" Clause 4?3. Has the Contract Price in  HYPERLINK \l "Clause_5_1" Clause 5.1 been filled in?4. Are there any agreed exclusions from the Contract Price? If so, have the agreed exclusions been included in the table in  HYPERLINK \l "Clause_5_2" Clause 5.2?5. If it is agreed to exclude some fixtures and fittings from the Contract Price, have the exclusions been listed in  HYPERLINK \l "Clause_5_3" Clause 5.3?6. Has a detailed description of the Work required in  HYPERLINK \l "Clause_9_3" Clause 9.3 been filled in?7. Has the Builder provided the Building Owner with a copy of the policy of Domestic Building Insurance, Certificate of Insurance and summary of insurance product as required under  HYPERLINK \l "Clause_8_4" Clause 8.4?8. Has the deposit amount in  HYPERLINK \l "Clause_6_1" Clause 6.1 been filled in?9. Has the staged payment of the deposit been calculated and do both the Builder and the Building Owner understand when it is due? The staged payment of the deposit is as follows: 80% of the deposit when the contract has been signed and a copy of the Domestic Building Insurance policy provided to the Building Owner (see  HYPERLINK \l "Clause_6_2" Clause 6.2(a)) 20% of the deposit when Work has commenced. (see  HYPERLINK \l "Clause_6_2" Clause 6.2(b))10. Has the Builder listed all the documents that form part of the plans and specification documents ( HYPERLINK \l "Clause_10_3" Clause 10.3) in the  HYPERLINK \l "_Document_List_Attachment_3" Document List Attachment?11. Has the Builder filled in the description of the Foundations Data in  HYPERLINK \l "Clause_12_2" Clause 12.2?12. Have the Builder and the Building Owner completed the General Attachment? (seeHYPERLINK \l "Clause_12_15"Clause 12.15 and  HYPERLINK \l "Clause_20_2" Clause 20.2)13. Has the agreed commencement of Work date (if applicable) in the Contract Details been filled-in in  HYPERLINK \l "_4._Contract_Details_6" Clause 4? (see also  HYPERLINK \l "Clause_13_1" Clause 13.1)14. Has the Builder estimated and listed the number of days allowed for Inclement Weather, holidays and other delays? (see  HYPERLINK \l "Clause_14_4" Clause 14.4)15. Has the Builder identified in  HYPERLINK \l "Clause_14_5" Clause 14.5 the likely cause of any delay that cannot be estimated as a period of time?16. Has the Building Owner provided details in  HYPERLINK \l "Clause_15_1" Clause 15.1 of the likely loss and damage they expect to incur if the Builder fails to complete the Work by the Finish Date?17. Has the Building Owner stated in  HYPERLINK \l "Clause_16_1" Clause 16.1 the particular purpose for which the Work is required or the result desired to be achieved?18. Has the Building Owner read and initialled  HYPERLINK \l "Clause_17_3" Clause 17.3 that relates to the Builders warranties?19. Has the Building Owner made this contract subject to finance and, if so, has the loan amount in the Contract Details in  HYPERLINK \l "_4._Contract_Details_7" Clause 4 been filled in? (see also  HYPERLINK \l "_19._Loan_approvals_2" Clause 19)20. Have the Building Owner and the Builder read and initialled  HYPERLINK \l "_Section_37__2" sections 37 and 38 of the Act in the Legislation Extracts? This relates to Variations under  HYPERLINK \l "_23._Variations_2" Clause 23.21. Has the Builders reasonable margin for Variations, Provisional Sums and Prime Cost Items been specified in the Contract Details in  HYPERLINK \l "_4._Contract_Details_8" Clause 4?22. Have the Building Owner and the Builder read and initialled  HYPERLINK \l "_Section_40__1" sections 40(1) and (2) of the Act in the Legislation Extracts? This relates to progress payments under  HYPERLINK \l "_7._Progress_payments_2" Clause 7.23. Are the Building Owner and the Builder both ready to sign and date this contract in  HYPERLINK \l "_11._Signatures_1" Clause 11?Read, signed and dated by the Building Owner(s) Signature(s):Date:Read, signed and dated by the Builder Signature(s):Date:[Form ends] Part B: Terms of the contract This is the commencement of the contract terms 1. Definitions Clause function: This clause defines terms used throughout this contract. In this contract, the following definitions apply, unless the context requires a different meaning: Act means the Domestic Building Contracts Act 1995. Approval Work means the work necessary to apply for and obtain the building permits and any prescribed approvals for the Work but does not include the appointment of a private building surveyor or applying for and obtaining an occupancy permit. Builder means the person, partnership or company named in the Contract Details as the Builder and includes the Builders employees, agents, contractors, heirs, executors, administrators and permitted assignees and transferees. Builders Representative means the natural person identified by the Builder in the Contract Details as authorised to communicate on behalf of the Builder with the Building Owner. Building Owner means the person, partnership or company named in the Contract Details as the Building Owner and includes the Building Owners heirs, executors, administrators and permitted assignees and transferees. Building Owners Representative means the natural person identified by the Building Owner in the Contract Details as authorised to communicate on behalf of the Building Owner with the Builder. Building Site means the place where the Work is to be carried out and is described in the Contract Details. Business Day means a day that is not: Saturday or Sunday a public holiday in ɫƵ (whether a whole day or part of a day). Completion of Work means the time when the Work is complete in accordance with  HYPERLINK \l "_31._Completion_of" Clause 31. Contract Details means the contract details set out in  HYPERLINK \l "_4._Contract_Details_9" Clause 4. Contract Price means the total amount payable under this contract and includes the amount: the Builder is to receive and retain under this contract the Builder is to receive under the contract for payment to any other person any third person is to receive (or is reasonably estimated to receive) directly from the Building Owner for: conveying to the Building Site or connecting or installing services such as gas, electricity, telephone, water and sewerage, or issuing planning and building permits. The Contract Price does not include any amount that the Builder excludes in accordance with  HYPERLINK \l "Clause_5_2" Clause 5.2. Defect means: Work that is in breach of a warranty in  HYPERLINK \l "Clause_17_1" Clause 17.1 Work that is not of a standard or quality specified in this contract a failure to carry out and complete the Work in accordance with, and as required by, the plans and specifications and this contract. Dispute Resolution Procedure means the dispute resolution procedure set out in  HYPERLINK \l "_34._Dispute_Resolution_1" Clause 34. Domestic Building Dispute has the HYPERLINK \l "domestic_building_dispute"meaning given in section 54 of the Act reproduced in the Legislation Extracts. Domestic Building Insurance means the insurance described in  HYPERLINK \l "Clause_8_1" Clause 8.1. Extension of Time means a period of postponement of the Finish Date. Final Completion has the meaning in  HYPERLINK \l "Clause_28_2" Clause 28.2. Finish Date means the date stated in the Contract Details as the date when the Work will be finished. If no date is stated, Finish Date means the date calculated by adding the number of days stated in the Contract Details as being required to finish the Work to the date of commencement of Work set out in  HYPERLINK \l "Clause_13_1" Clause 13.1. Foundations Data has the meaning given in  HYPERLINK \l "_Section_30_" section 30(3) of the Act reproduced in the Legislation Extracts. Inclement Weather means weather during which it is either not reasonable or not safe to continue the Work. Legislation Extracts means the provisions set out in  HYPERLINK \l "_Part_C:_Legislation_2" Part C headed Legislation Extracts, which form part of this contract. Lender means a bank, building society or other financier that lends the Building Owner the Contract Price or any portion of that amount. Loan Approval Date means the date in the Contract Details in  HYPERLINK \l "_4._Contract_Details_10" Clause 4 that has been nominated by the Building Owner as the date by which the Building Owner expects a loan application for the purpose of the Work will be determined. Opinion Procedure means the opinion procedure set out in  HYPERLINK \l "_32._Completion_notifications_1" Clause 32. Penalty Interest Rate means the interest rate fixed from time to time under section 2 of the Penalty Interest Rates Act 1983. Prime Cost Item has the  HYPERLINK \l "prime_cost_item" meaning given in section 3 of the Act reproduced in the Legislation Extracts. Provisional Sum has the  HYPERLINK \l "provisional_sum" meaning given in section 3 of the Act reproduced in the Legislation Extracts. Variation means a variation according to law or  HYPERLINK \l "_23._Variations_3" Clause 23 of this contract (or both). Work means the work required to be carried out under this contract, which is described in  HYPERLINK \l "Clause_9_3" Clause 9.3 and described in more detail in the plans and specifications (which are attached to this contract). Work does not include Approval Work. 2. Interpretation Clause function: This clause provides guidance about how the contract is to be interpreted. 2.1 In this contract, except where the context makes it clear that another meaning is intended, the following rules apply. 2.2 A word (or words) in italics and starting with a capital letter is a defined term for the purposes of this contract. This means it has the meaning outlined in  HYPERLINK \l "_1._Definitions_2" Clause 1 (Note: Legislation is also italicised but should not be read as a defined term). 2.3 A reference to a Clause is a reference to one of the numbered Clauses under Part B of this contract. 2.4 A reference to an Attachment is a reference to one of the attachments to this contract (the  HYPERLINK \l "_Document_List_Attachment_4" Document List Attachment and the  HYPERLINK \l "_General_Attachment_2" General Attachment). 2.5 A reference to a person in this contract includes a partnership or a company. 2.6 Words suggesting the singular include the plural and vice versa. 2.7 Headings, clause function notes and user notes in shaded text boxes are advisory notes only and must not be used to interpret this contract. 2.8 A reference to include or including or for example in a list does not mean that items not listed are not included. 2.9 In the event of a conflict that cannot be resolved between the drawings and the relevant text, the meaning of the text will take precedence. 3. Communication between the Building Owner and the Builder Clause function: This clause states how the parties to the contract will communicate with each other. 3.1 Communication between the parties for the purposes of this contract must be made between the Builder and the Building Owner or their appointed representatives nominated in  HYPERLINK \l "_4._Contract_Details_11" Clause 4 in the Contract Details. 3.2 If the Building Owner communicates with the Builders Representative in a way that complies with this contract it means the same as having communicated with the Builder. Similarly, if the Builder communicates with the Building Owners Representative in a way that complies with this contract it means the same as having communicated with the Building Owner. 3.3 The Building Owner must not give directions to the Builders employees or sub-contractors except as provided in  HYPERLINK \l "Clause_3_1" Clause 3.1. 3.4 The Building Owner can only rely on statements or representations as to any matter concerning the Work or its progress that are made by the Builder or the Builders Representative. The Builder can only rely on statements or representations as to any matter concerning the Work that are made by the Building Owner or the Building Owners Representative. 3.5 Wherever this contract requires the Building Owner or the Builder to make a demand or claim, serve a notice or document or communicate in connection with this contract, such demand, notice, document or other communication must be written in English and must be legible. As appropriate, such communication may be by the forms that are attached to this contract. Where a demand, claim notice, document or other communication is given in person, a written receipt should be given. Otherwise, all communications may be delivered by a method stated in the Contract Details (or to a subsequent address, if one is notified subsequently). 3.6 Receipt of service Unless otherwise established by contrary evidence, a demand, claim, notice, document or other communication in connection with this contract is taken to be received at the following times: a) if sent by post before 5.00pm on the day of posting: i) the second day after posting, if posted to or from a place within the State of ɫƵ or an interstate capital city ii) five Business Days after posting, if posted to or from a place within another state within Australia other than a capital city iii) 10 Business Days after posting, if posted to or from a place outside Australia b) if delivered by hand, at the time of delivery, if delivered to the person or left at the persons address nominated in  HYPERLINK \l "_4._Contract_Details_17" Clause4 with a person not less than 16 years of age and apparently residing or employed at that place c) in the case of a facsimile if sent before 5.00pm on a Business Day, on the day it is sent and, if sent later in the day, on the next Business Day d) in the case of electronic mail, if sent before 5.00pm on a Business Day, on the day it is sent and, if sent later in the day, on the next Business Day. 4. Contract Details Clause function: This clause sets out relevant particulars of the contract. [Form begins] Building Owner Name(s):Address and address for service of documents Address:Postal address (for service of documents include postcode):Contact details Business:After Hours:Mobile:Fax:Email: Building Owners preferred method(s) of receipt of a demand, claim, notice, document or other communication in connection with this contract (there are three options mark the option/s which apply with an X):Mail:Fax:Email:[Form continues next page] Building Owners Representative Name(s):Address and address for service of documents Address:Postal address (for service of documents include postcode):Contact details Business:After Hours:Mobile:Fax:Email: Building Owners Representatives preferred method(s) of receipt of a demand, claim, notice, document or other communication in connection with this contract (there are three options mark the option/s which apply with an X):Mail:Fax:Email:[Form continues next page] Builder Name(s):Address and address for service of documents Address:Postal address (for service of documents include postcode): Australian Company Number (ifapplicable):Australian Business Number (ifapplicable):Contact details Business:After Hours:Mobile:Fax:Email: Builders preferred method(s) of receipt of a demand, claim, notice, document or other communication in connection with this contract (there are three options mark the option/s which apply with an X):Mail:Fax:Email: Name of registered building practitioner (as shown on the ɫƵn Building Authority or Building Practitioners Board registration card):Registration number (as shown on the ɫƵn Building Authority or Building Practitioners Board registration card):Category of Work shown on the registration (as shown on the registration (as shown on the ɫƵn Building Authority or Building Practitioners Board registration card):Insurer providing Domestic Building Insurance (DBI):DBI Policy number:Date of issue of policy:[Form continues next page] Builders Representative Name(s):Address and address for service of documents Address:Postal address (for service of documents include postcode):Contact details Business:After Hours:Mobile:Fax:Email: Builders Representatives preferred method(s) of receipt of a demand, claim, notice, document or other communication in connection with this contract (there are three options mark the option/s which apply with an X):Mail:Fax:Email:[Form continues next page] Building Site Address Street address number:Unit number (if applicable):Street name:Suburb:Postcode: Title details/property identifier Volume:Folio number:Lot/plan number:Other property identifier (please specify):Timing Agreed commencement date (If no date is specified here, then the commencement date will be determined under  HYPERLINK \l "Clause_13_1" Clause 13.1):Finish Date or number of days required to finish Work once it is commenced under  HYPERLINK \l "Clause_13_1" Clause 13.1:Finance This contract it subject to loan approval (see  HYPERLINK \l "_19._Loan_approvals_3" Clause 19) (YesorNo):Loan amount (if applicable):Name of Lender:Loan Approval Date:Other The following Work is to be performed by the Building Owner:The Building Owners undertaking to obtain permits and prescribed approvals  HYPERLINK \l "_18._Permits,_prescribed" Clause 18 provides that the Builder will undertake the Approval Work unless otherwise stated. The Builder is exempt from undertaking the Approval Work by ticking the boxes below.  HYPERLINK \l "Clause_18_2" Clause 18.2 requires that, if the Builder is responsible for applying for a building permit, the Building Owner must, as soon as practicable, appoint a private building surveyor and give notice to the Builder of the appointment, or give instructions to the Builder to apply to a municipal building surveyor for a building permit. The Building Owner will be responsible and so releases the Builder from the obligation under  HYPERLINK \l "Clause_18_1" Clause 18.1 to obtain the necessary (there are three options mark the option/s which apply with an X and provide details where applicable):planning approvalbuilding permitother prescribed approval being:Builders margin The margin must be reasonable. A rule of thumb is around 20%. The Builders margin for overheads supervision and profit under  HYPERLINK \l "_23._Variations_4" Clause 23 (Variations),  HYPERLINK \l "Clause_24_4" Clause 24.4 (Provisional Sum item) and  HYPERLINK \l "Clause_25_4" Clause 25.4 (Prime Cost Item) is (specify percentage margin):[Form ends] 5. Contract Price Clause function: This clause sets out the Contract Price for the Work and any additional charges that could apply. 5.1 The Building Owner will pay the Contract Price in accordance with the terms of this contract [Form begins] Contract Price (amount in words):$[Form ends] Form pursuant to section 33(2)(b) Price Warning: Changes to the Contract Price The price of this contract may be altered as a result of: the actual cost of Prime Cost Items and Work for which Provisional Sums have been specified being more or less than the estimates set out in the contract (see  HYPERLINK \l "_24._Provisional_Sums_2" Clause 24 and  HYPERLINK \l "_25._Prime_Cost_2" Clause 25) Variations, including those required by council or a registered building surveyor (see  HYPERLINK \l "_23._Variations_5" Clause 23) interest on overdue payments (see  HYPERLINK \l "Clause_27_2" Clause 27.2). Ensure that you fully understand how the clauses dealing with these matters may affect the Contract Price. Warning to the Building Owner as to Prime Cost Items It is always better to get a fixed price for all Work even your fixtures and fittings (for example, type and model of stove or taps). However, some fixtures and fittings may need to be selected after the contract is signed. Alternatively, for fixtures and fittings that are considered a special order, the fixed price for the supply of the goods may not be available at the time of entering into the contract. If these items are specified as Prime Cost Items, the Builder will allow an amount in the Contract Price, which should cover the expected cost of the item. If the actual cost of the Prime Cost Item is more than the amount allowed for, you will have to pay the extra amount. You may also have to pay the Builders margin on the goods as part of that extra amount. If this is intended, the margin should be specified otherwise it cannot be claimed unless you agree in writing to such an additional amount. If the Prime Cost Item costs less than is allowed for in the contract, the difference should be deducted from the Contract Price. Warning to the Building Owner as to Provisional Sum Items It is always better to get a fixed price for all Work and provide sufficient information for the Builder to accurately estimate how fittings, fixtures and materials are to be installed. This is critical to minimising the need for Provisional Sum items. However, even after making all reasonable inquiries, the Builder may not be able at the time of entering into the contract to give a definitive figure for the cost of carrying out a particular Work (including the supplying of materials needed to carry out the Work). If this Work is specified as a Provisional Sum item, the Builder will allow an amount in the Contract Price, which should cover the expected cost of the item. If the actual Provisional Sum cost is more than the amount allowed for, you will have to pay the extra amount. You may also have to pay the Builders margin on the Provisional Sum item as part of that extra amount. If this is intended, the margin should be specified otherwise it cannot be claimed unless you agree in writing to such an additional amount. If the Provisional Sum item costs less than is allowed for in the contract, the difference should be deducted from the Contract Price. 5.2 The Builder states that the Contract Price does not include the amount a third person is to receive (or is reasonably estimated will receive) for any Work or thing stated in the table below: Clause 5.2 note: This section is optional. If there are no exclusions from the Contract Price, cross out this section. [Form begins] Work or thing not included in the Contract PriceReasonably estimated amount ($)Amount or % of Builder profit marginName of third person to receive amounta) Conveying, connecting or installing services:gaselectricitytelephonewatersewerageotherb) Permits and approvals:planningbuildingother required permitsother prescribed approvalsEstimated total cost of excluded items[Form ends] 5.3 The Contract Price includes the cost of any fixtures or fittings shown in the plans and specifications included in this contract, except for those fixtures or fittings stated in the table below (after the note). Clause 5.3 note: This clause is optional. If the Contract Price does not exclude the cost of any fixtures or fittings, cross out this clause. If there are items listed in this table, the Building Owner will be required to pay for these items in addition to the Contract Price. If there are items in this table, the Act requires the Building Owner to sign here. [Form begins] Fixtures or fittings not included in the Contract PriceReference to plans or specifications page numbersEstimated price ($)Signature of Building Owner(s):[Form ends] 5.4 After signing this contract, the Contract Price may only be adjusted in accordance with this contract. 5.5 The Contract Price includes all taxes (including GST) associated with the Work. Any pricing, consideration and progress amounts payable under this contract will be calculated on a GST inclusive basis. This includes any Variation under  HYPERLINK \l "_23._Variations_6" Clause 23. 5.6 The Builder warrants that the Contract Price is based upon Building Site inspections and all other investigations that would be undertaken by an experienced and competent builder. It includes the performance of all the necessary ancillary Work, inspection of the site and processes that would be undertaken by a builder exercising reasonable care and skill, whether described in the plans and specifications or not, and the provision of all equipment and materials for that purpose. 5.7 In the event that the Builder wishes to vary the plans and specifications as a result of conditions that could not reasonably have been ascertained from the Foundations Data, the Builder will apply for any necessary Variation under  HYPERLINK \l "_Section_37__6" section 37 of the Act. 6. Deposit Clause function: This clause sets out the deposit to be paid under the contract. 6.1 The total deposit under this contract is 5% of the Contract Price, which is equal to: [Form begins] (amount in words):$[Form ends] [Form begins] 6.2 The deposit will be paid as follows: 80% of the deposit being ($ insert amount here ) will be paid on the Builder giving to the Building Owner all the documents mentioned in  HYPERLINK \l "Clause_8_4" Clause 8.4 relating to Domestic Building Insurance 20% of the deposit being ($ insert amount here ) will be paid within five Business Days of the Building Owner receiving from the Builder a notice that states that the Builder has made a substantial commencement of the Work and stating the date of such commencement. [Form ends]  HYPERLINK \l "_FORM_A_" Form A in Part D of the contract can be used for the purpose of giving this notice. 6.3 If the Building Owner has paid the Builder a deposit that is more than the amount payable to the Builder under this clause, the Builder must refund the excess to the Building Owner within five Business Days of receiving the excess amount. Clause 6 notes The Act prevents a builder from demanding or receiving, before they commence Work, a deposit that is more than 5% of the Contract Price if the Contract Price is $20,000 or more. If the Builder does not comply with this legislative provision, section 11 of the Act enables the Building Owner to void the contract at any time before it is completed. The law also provides that the Building Owner must have received a copy of the Domestic Building Insurance policy before the deposit is payable. This contract splits up the deposit so that 80% of the deposit is payable once the Building Owner receives the documents relating to Domestic Building Insurance identified in  HYPERLINK \l "Clause_8_4" Clause 8.4 and the balance is payable when the Building Owner receives a notice from the Builder advising that building Work has substantially commenced. 7. Progress payments Clause function: This clause sets out the progress payments under the contract. 7.1 At the relevant stages defined in  HYPERLINK \l "_Section_40__2" section 40(1) of the Act, the Builder may demand and recover or retain amounts by way of progress payments for the Work done that are not a greater percentage of the Contract Price than permitted by section 40 of the Act.  HYPERLINK \l "_FORM_J_" Form J in Part D of the contract can be used to make a claim for a progress payment. 7.2 The Builder and the Building Owner acknowledge they have read and initialed the terms set out in  HYPERLINK \l "_Section_40__3" sections 40(1) and 40(2) of the Act, reproduced in the Legislation Extracts. 7.3 The Building Owner is not entitled to make deductions from a progress payment because of any claim made by the Building Owner against the Builder (whether the claim is made under this contract or otherwise). 7.4 If the Builder claims they cannot complete the Work solely for the reason in  HYPERLINK \l "Clause_22_1" Clause 22.1(d), the Builder may demand and recover a further payment of not more than 5% of the Contract Price, less the Builders reasonable estimate of the cost to rectify the Defect preventing Completion of Work. Clause 7 notes For a description of the stages and percentages allowed, see the  HYPERLINK \l "Table_progress_payments" table in section 40 of the Act reproduced in the Legislation Extracts. It is important that the Building Owner ensures each of the stages is complete before making a progress payment. Under this contract, the Builder cannot demand, recover or retain more than the legislated percentage of the Contract Price for each stage of work. [Form begins] Table of payments and progress payments Type of contract% of Contract PriceAmount $Payments and stagesContract to build all stages5%Deposit10%Base stage15%Frame stage35%Lock-up stage25%Fixing stage10%Final payment100%Total[Form ends] 8. Domestic Building Insurance Clause function: This clause sets out the requirements for Domestic Building Insurance. 8.1 The Builder must obtain Domestic Building Insurance that: a) complies with Domestic Building Insurance Ministerial Order No. 98 of 23 May 2003 or any subsequent Order that replaces or amends that Ministerial Order before the required Domestic Building Insurance is obtained b) covers the Work to be carried out under this contract. 8.2 The Builder must pay the insurance premium for the Domestic Building Insurance. 8.3 The Builder must not enforce any provision of this contract, perform any Domestic Building Work under this contract or demand or receive any money (including deposit money) payable under this contract until the Domestic Building Insurance policy has been issued. 8.4 The Builder must give to the Building Owner the following documents within seven Business Days of the policy of Domestic Building Insurance being issued: a) a copy of the Domestic Building Insurance policy b) the certificate of insurance c) a summary of the insurance product. Clause 8 note The Building Owner should not pay the deposit until the Building Owner has received the documents relating to Domestic Building Insurance identified in  HYPERLINK \l "Clause_8_4" Clause 8.4. 9. Obligations of the Builder and the Building Owner Clause function: This clause sets out the obligations of the Builder and the Building Owner. 9.1 The Builder will perform the Work and any Approval Work in accordance with the terms of this contract and according to law. 9.2 The Builder will apply for and obtain an occupancy permit if required by the building permit. 9.3 The following is a description of the Work: [Form begins] Complete detailed description of the Work Insert a description of what is to be built, for example, construction of a new home, carport, brick fence and landscaping. Include as much information as possible. Further detail of the Work is included in the plans and specifications, which form part of this contract.[Form ends] 10. Contract documents Clause function: This clause identifies the documents that form part of the contract. 10.1 This contract includes all the writing that follows the words This is the Commencement of the contract terms at the beginning of  HYPERLINK \l "_Part_B:_Terms_2" Part B, including the  HYPERLINK \l "_Document_List_Attachment_5" Attachments and the  HYPERLINK \l "_Provisional_Sums_Schedule_3" Schedules. 10.2 The plans and specifications and other documents for the Work listed in the  HYPERLINK \l "_Document_List_Attachment_6" Document List Attachment and the documents referred to in the  HYPERLINK \l "_General_Attachment_3" General Attachment are part of this contract. 10.3 The Builder warrants that they have given the Building Owner a copy of all the documents that the Builder lists in the  HYPERLINK \l "_Document_List_Attachment_7" Document List Attachment. Clause 10.3 note: The Building Owner should check that they have received all the documents listed in the  HYPERLINK \l "_Document_List_Attachment_8" Document List Attachment and keep a copy of these documents for their records. 10.4 As soon as is practicable, but no later than five Business Days after entering into this contract, the Builder must give the Building Owner a signed copy of the contract. [Form begins] 11. Signatures Clause function: This clause is where the contract is formally signed. Warning before signing the contract Warning: The Building Owner and the Builder should read the checklists in  HYPERLINK \l "_Part_A:_Check_1" Part A of this contract to check they are aware of key terms and conditions and have completed all sections before signing this contract. Building Owner(s)Name:Signature:Name:Signature:Date: Builder:Company name:Australian Company Number (ifapplicable):Australian Business Number (ifapplicable): Authorised personName:Signature:Authorised person:Date:[Form ends] 12. General conditions of contract Clause function: This clause outlines important general conditions of the contract. 12.1 The Builder warrants that before entering into the contract, the Builder has complied with each of the Builders obligations under  HYPERLINK \l "_Section_30__1" section 30 of the Act reproduced in the Legislation Extracts relating to Foundations Data and will continue to do so. 12.2 The Builder warrants that the following Foundations Data has been obtained for the Building Site before entering into this contract: [Form begins] Description of Foundations Data (e.g. ɫƵ, survey, test, computation)Person or company that provided reportDate issued[Form ends] 12.3 The Builder will ensure that the Building Site is on the land identified in the title details in the Contract Details. If there is any doubt as to the correct location of the boundaries of the Building Site, the Builder will take all necessary steps to determine the correct position of the boundaries. 12.4 The Builder may give the Building Owner a notice that within 10 Business Days after receiving the notice, the Building Owner must give the Builder satisfactory evidence of the: a) Building Owners title to the Building Site b) dimensions of the Building Site.  HYPERLINK \l "_FORM_B_" Form B in Part D of the contract can be used for the purpose of giving this notice. 12.5 If the position of the boundaries can only be determined by a licensed land surveyor, the Builder must provide a boundary survey. The Builder must notify the Building Owner of this intention before obtaining the survey, and must give a reasonable estimate of the cost. The Building Owner will be responsible for paying the reasonable cost of the survey.  HYPERLINK \l "_FORM_C_" Form C in Part D of the contract can be used for the purpose of giving this notice. 12.6 If the Building Owner fails to provide satisfactory evidence following a request under  HYPERLINK \l "Clause_12_4" Clause 12.4, the Builder may suspend the Work under  HYPERLINK \l "_35._Suspension_of_1" Clause 35, or take action to terminate this contract under  HYPERLINK \l "Clause_37_1" Clause 37.1. 12.7 The Building Owner may not assign rights and obligations under this contract without the prior written consent of the Builder. Similarly, the Builder may not assign rights and obligations under this contract without the prior written consent of the Building Owner. Such consents required by either party must not be unreasonably withheld. 12.8 The Builder may sub-contract any part (but not the whole) of the Work without the Building Owners consent. If they do so, the Builder is not relieved from liability and ɫƵ under this contract and the Builder must ensure that any sub-contracted Work complies with this contract. 12.9 The Building Owner and the Builder must cooperate to enable the other to carry out their obligations under this contract. 12.10 Either party may require the other to provide reasonable evidence of capacity to meet the terms of this contract. This request can be made at any time. On receiving such a request, the person must provide that evidence within 10 Business Days. Where such evidence is provided, the person who asked for the evidence must pay the reasonable amount of any costs incurred in obtaining and providing it. This amount should be added to, or deducted from, the Contract Price.  HYPERLINK \l "_FORM_D_" Form D in Part D of the contract can be used to make this request. 12.11 The rights, powers and remedies provided in this contract are cumulative with other law. They do not exclude the rights, powers and remedies provided by that law. 12.12 The Building Owner must notify the Builder in writing of any change in details of the Building Owners Representative. There is no requirement to change the Building Owners Representatives details in the Contract Details. 12.13 The Builder must notify the Building Owner in writing of any change in details of the Builders Representative. There is no requirement to change the Builders Representatives details in the Contract Details.  HYPERLINK \l "_FORM_E_" Form E in Part D of the contract can be used to notify the other party of a new representative. 12.14 Where more than one person signs this contract as the Building Owner, all such persons will be jointly and severally responsible for the obligations of the Building Owner pursuant to the terms of this contract. 12.15 The Building Owner will supply to the Builder each of the items listed in the General Attachment as being provided by the Building Owner. Upon the Builder giving to the Building Owner five Business Days notice that any such item is required by the Builder, the Building Owner will deliver the item at the Building Owners expense to the place directed by the Builder in the notice. Clause 12 notes The Building Owner must enable the Builder to perform the contract. This includes giving the Builder access to the Building Site. The Building Owner must also provide the Builder with evidence that they own the Building Site and that they can pay the Contract Price if the Builder asks in writing, complying with the contract. If asked in writing by the Building Owner, the Builder must show in writing that they can perform the contract. This might mean providing evidence that the Builder is solvent, currently registered and insured. 13. Commencement of Work Clause function: This clause states how the date of commencement of the Work is determined. 13.1 The Builder: a) will start the Work on the date (if any) specified in  HYPERLINK \l "_4._Contract_Details_12" Clause 4; or b) will start the Work within 10 Business Days of whichever is the latest of: i) the date the Builder receives the building permit for the Work ii) if the Lenders approval is required before the Work may proceed, the date the Builder receives notice of that approval. 13.2 If the commencement date is to be determined under  HYPERLINK \l "Clause_13_1" Clause 13.1(b), the Builder will do everything that it is reasonably possible for the Builder to do to ensure that the Work will start as soon as possible. 14. Finish Date Clause function: This clause states how the Finish Date is determined. 14.1 The Builder will perform the Work diligently and at a reasonable speed. 14.2 The Builder must complete the Work on or before the Finish Date. 14.3 If the Builder is entitled to an Extension of Time under  HYPERLINK \l "_22._Extension_of_2" Clause 22, the Finish Date will be adjusted by that Extension of Time. [Form begins] 14.4 In calculating the Finish Date, the Builder has made the following allowances: a) (insert number of) days for Inclement Weather and its effect b) (insert number of) days for weekend days, public holidays, rostered days off and other foreseeable breaks in the continuity of the Work c) (insert number of) days for other delays that are reasonable having regard to the nature of the contract. Clause 14.4 note: The Builder is required by section 32 of the Act to set out how many days they have allowed under each of these categories. Penalties apply for not complying with this legislative requirement. [Form ends] [Form begins] 14.5 If it is not possible for the Builder to adequately estimate the period of a particular likely delay in  HYPERLINK \l "Clause_14_4" Clause 14.4(c), the Builder will identify here the likely cause of the delay: [Form ends] 15. Loss or damage incurred by Building Owner Clause function: This clause states the loss or damage that will be incurred by the Building Owner if the Work is not completed by the Finish Date. [Form begins] 15.1 The Building Owner will set out below the nature of the loss and damage the Building Owner expects to incur (as much as this is known) if the Builder fails to complete the Work by the Finish Date: Clause 15.1 note: The Building Owner has the opportunity to set out in detail here the type of any likely loss or damage they will incur if the completion of the Work is delayed. Examples of likely loss and damage may include rental payments, storage costs and extra travel costs. This alerts the Builder to the type of loss and damage that may be incurred and what the Builder may be liable for if there is a delay. This is intended to help clarify each partys ɫƵ. The Building Owner should only indicate, where possible, the type of any loss or damage rather than specific amounts. This clause is not a liquidated damages clause, and does not stop the Building Owner from claiming loss or damage for expenses not listed here. [Form ends] 16. Purpose of Work Clause function: This clause requires the Building Owner to identify their expectations of the Work. [Form begins] 16.1 The Building Owner relies on the Builders skill and judgment in performing and completing the Work for the particular purpose for which the Work is required or the result that the Building Owner wishes to achieve. The particular purpose or result is stated below so as to show that reliance by the Building Owner: Clause 16.1 note: The Building Owner has the opportunity to identify what they are expecting to achieve from the Work, for example, to build a home with a specific environmental outcome or to build a home that meets the needs of a person with a disability. [Form ends] 17. Builders warranties Clause function: This clause identifies the implied warranties the Builder must provide. 17.1 The Builder warrants that: a) the Work will be carried out in a proper and workmanlike manner and in accordance with the plans and specifications set out in this contract [Form begins] b) all materials to be supplied by the Builder for use in the Work will be good and suitable for the purpose for which the materials are to be used and, unless otherwise stated here, those materials will be new. Insert below details of any materials to be used that are not new: [Form ends] c) the Work and, where undertaken by the Builder, the Approval Work will be carried out in accordance with, and comply with, all laws and legal requirements including, without limiting the generality of this warranty, the Building Act 1993 and Regulations made under that Act d) the Work will be carried out with reasonable care and skill and will be completed by the Finish Date e) the home will be suitable for occupation upon Completion of Work f) the Work and any material used in carrying out the Work will be reasonably fit for the purpose or result stated in  HYPERLINK \l "_16._Purpose_of_1" Clause 16, or will be of such a nature and quality as might reasonably be expected to achieve that result. 17.2 The Builder acknowledges that these warranties do not in any way reduce or limit the obligations of the Builder in relation to quality, materials or other matters specified in this contract. [Form begins] 17.3 The Builder acknowledges that it is the Building Owners right to be satisfied that the Work and, so far as they are applicable to it, the Approval Work complies with the warranties set out in  HYPERLINK \l "Clause_17_1" Clause 17.1. In the course of doing so, the Building Owner may exercise rights of access to the Building Site under  HYPERLINK \l "_21._Access_to_1" Clause 21. The Building Owner must initial below that they have read Clause 17.3:[Form ends] Clause 17.3 note The Building Owner should consider engaging a competent professional to monitor the progress of the Work. This could be an architect, building surveyor, building inspector, construction economist or building engineer or any combination of these persons. Engaging a competent professional is one way the Building Owner can get some assurance that the Work carried out complies with this contract. This may help the parties to proactively deal with disagreements over this contract or possible Defects. The Building Owner, a person engaged by the Building Owner or both, should inspect the Building Site at key stages because, once a stage is complete, Defects may not be readily visible or ascertainable. The law requires that the Builder gives the Building Owner or someone authorised by them access to the Building Site to view the progress of the Work. If the Building Owner relies on the building surveyor (whether private or municipal) who issued the building permit to inspect the Work, they should remember that the building surveyors statutory role is limited: the building surveyor is only responsible for checking that certain minimum standards under the Building Regulations 2006 have been met. To the extent that the standard of Work specified in the plans and specifications goes beyond the minimum standards under the Regulations, it is not the building surveyors statutory role to ensure these contractual standards have been met. [Form begins] 17.4 Where the Builder made available for inspection a home or a building suitable for use as a home to encourage the Building Owner to enter into a contract for the construction of a similar home, the Builder will perform the Work: a) using the same plans and specifications that were displayed in the home made available for inspection except for the following variation to the original plans: b) to at least the same standard or Work quality and quality of materials used in the construction of the home made available for inspection except for the following: [Form ends] 18. Permits, prescribed approvals and third-party requirements Clause function: This clause identifies the parties ɫƵ for permits, approvals and third-party requirements. 18.1 Unless otherwise stated in the Contract Details, the Builder must perform the Approval Work. 18.2 If the Builder is responsible for applying for a building permit under the contract, the Building Owner must, as soon as practicable: appoint a private building surveyor and give notice to the Builder of the appointment, or give instructions to the Builder for the Builder to apply to a municipal building surveyor for a building permit.  HYPERLINK \l "_Form_R_" Form R in Part D of the contract can be used to give notice of appointment of a private building surveyor or to give the Builder instructions to apply to a municipal building surveyor for a building permit. 18.3 The Builder must apply for an occupancy permit, if required by the building permit. 18.4 If the Builder performs the Approval Work, any fee or associated charge (or both) incurred as a result of that Approval Work by the Builder is included in the Contract Price unless excluded under  HYPERLINK \l "Clause_5_2" Clause 5.2. 18.5 Any Approval Work will be performed punctually and diligently so that the necessary permits and approvals can be obtained at the earliest practicable date. 18.6 If: the Builder is responsible for applying for a building permit and has not secured its issue within 60 calendar days from the date of being given notice or instructions by the Building Owner under  HYPERLINK \l "Clause_18_2" Clause 18.2, or the Building Owner is required to give notice or instructions to the Builder under  HYPERLINK \l "Clause_18_2" Clause 18.2 and has not given notice or instructions to the Builder within 60 calendar days from the date of this contract, or the Building Owner is responsible for applying for a building permit and has not secured its issue within 60 calendar days from the date of this contract the other party may terminate this contract by giving notice of termination. The terminating party must give that notice within 10 Business Days after the 60-day period expires. If this contract is terminated under this clause, the Building Owner is liable to pay the Builders reasonable costs incurred in association with the Approval Work but no more.  HYPERLINK \l "_FORM_P__1" Form P in Part D of the contract can be used to give notice of termination. 18.7 The Builder acknowledges the obligation set out in full in section 26 of the Act to give the Building Owner copies of documents in relation to the Work. A  HYPERLINK \l "_Section_26_" copy of section 26 is reproduced in the Legislation Extracts. 18.8 The Building Owner will inform the Builder promptly of any requirement, notice or order affecting the Work from a statutory authority or Lender and will provide the Builder with copies of any relevant documents. Clause 18 note A building permit must be issued before the Work can commence. Before issuing the building permit, the building surveyor who issues the building permit and is responsible for the required inspections of the Work at the required stages, must ensure: the building work and the building permit will comply with the Building Act 1993 and the Building Regulations 2006 any consent of a reporting authority required under the Building Act 1993 and the Building Regulations 2006 or under any other Act or regulations is obtained any relevant planning permit or other prescribed approval has been obtained the building permit will be consistent with that planning permit or other prescribed approval. The default in this contract is for the Builder to undertake the Approval Work. However, the contract also provides an option for the Building Owner to release the Builder from any obligation to undertake the Approval Work. If the Building Owner releases the Builder from this obligation the Building Owner is responsible for undertaking the Approval Work themselves. If the default is accepted and the Builder completes the Approval Work, the Building Owner is authorising the Builder to make any application, appeal, referral or representation under the Building Act 1993 and any other authorisation required to complete the Approval Work on behalf of the Building Owner. 19. Loan approvals Clause function: This clause sets out the parties obligations if the Building Owner takes out a loan for the purpose of the contract. 19.1 Unless the Contract Details state otherwise, this contract is conditional upon the Lender approving, on or before the Loan Approval Date, a loan to the Building Owner for the purposes of this contract of an amount that is not less than the amount stated for that purpose in the Contract Details. 19.2 The Building Owner must apply to the Lender for approval of such a loan within five Business Days from the date of this contract and also provide all relevant information required by the Lender for the purpose of considering the application. 19.3 Within three Business Days after the Loan Approval Date, the Building Owner must give to the Builder a notice stating whether the Lender has approved or refused to approve the loan.  HYPERLINK \l "_FORM_F_" Form F in Part D of the contract can be used for this purpose. 19.4 Unless the Building Owner notifies the Builder within three Business Days of the Loan Approval Date that the Lender has refused to approve the loan, this contract will cease being conditional upon loan approval. 19.5 If, on or before three Business Days after the Loan Approval Date, the Building Owner gives the Builder notice that the Lender has refused to approve the loan, this contract is at an end and, subject to the following sub-clauses, neither the Builder nor the Building Owner is bound to perform it. 19.6 If this contract comes to an end under this clause, the Builder must refund to the Building Owner any deposit or other money paid by the Building Owner to the Builder less the amount of any deduction permitted under  HYPERLINK \l "Clause_19_7" Clause 19.7. That refund must be paid within 10 Business Days of the Builder being notified that the Building Owners loan has not been approved. 19.7 The Builder may deduct the following costs from the refund referred to in  HYPERLINK \l "Clause_19_6" Clause 19.6, where the costs were incurred by the Builder up to the date the contract was deemed to come to an end and where the costs were previously agreed to be paid by the Building Owner: a) $100.00 b) fees paid by the Builder to another person for the Foundations Data c) fees paid by the Builder in relation to Approval Work. 19.8 At the time of making the refund under  HYPERLINK \l "Clause_19_6" Clause 19.6, the Builder must provide the Building Owner with copies of all documents evidencing the Builders entitlement to any deductions made under  HYPERLINK \l "Clause_19_7" Clause 19.7. 20. Occupation of the Building Site Clause function: This clause sets out the parties obligations in occupying the Building Site. 20.1 This contract does not give the Builder a greater right to occupy the Building Site than that of a contractual licensee. This right includes the right to place materials, equipment and, if the Building Owner agrees, signage on the Building Site. 20.2 Where the Building Owner must remain in residence or in occupation of part of the property during the Work the following will apply: a) the General Attachment will include a site plan of the property clearly showing the Building Site, the portion of the property to be occupied by the Building Owner and any common areas that both the Builder and the Building Owner may need to have access to b) the Builder will be responsible for providing and maintaining an adequate physical barrier separating the Building Site from the remainder of the property. 21. Access to the Building Site Clause function: This clause sets out the parties obligations in accessing the Building Site. 21.1 The Builder must do all Work necessary to provide access to the Building Site for vehicles and other equipment to carry out the Work. The Contract Price includes the cost of providing this access to the Building Site. 21.2 Except as provided under  HYPERLINK \l "Clause_12_15" Clause 12.15, the Builder must bear all costs involved in the delivery of materials to the Building Site; the handling of materials; and the removal and disposal from the Building Site of the Builders rubbish, surplus material, and demolished or dismantled structural material. 21.3 The Builder is liable for any damage caused in carrying out the Work if that damage was caused by the Builders own negligence or fault. This includes damage caused by the Work to kerbs, gutters, paving, underground services, drains, structures or other property whether on the Building Site or adjacent to, or abutting, the Building Site. 21.4 The Builder will permit the Building Owner or any person authorised by the Building Owner (either together or separately) to have reasonable access to the Building Site and to view any part of the Work. 21.5 The Building Owner, or persons authorised by the Building Owner, will not interfere with the carrying out of the Work when accessing the Building Site under  HYPERLINK \l "Clause_21_4" Clause 21.4. 21.6 The Builder is not liable for any reasonable costs or delays that result from any person failing to comply with  HYPERLINK \l "Clause_21_5" Clause 21.5 provided the Builder notifies the Building Owner of the cost or delay within five Business Days of the failure to comply occurring. Clause 21 note The Act nominates a penalty of 20 penalty units if the Builder does not permit the Building Owner to have reasonable access to the Building Site. Dangers could exist on the Building Site. The Building Owner should discuss appropriate occupational health and safety issues with the Builder before attending the Building Site. 22. Extension of Time Clause function: This clause sets out the process for a Builder to claim for an Extension of Time. 22.1 The Builder will be entitled to an Extension of Time if, for any one or more of the following reasons, the Builder is delayed in achieving Completion of Work by the Finish Date: a) Inclement Weather and its effect over and above the amount of days estimated by the Builder in  HYPERLINK \l "Clause_14_4" Clause14.4(a) b) an industrial dispute that is not limited to the Building Site or to employees of the Builder c) anything else that is beyond the reasonable control of the Builder and is not the result of the Builders fault d) Completion of Work has been reached, except for minor Defects that do not prevent the Work being used for its purpose and which it is not practical for the Builder to rectify for the time being, or as to which the Builder has reasonable grounds for delaying the rectification e) provided that the Builder gives notice to the Building Owner as required by  HYPERLINK \l "Clause_22_2" Clause 22.2, an act or omission by the Building Owner or any person who is in any way acting on the Building Owners behalf or under the Building Owners instruction f) a suspension of the Work by the Builder under  HYPERLINK \l "_35._Suspension_of_2" Clause 35. 22.2 As soon as practical after the Builder becomes aware that it is likely for any reason there will be delay in completing the Work by the Finish Date, the Builder will give the Building Owner a notice informing them of the likely delay, its cause and (as far as possible) its likely duration. The Builder will keep the Building Owner informed about the likely delay, providing adequate information so that the Building Owner can assist the Builder in avoiding or minimising its effect.  HYPERLINK \l "_FORM_G_" Form G in Part D of the contract can be used for the purpose of giving this notice. 22.3 Both the Builder and Building Owner must take all reasonable steps to avoid or minimise any delay to the progress of the Work, whether or not it is likely to cause delay in achieving Completion of Work. The Building Owner is not obliged to agree to changes or deletions from the plans or specifications to avoid such delay. 22.4 If an act or omission by the Building Owner is causing, or has caused, delay in the progress of the Work, the Builder must notify the Building Owner in writing of that cause within two Business Days of it commencing. This requirement also applies if the delay is caused by a person who is acting on the Building Owners behalf, or under the Building Owners instruction. 22.5 The extent of any Extension of Time must be fair and reasonable in the circumstances. Circumstances bearing on fairness and reasonableness of such claims include: a) the extent to which there is a failure (if any) in meeting an obligation under  HYPERLINK \l "Clause_22_2" Clause 22.2,  HYPERLINK \l "Clause_22_3" Clause 22.3, and  HYPERLINK \l "Clause_22_6" Clause 22.6 and the effect of any such failure b) the cause arising after the Finish Date c) the period of any allowance mentioned in  HYPERLINK \l "Clause_14_4" Clause 14.4. 22.6 If the Builder wants to claim an Extension of Time, the Builder must give the Building Owner a claim within 15Business Days after the delay ceases, stating: a) the reason for the delay b) the length of the claimed Extension of Time. 22.7 Within 10 Business Days of receiving the Builders claim under  HYPERLINK \l "Clause_22_6" Clause 22.6, the Building Owner must respond by stating in writing that the Building Owner either wholly accepts the Extension of Time or disputes wholly or partly the Extension of Time to the extent stated in the response. 22.8 If the Building Owner wholly or partly disputes the Builders claim for an Extension of Time, the Building Owner must give the Builder a written explanation that is sufficiently detailed for the Builder to know the basis of the dispute. 22.9 If within 10 Business Days of receiving the Builders claim for an Extension of Time the Building Owner does not deliver a written response, the Finish Date will be adjusted as set out in the claim. 22.10 Where the Building Owner accepts the Builders claimed Extension of Time, either wholly or partly, the Finish Date will be adjusted by the period of the Builders claimed Extension of Time that the Building Owner accepts. 22.11 Any dispute as to the Builders claim for an Extension of Time will be dealt with under the Dispute Resolution Procedure. 23. Variations Clause function: This clause identifies the process for varying the contract. 23.1 The Builder and the Building Owner acknowledge that the Work may be varied at the request of the Builder or Building Owner on the terms in  HYPERLINK \l "_Section_37__3" sections 37 and 38 of the Act and in this clause.  HYPERLINK \l "_FORM_H_" Form H in Part D of the contract can be used to request and approve Variations. 23.2 The Builder and the Building Owner acknowledge having read and initialled the copy of  HYPERLINK \l "_Section_37__3" sections 37 and 38 of the Act reproduced in the Legislation Extracts. Clause 23.2 note: It is important that the Builder and Building Owner are aware of the process that must be followed if they wish to make a Variation. This process is outlined in  HYPERLINK \l "_Section_37__3" sections 37 and 38 of the Act. 23.3 Before consenting to or requesting a Variation, the Building Owner may dispute that the Builder has stated the Builders reasonable cost, delay or effect. In that event, the dispute will be dealt with under the Dispute Resolution Procedure. Clause 23.3 note: HYPERLINK \l "_Section_37__3"Sections 37 and 38 of the Act may require the Builder to provide the Building Owner with a notice stating the reasonable cost, delay or effect of a proposed Variation. 23.4 Unless agreed in writing between the Builder and the Building Owner, any adjustments to the Contract Price as a result of an approved Variation will be taken into account at the time of the next progress payment. Clause 23.4 note: Payment of the Variation by the Building Owner or reduction of the Contract Price by the Builder resulting from a Variation should only occur at the next progress payment where it is demonstrated that the liability for the Variation occurred within the period of the progress payment. 23.5 The Building Owner can terminate the contract by notice to the Builder stating that the Building Owner is unable to meet the cost of the Variation because: a) the Variation is due to a matter that could not reasonably have been expected to be needed for the Work to be completed; or b) the Variation is due to a requirement of an approving authority or any other statutory authority, which was not known at the date of this contract. The Building Owner can use  HYPERLINK \l "_FORM_Q__1" Form Q in Part D of the contract to terminate the contract. 23.6 The Builder and Building Owner intend that any Variation in accordance with this clause will be made as though section 39 of the Act applied to it. A  HYPERLINK \l "_Section_39_" copy of section 39 is reproduced in the Legislation Extracts. 24. Provisional Sums Clause function: This clause sets out the process to be followed if the contract includes Provisional Sum items. 24.1 The Builder warrants that each Provisional Sum included by the Builder in the  HYPERLINK \l "_Provisional_Sums_Schedule_4" Provisional Sums Schedule has been calculated with reasonable care and skill, taking account of all the information reasonably available at the date of this contract, including the nature and location of the Building Site. 24.2 For each Provisional Sum in the Provisional Sums Schedule, the Builder has set out: a) a detailed description of the Work to which the Provisional Sum relates b) a breakdown of the cost estimate for each Provisional Sum, including showing the estimated quantities of materials involved and the unit cost to the Builder c) where the Builder proposes to charge more than the actual amount of any increase to the Provisional Sum, how that excess amount will be worked out. 24.3 The Builder must give the Building Owner reasonable notice of when Work included in the Provisional Sums Schedule will be done so that the Building Owner can verify the actual cost of the Work. The Builders notice to the Building Owner must state that the Provisional Sums may vary in price. If the Building Owner attends the Building Site to observe that Work, the Builder must allow the Building Owner reasonable access to do so. The Builder can proceed with that Work without delay at the time specified in the Builders notice even if the Building Owner does not attend the Building Site.  HYPERLINK \l "_FORM_I_" Form I in Part D of the contract can be used for the purpose of giving this notice. 24.4 If the actual cost to the Builder is greater than the Provisional Sum allowed, the excess amount, together with the Builders margin specified in the Contract Details, will be added to the Contract Price, along with the additional GST. If the actual cost to the Builder is less than the Provisional Sum allowed, the Contract Price will be reduced by the difference between the Provisional Sum allowed, and the actual cost. Clause 24.4 note: The Builder and the Building Owner should ensure a margin is specified in the Contract Details. 24.5 Any addition or deduction under  HYPERLINK \l "Clause_24_4" Clause 24.4 will be taken into account in the next progress payment or as agreed between the parties in writing. 25. Prime Cost Items Clause function: This clause sets out the process to be followed if the contract includes Prime Cost Items. 25.1 The Builder warrants that the amount or estimated amount for each Prime Cost Item listed in the  HYPERLINK \l "_Prime_Cost_Items_3" Prime Cost Items Schedule is no less than the reasonable cost of supplying the items. This warranty is based on information that the Builder had, or reasonably should have had, at the time of making this contract and given the Builders knowledge of the nature and location of the Building Site. This warranty does not apply to items to be supplied or specified by the Building Owner. 25.2 For each Prime Cost Item in the Prime Cost Items Schedule, the Builder has set out: a) a detailed description of the item to which the Prime Cost Item relates b) a breakdown of the cost estimate for each Prime Cost Item, including showing the estimated quantities of materials that will be involved and the unit cost to the Builder of the item c) where the Builder proposes to charge any amount over the actual amount of any increase to the Prime Cost Item, how that excess amount is to be determined. 25.3 The Builder must give the Building Owner reasonable notice of when Work included in the Prime Cost Items Schedule will be done so that the Building Owner can verify the actual cost of the Work. The Builders notice to the Building Owner must state that the Prime Cost Item may vary in price. If the Building Owner attends the Building Site to observe that Work the Builder must allow the Building Owner reasonable access to do so. The Builder can proceed with that Work without delay at the time specified in the Builders notice even if the Building Owner does not attend the Building Site.  HYPERLINK \l "_FORM_I_" Form I in Part D of the contract can be used for the purpose of giving this notice. 25.4 If the actual cost to the Builder is greater than the Prime Cost Item amount allowed, the excess amount, together with the Builders margin specified in the Prime Cost Item Schedule, will be added to the Contract Price, along with the additional GST. If the actual cost to the Builder is less than the Prime Cost Item amount allowed, the Contract Price will be reduced by the difference between the Prime Cost Item amount allowed, and the actual cost. Clause 25.4 note: The Builder and the Building Owner should ensure a margin is specified in the Contract Details. 25.5 Any addition or deduction under  HYPERLINK \l "Clause_25_4" Clause 25.4 will be taken into account in the next progress payment or as agreed between the parties in writing. 25.6 Unless otherwise specified, the Contract Price includes the installation of each Prime Cost Item listed in the Prime Cost Items Schedule, as well as its connection to services. 26. Evidence of cost of Prime Cost Items and Provisional Sums Clause function: This clause sets out the Builders requirements for providing evidence of the cost of a Prime Cost Item or a Provisional Sum. 26.1 The Builder must give the Building Owner a copy of any invoice, receipt or other document that shows the cost to the Builder of any Prime Cost Item, or that relates to any Provisional Sum. The Builder must do this as soon as practical after receiving the invoice, receipt or document. Clause 26 note The Builder is required by the Act to provide the Building Owner with copies of any invoice, receipt or document relating to Prime Cost Items or Provisional Sums. 27. Effect of payments and non-payments to the Builder Clause function: This clause identifies the impact of non-payment by the Building Owner. 27.1 The Builder and the Building Owner acknowledge that if the Building Owner fails to pay punctually any amount by the date it is due under this contract to the Builder, a Domestic Building Dispute exists between the parties. 27.2 Once a Domestic Building Dispute is resolved, the Building Owner must pay the Builder interest at the Penalty Interest Rate on any overdue amount determined or agreed to be due and owing. 27.3 The Building Owner may still dispute any matter relating to the Work or Approval Work even though the Building Owner has paid the Builder for the Work or Approval Work. 28. Final Completion and final payment Clause function: This clause states what the Builder must do before demanding final payment and when the Building Owner must make final payment. 28.1 The Builder must not demand final payment under this contract until the Builder has achieved Final Completion. 28.2 Final Completion is achieved when the Builder has: a) achieved Completion of Work b) given the Building Owner a copy of the occupancy permit under the Building Act 1993 if the building permit for the Work requires the issue of an occupancy permit or, in any other case, a copy of the certificate of final inspection c) handed over to the Building Owner all guarantees, instruction manuals and related documents relating to the Work; all keys relating to the Work; and any permits, certificates or notices relating to the Work. 28.3 Unless  HYPERLINK \l "_29._Building_Owners_1" Clause 29 or  HYPERLINK \l "_30._Lender_payment_1" Clause 30 applies, the Building Owner must make the final payment within five Business Days after receiving from the Builder a demand that conforms with this clause. 29. Building Owners recovery for delay, loss, expense or damage Clause function: This clause states what the Building Owner must do to recover loss or damages incurred as a result of a delay in completing the Work. 29.1 If there is a delay in completing the Work beyond the Finish Date, the Building Owner is entitled to recover from the Builder reasonable loss, expense or damage caused to the Building Owner by the delay. Clause 29.1 note: The Building Owner will have indicated in  HYPERLINK \l "Clause_15_1" Clause 15.1 the nature (so far as known) of any loss or damage they expect to incur if the Work is not completed by the Finish Date. The Building Owner can claim all expenses realised as a result of a loss or damage, incurred under this clause. However, these expenses are not limited only to the types of loss or damage foreshadowed in  HYPERLINK \l "Clause_15_1" Clause 15.1. Clause 15.1 is only indicative of the types of loss or damage that may be known at the time of entering into the contract.  HYPERLINK \l "_FORM_K_" Form K in Part D of the contract can be used to make this claim. 29.2 The Building Owner will, within 15 Business Days of the Finish Date, give to the Builder notice that: a) the Building Owner intends to seek recovery of reasonable loss, expense or damage caused by the delay b) details of the that loss, expense or damage, together with copies of relevant documents that support the Building Owners claim. 29.3 During the period of delay, the Building Owner will keep the Builder informed about material changes in the nature and extent of the loss, expense or damage the Building Owner is suffering or is likely to suffer. 29.4 To resolve the Building Owners claim under  HYPERLINK \l "Clause_29_2" Clause 29.2, the following procedure applies: a) within 10 Business Days of receiving the Building Owners claim, the Builder must deliver a written response, stating whether the Builder accepts the claim wholly or disputes the claim wholly or in part b) if the Builder wholly or partly disputes the Building Owners claim, the Builder must explain in writing why, so that the Building Owner has enough information to know the basis of the dispute c) any dispute about the Building Owners claim will be dealt with under the Dispute Resolution Procedure. 29.5 The amount of the Building Owners claim agreed between the parties or agreed under the Dispute Resolution Procedure will be a debt from the Builder to the Building Owner. This will be deducted from the final payment otherwise due from the Building Owner to the Builder. If the final payment is insufficient to satisfy the Building Owners claim, the Builder will pay the balance to the Building Owner within five Business Days of the Building Owners claim being agreed. 30. Lender payment Clause function: This clause identifies the details for payment by the Lender. 30.1 If the payments on behalf of the Building Owner are to be made by the Lender, the Builder will accept the usual payment terms (including the need for inspections and certificates) required by the Lender. 31. Completion of Work Clause function: This clause sets out when Completion of Work is achieved. 31.1 The Work will be complete when: a) it has been fully performed in accordance with this contract, including the plans and specifications forming part of this contract b) the Builder has made good any damage of the kind referred to in  HYPERLINK \l "Clause_21_3" Clause 21.3 c) the Builder has removed all the Builders rubbish, surplus material and demolished or dismantled structural material from the Building Site. 31.2 When the Builder is of the opinion that Completion of Work has been achieved, the Builder must give a notice to the Building Owner stating that opinion. Thereafter, the parties will follow the Opinion Procedure. 32. Completion notifications Opinion Procedure Clause function: This clause states the process the parties will follow when giving an opinion about Completion of Work. 32.1 The Building Owner must give a notice to the Builder within 10 Business Days of receiving the Builders opinion that Completion of Work has been achieved, that the Building Owner: a) accepts the opinion, or b) does not accept the opinion, giving detailed reasons. 32.2 Unless the Building Owner accepts the Builders opinion in the form and time required above: a) the Building Owner and the Builder must meet to resolve the differences between them as to Completion of Work and undertake genuine and good faith negotiations based on their contractual rights and obligations within 20 Business Days of the Building Owners receipt of the Builders opinion b) the Builder will record the details of any agreement with the Building Owner about what is necessary to achieve Completion of Work, including timing of actions to be taken by either of them c) If the parties cannot agree or fail to meet, the dispute will be dealt with under the Dispute Resolution Procedure 32.3 If the parties agree under  HYPERLINK \l "Clause_32_2" Clause 32.2: a) the Builder must give a further notice to the Building Owner when it is of the opinion that Completion of Work has been achieved, stating that opinion and giving details of actions since the first notice. The Building Owner must give a notice to the Builder that the Building Owner accepts the resubmitted opinion or, if not, give detailed reasons within five days of receipt b) the parties may, if they agree, repeat the steps in  HYPERLINK \l "Clause_32_2" Clause 32.2 and  HYPERLINK \l "Clause_32_3_a" Clause 32.3(a) c) subject to any right under this contract to suspend or terminate it, if the parties cannot agree that Completion of Work has been achieved or do not agree to repeat the Opinion Procedure, the dispute will be dealt with under the Dispute Resolution Procedure.  HYPERLINK \l "_FORM_L_" Form L in Part D of the contract can be used by the Builder and Building Owner in relation to completion notifications. Clause 32 note This clause provides for the Builder to notify the Building Owner that Completion of Work has been reached. The Builder should be satisfied that all Work is completed before providing the Completion of Work notice. The Building Owner should be satisfied that the Work is complete and is performed in accordance with the contract before accepting the Builders opinion that Completion of Work has been achieved. The Building Owner may consider engaging a competent professional to assist them to establish Completion of Work has been achieved. 33. Rectification period and maintenance Clause function: This clause provides for a period after Final Completion during which the Builder may be obliged to rectify. 33.1 The Builder must rectify any Defect that is apparent in the Work as at three calendar months after the date of final payment if the Building Owner gives a notice under Clause 33.2 [below]. 33.2 If the Building Owner requires the Builder to rectify a Defect, the Building Owner must give the Builder a notice (called here a Defect Rectification Request) within 10 Business Days of the expiry of the three calendar month period. 33.3 If the Building Owner gives the Builder a Defect Rectification Request, the Builder must give a written response to the Building Owner stating what the Builder agrees to rectify and does not agree to rectify in the Request at the Builders cost, within 10 Business Days. 33.4 Unless the Builder has reasonable grounds for being unable to do so, the Builder must rectify the item or items within 20 Business Days from receiving the Defect Rectification Request. 33.5 If a dispute arises between the parties as to whether there is a Defect or as to the extent of the Defect or whether the Defect has been rectified so as to accord with the contract, the dispute will be dealt with under the Dispute Resolution Procedure. 33.6 The Building Owner must give the Builder reasonable access to the Building Site for the purpose of rectifying a Defect.  HYPERLINK \l "_FORM_M_" Form M in Part D of the contract can be used to give notice of Defects. Clause 33 note The Building Owner still has a right to make claims for Defects beyond the rectification period. 34. Dispute Resolution Procedure Clause function: This clause sets out the process to be followed when a matter under this contract is in dispute. 34.1 If a dispute arises, the Builder and the Building Owner will take the following steps before resorting to the procedures set out in Part 3A (Conciliation of Disputes) and Part 4 (Inspectors) of the Act: a) If the Building Owner or Builder considers that a dispute has arisen about any matter covered by this contract, that party must promptly give the other notice of the dispute. The notice should identify both the matter and the claim being made. Matters can be those that arose during the progress of the Work, arose after Completion of Work or arose after the contract was terminated.  HYPERLINK \l "_FORM_N_" Form N in Part D of the contract can be used to give this notice. b) The Builder and the Building Owner will then arrange a meeting and will negotiate in an honest and genuine attempt to resolve the dispute. The Builders Representative or the Building Owners Representative can represent their principal for that purpose only if they have been authorised in writing. 34.2 If the dispute is not resolved within 10 Business Days, the parties may lodge a complaint with Building Advice and Conciliation ɫƵ or ask for an inspector to be appointed under the Act. 34.3 Where a dispute exists, each of the parties must continue to perform its obligations under this contract unless the other party evinces an intention not to comply with this clause. Clause 34 note See the  HYPERLINK "http://www.consumer.vic.gov.au" Consumer Affairs ɫƵ website or call 1300 55 75 59 for details of the Building Advice and Conciliation ɫƵ process. 35. Suspension of Work by the Builder Clause function: This clause states the process to be followed when the Builder intends to suspend the Work. 35.1 After giving five Business Days notice (called here Suspension notice) of its intention to do so, the Builder may suspend the Work if the Building Owner fails to do any of the following things in accordance with the terms of this contract: a) provide satisfactory evidence of title to the Building Site after being required to do so under  HYPERLINK \l "Clause_12_4" Clause 12.4 b) pay any amount due and payable to the Builder c) provide satisfactory evidence of its capacity to pay the Contract Price, including any Variations, after being required to do so under  HYPERLINK \l "Clause_12_10" Clause 12.10 d) provide the Builder or the Builders sub-contractors access to the Building Site. 35.2 The Suspension notice must specify clearly the failure or failures that caused the Builder to give it. 35.3 If the Building Owner remedies the failure or failures specified in the Suspension notice after the Builder has suspended the Work, unless the Builder has already terminated this contract, the Builder will recommence the Work within 10 Business Days after the remedy of the failure or failures. 35.4 If the Builder suspends the Work under this clause, the Builder will be entitled to recover from the Building Owner any cost, loss expense or damage caused by the suspension. 35.5 The right to suspend under this contract is in addition to any other powers, rights or remedies the Builder may have under common law and does not restrict them in any way. 36. Consequences of insolvency Clause function: This clause deals with what can be done if the Builder or the Building Owner has serious financial trouble. 36.1 If a party to this contract does any of the following things: a) commits an act of bankruptcy b) is made bankrupt c) assigns assets for the benefit of creditors generally d) makes a composition or other arrangement with creditors e) goes into liquidation or receivership or otherwise loses full capacity f) the other party may, at its option, immediately suspend or terminate this contract by giving a notice stating that it is doing so.  HYPERLINK \l "_FORM_P_" Form P (Builder) or  HYPERLINK \l "_FORM_Q_" Form Q (Building Owner) in Part D of the contract can be used for the purpose of terminating the contract. 36.2 The notice under this clause must specify clearly the act or acts that caused it to be given. 36.3 The right to suspend or terminate under this contract is in addition to any other powers, rights or remedies the suspending or terminating party may have under common law and does not restrict them in any way. 37. Termination after notice of default Clause function: This clause sets out the process the parties will follow to terminate the contract if a party is in breach of this contract.  HYPERLINK \l "_FORM_P_" Form P (Builder) or  HYPERLINK \l "_FORM_Q_" Form Q (Building Owner) in Part D of the contract can be used for the purpose of terminating the contract. 37.1 If the Building Owner or the Builder is in substantial breach of this contract, the other party may give a notice clearly identifying the breach and stating that partys intention to terminate this contract if the breach is not remedied within five Business Days. If the breach is not remedied within that time, the party giving the notice may terminate this contract. 37.2 To terminate this contract a further notice must be given to the party in breach clearly identifying the breach and stating the contract is terminated, effective at the time stated in the notice. 37.3 The right to terminate under this clause is in addition to any other powers, rights or remedies the terminating party may have under common law and does not restrict them in any way. 37.4 Substantial breach by the Building Owner includes, without reasonable cause, the Building Owner: a) failing to provide satisfactory evidence of title to the Building Site after being required to do so under  HYPERLINK \l "Clause_12_4" Clause 12.4 b) failing to pay any amount due and payable to the Builder c) failing to provide satisfactory evidence of the Building Owners capacity to pay the Contract Price, including any Variations after being required to do so under  HYPERLINK \l "Clause_12_10" Clause 12.10 d) continually failing to provide the Builder or the Builders sub-contractors access to the Building Site e) substantially or persistently obstructing the Builder in the performance of the Work f) failing to perform or progress the Approval Work in accordance with this contract. 37.5 Substantial breach by the Builder includes, without reasonable cause, the Builder: a) failing to perform or progress the Work or the Approval Work in accordance with this contract b) failing to provide materials that comply with this contract c) unreasonably failing to replace or remedy defective Work or materials d) failing to take out or maintain any insurance required by this contract. 38. Termination other than after notice of default Clause function: This clause states the grounds upon which a contract can be terminated. 38.1 The Building Owner and the Builder acknowledge that  HYPERLINK \l "_Section_41__1" section 41 of the Act sets out when and how the Building Owner may end this contract if, on the day this contract was entered into, the Builder could not reasonably have foreseen that either: a) the Contract Price would rise by 15% or more after this contract was entered into; or b) the contract would not be completed within one and a half (1.5) times the period by which it was to have been completed. A copy of  HYPERLINK \l "_Section_41__2" section 41 of the Act is reproduced in the Legislation Extracts. 38.2 In addition to the circumstances set out in section 41(1) of the Act, the Building Owner may end this contract if there is the increased time or cost stated in  HYPERLINK \l "Clause_38_1" Clause 38.1 as a result of a Variation requirement within  HYPERLINK \l "Section_37_2" section 37(2) (b) of the Act.  HYPERLINK \l "_FORM_P_" Form P (Builder) or  HYPERLINK \l "_FORM_Q_" Form Q (Building Owner) in Part D of the contract can be used for the purpose of terminating the contract. 39. Builders entitlement at termination Clause function: This clause states the grounds upon which the Builder can be paid for the Work performed up to the time the contract is terminated. 39.1 If the contract is terminated the Builder is entitled to: a) payment in accordance with this contract for any completed stages b) the reasonably incurred cost of the Work done since the last stage was completed, exclusive of any Work done for rectification of Defects and the cost of any unfixed materials or goods on the Building Site, together with the Builders margin specified in the Contract Details and GST payable. 39.2 The Builders entitlement under  HYPERLINK \l "Clause_39_1" Clause 39.1 is limited to an amount that does not cause the total amount to be paid to the Builder under this contract, exclusive of any claim under  HYPERLINK \l "Clause_40_1" Clause 40.1(b), to exceed the Contract Price. 40. Consequences of termination by the Builder Clause function: This clause sets out the Builders rights if the Builder terminates the contract. 40.1 If the Builder terminates this contract, the Builder may: a) remove from the Building Site and retain all unfixed materials, goods, plant and equipment provided by the Builder. In the event that any unfixed materials, goods, plant or equipment provided by the Builder are not collected, the Building Owner must dispose of such materials, goods, plant or equipment according to law b) recover from the Building Owner the amount of all cost, loss and damage incurred by the Builder as a result of the termination and the act or default that gave rise to it. The Builder may set off any such amount against any money owing by the Builder to the Building Owner under this contract.  HYPERLINK \l "_FORM_P_" Form P (Builder) or  HYPERLINK \l "_FORM_Q_" Form Q (Building Owner) in Part D of the contract can be used for the purpose of terminating the contract. 40.2 The Builder will, within 20 Business Days of notifying the Building Owner that the contract is terminated, submit to the Building Owner: a) any claim that the Builder asserts for Work performed by it prior to the termination of this contract and for which the Builder has not been paid. The Builders entitlement to claim for Work performed by it prior to the termination of this contract and for which the Builder has not been paid is identified in  HYPERLINK \l "_39._Builders_entitlement_1" Clause 39 b) any claim that the Builder asserts the Builder is entitled to under  HYPERLINK \l "Clause_40_1" Clause 40.1(b). Notification to building surveyor of termination of contract The Building Act 1993 requires the Building Owner and the Builder to each notify the building surveyor for the Work within 14 days after the engagement of the Builder ends by termination of the contract. Failure to perform this notification can incur a maximum penalty of 10 penalty units. The Building Owner should discuss with the building surveyor the capacity to continue the Work once the contract is terminated with the Builder and the process required for notification of appointment of a subsequent Builder. If the Building Owner does not intend to complete the Work, either by appointing another builder or completing the Work themselves, the Building Owner should discuss with the building surveyor how this affects compliance with the requirements of the Building Act 1993 and any subsequent prescribed approval. 41. Consequences of termination by the Building Owner Clause function: This clause sets out the Building Owners rights if the Building Owner terminates the contract. 41.1 If the Building Owner terminates this contract, the Building Owner is entitled to recover from the Builder the amount of all cost, loss and damage incurred by the Building Owner as a result of the termination and the act or default that gave rise to it. The Building Owner may set off any such amount against any money owing by the Builder to the Building Owner under this contract.  HYPERLINK \l "_FORM_P_" Form P (Builder) or  HYPERLINK \l "_FORM_Q_" Form Q (Building Owner) in Part D of the contract can be used for the purpose of terminating the contract. 41.2 If the Building Owner terminates this contract, the Building Owner may, by itself, or by others, complete the Work and take and use all unfixed materials, goods, plant and equipment that the Building Owner has previously provided at the Building Site. 41.3 If the Building Owner terminates this contract, the Builder may: a) remove from the Building Site and retain all unfixed materials, goods, plant and equipment provided by the Builder. In the event that any unfixed materials, goods, plant or equipment provided by the Builder are not collected, the Building Owner must dispose of such materials, goods, plant or equipment according to law b) recover from the Building Owner the amount of all cost, loss and damage incurred by Builder as a result of the termination and the act or default that gave rise to it. The Builder may set off any such amount against any money owing by the Builder to the Building Owner under this contract. Note re  HYPERLINK \l "Clause_40_1" Clause 40.1(a) and  HYPERLINK \l "Clause_41_3" Clause 41.3 (a) Uncollected or abandoned goods: Situations can arise where the Builder does not collect the unfixed materials, goods, plant and equipment provided by the Builder and the unfixed materials, goods, plant and equipment could be considered to be abandoned. There are specific laws relating to the disposal of uncollected goods. These laws require the Building Owner to take care of the unfixed materials, goods, plant and equipment provided by the Builder until they are collected by the Builder, delivered to the Builder, or disposed of according to law. The law outlines procedures for the disposal of uncollected goods. A building owner who fails to follow these procedures may be liable for the loss of the uncollected goods. It is best if the Building Owner seeks professional advice at their own cost, before disposing of or taking possession of the uncollected goods. 41.4 The Builder must submit to the Building Owner any claim for Work performed by it prior to the termination of this contract for which the Builder has not been paid within 20 Business Days of being notified by the Building Owner that the contract is terminated. The Builders entitlement to claim for Work performed by it prior to the termination of this contract and for which the Builder has not been paid is identified in  HYPERLINK \l "Clause_39_1" Clause 39.1 and  HYPERLINK \l "Clause_39_2" Clause39.2. 41.5 The Building Owner will give notice to the Builder stating whether the Building Owner intends to complete the Work within 20 Business Days of receiving the Builders claim under  HYPERLINK \l "Clause_41_4" Clause 41.4. 41.6 If the Building Owner gives notice that the Building Owner does not intend to complete the Work, the Building Owner must calculate the total amount of cost, loss, expense or damage that the Building Owner has reasonably incurred as a result of the termination and the act or default that gave rise to it. 41.7 The Building Owner must give the Builder a notice stating that total amount within 20 Business Days. The notice must include a statement showing clearly how the total amount is made up and include copies of any relevant documents. 41.8 If the Building Owner gives notice stating that the Building Owner intends to complete the Work: a) the Builder is not entitled to any further payment under this contract until the Building Owner completes the Work b) upon completing the Work, the Building Owner must calculate the total amount of the cost of completing the Work, together with any other cost, loss, expense or damage that the Building Owner has reasonably incurred owing to the termination and the act or default that gave rise to it c) if the total amount stated in the notice exceeds the Contract Price, the Builder must pay the difference to the Building Owner within 20 Business Days after receiving the notice d) if the total amount stated in the notice is less than the Contract Price, the Building Owner must pay the difference to the Builder within 20 Business Days of giving the notice to the Builder e) the Building Owner must give the Builder a notice stating the total amount. The notice must include a statement showing clearly how the total amount is made up and include copies of any relevant documents. 42. Insurance Clause function: This clause sets out requirements for insurance other than Domestic Building Insurance. 42.1 Before commencing the Work and until Completion of Work has been reached and agreed to by the Building Owner or affirmed in any Dispute Resolution Procedure, the Builder must take out and maintain the following insurances for the benefit of the Building Owner and the Builder: a) public liability insurance for at least $5 million to cover death or personal injury to third parties or damage to property b) property damage insurance appropriate for the Work, including work in progress, any associated temporary work and materials on the site. This insurance must cover full reinstatement and replacement costs, including the costs of removing debris, demolition, architects fees and other consultants fees: this must be at least 100% of the estimated reinstatement and replacement costs. This insurance must include cross-liability provisions by which the insurer waives all rights of subrogation or action that the insurer may have against any of the persons comprising the insured and by which each person comprising the insured is deemed to be the subject of a separate policy of insurance. This insurance must cover loss by accident, theft, fire, explosions, vandalism, civil unrest and acts of God. Clause 42.1 note: The Builder is required by  HYPERLINK \l "Clause_42_1" Clause 42.1 to take out public liability insurance and property damage insurance appropriate for the Work. If the Builder fails to take out this insurance, this clause enables the Building Owner to take out these insurances and deduct the cost from the Contract Price. Alternatively, the Building Owner may choose to terminate the contract under  HYPERLINK \l "Clause_37_5" Clause 37.5. 42.2 On settlement of any claim for damage to the Work, the Builder must diligently proceed to rebuild, replace or repair the Work. In doing so, the Builder is not entitled to any payment other than that received from the insurer. 42.3 Whenever asked by the Building Owner, the Builder must show evidence that the Builder has obtained the insurances mentioned in  HYPERLINK \l "Clause_42_1" Clause 42.1, within 10 Business Days. Such evidence must include properly completed certificates showing the insurance is current and copies of the relevant policies. If the Builder fails to provide the evidence, or if the Builder does not take out any of the required insurances, the Building Owner may arrange the insurance and deduct the cost from payments then or subsequently due to the Builder. 42.4 The Builder indemnifies the Building Owner against any liability or loss, which may result from carrying out the Work. This indemnity covers loss for death or personal injury or property damage including damage to, or loss of, goods or materials on site including the Work. However, if such liability or loss arises in whole or in part through the fault of the Building Owner or Building Owners agents, the extent of the Builders indemnity may be reduced according to law to the extent that such fault contributed to the liability or loss. 43. Copyright Clause function: This clause identifies the legal use of plans and specifications. 43.1 Any party supplying plans and specifications or either for the purpose of the Work warrants that they may be used without breach of any legal or equitable right and indemnifies the other party against any claim in respect of their use. 43.2 Where plans are drawn by the Builder, the Building Owner agrees that the Builder has copyright in those plans. The Building Owner has the right to have the Works completed in accordance with those plans if the Builders employment is terminated under this contract for any reason. Document List Attachment All plans and specifications for Work to be done under this contract must be listed below, as they form part of this contract. [Form begins] Plans Designer Drawing No. or JobNo.Sheet No.Revision No.E.g. Smith and Jones Architects0923451CSpecifications Designer Drawing No. or JobNo.Sheet No.Revision No.E.g. Natspec0923451-52A[Form ends] Other relevant contract documents: General Attachment [Form begins] Relates to  HYPERLINK \l "Clause_12_15" Clause 12.15 and  HYPERLINK \l "Clause_20_2" Clause 20.2 of the contract The Building Owner will supply to the Builder each of the following items: Attached is a site plan showing the areas to be occupied by the Builder, the Builder Owner and common areas.[Form ends] Provisional Sums Schedule (Relates to  HYPERLINK \l "_24._Provisional_Sums_3" Clause 24) Provisional Sums are estimates of the cost of carrying out particular Work (including the cost of supplying any materials needed for the Work) under the contract for which the Builder, after making all reasonable enquiries, cannot give a definite amount at the time the contract is entered into. The Builder must calculate each sum included in this schedule with reasonable care and skill, taking account of all the information reasonably available at the date of this contract, including the nature and location of the Building Site. If the actual cost to the Builder is greater than the estimate in this table, the excess amount, together with the Builders margin on the excess, will be added to the Contract Price. This margin is to cover overheads, supervision and profit. The Builders margin is set out in the Contract Details in  HYPERLINK \l "_4._Contract_Details_13" Clause 4. [Form begins] Detailed description of the Work to which the Provisional Sum relatesUnit costQuantityTotal estimated cost of Sum[Form ends] Prime Cost Items Schedule (Relates to  HYPERLINK \l "_25._Prime_Cost_3" Clause 25) Prime Cost Items are items (for example, fixtures or fittings) that either have not been selected, or for which the price is not known, at the time the contract is entered into and for the cost of supply and delivery of which the Builder must make a reasonable allowance in the contract. The Builder must calculate each item included in this schedule with reasonable care and skill, taking account of all the information reasonably available at the date of this contract, including the nature and location of the Building Site. If the actual cost to the Builder is greater than the estimate in this table, the excess amount, together with the Builders margin on the excess will be added to the Contract Price. This margin is to cover overheads, supervision and profit. The Builders margin is set out in the Contract Details in  HYPERLINK \l "_4._Contract_Details_13" Clause 4. [Form begins] Detailed description of the Prime Cost (e.g.fixtures and fittings)Unit costQuantityTotal estimated cost of Sum[Form ends] Part C: Legislation Extracts Clause 1: Definitions Definitions extracted from sections 3, 30 and 54 of the Act builder means a person who, or a partnership which (a) carries out domestic building work; or (b) manages or arranges the carrying out of domestic building work; or (c) intends to carry out, or to manage or arrange the carrying out of, domestic building work. building owner means the person for whom domestic building work is being, or is about to be, carried out. contract price means the total amount payable under a domestic building contract and includes (a) the amount the builder is to receive and retain under the contract; and (b) the amount the builder is to receive under the contract for payment to any other person; and (c) the amount any third person is to receive (or it is reasonably estimated will receive) directly from the building owner in relation to the domestic building work to be carried out under the contract (i) for conveying to the building site or connecting or installing services such as gas, electricity, telephone, water and sewerage; or (ii) for the issue of planning or building permits but does not include any amount that the builder excludes in accordance with section 24. domestic building dispute is a dispute or claim arising (a) between a building owner and (i) a builder; or (ii) a building practitioner (as defined in the Building Act 1993); or (iii) a sub-contractor; or (iv) an architect in relation to a domestic building contract or the carrying out of domestic building work; or (b) between a builder and (i) another builder; or (ii) a building practitioner (as defined in the Building Act 1993); or (iii) a sub-contractor; or (iv) an insurer in relation to a domestic building contract or the carrying out of domestic building work; or (c) between a building owner or a builder and (i) an architect; or (ii) a building practitioner registered under the Building Act 1993 as an engineer or draftsperson in relation to any design work carried out by the architect or building practitioner in respect of domestic building work. (2) For the purposes of subsection (1), a dispute or claim includes any dispute or claim in negligence, nuisance or trespass but does not include a dispute or claim related to a personal injury. (3) A reference to a building owner in this section includes a reference to any person who is the owner for the time being of the building or land in respect of which a domestic building contract was made or domestic building work was carried out. foundations data means (a) the information concerning the building site that a builder exercising reasonable care and skill would need to prepare (i) a proper footings design for the site; and (ii) an adequate estimate of the cost of constructing those footings; and (b) any reports, surveys, test results, plans, specifications, computations or other information required by the regulations for the purposes of section 30 of the Act. prime cost item means an item (for example, a fixture or fitting) that either has not been selected, or whose price is not known, at the time a domestic building contract is entered into and for the cost of supply and delivery of which the builder must make a reasonable allowance in the contract. provisional sum is an estimate of the cost of carrying out particular work (including the cost of supplying any materials needed for the work) under a domestic building contract for which a builder, after making all reasonable inquiries, cannot give a definite amount at the time the contract is entered into. Clause 7: Progress payments Section 40 Limits on progress payments [Form begins] Initial here that you have read Clause40(1)Building Owner:Builder[Form ends] (1) In this section base stage means (a) in the case of a home with a timber floor, the stage when the concrete footings for the floor are poured and the base brickwork is built to floor level; (b) in the case of a home with a timber floor with no base brickwork, the stage when the stumps, piers or columns are completed; (c) in the case of a home with a suspended concrete slab floor, the stage when the concrete footings are poured; (d) in the case of a home with a concrete floor, the stage when the floor is completed; (e) in the case of a home for which the exterior walls and roof are constructed before the floor is constructed, the stage when the concrete footings are poured. frame stage means the stage when a homes frame is completed and approved by a building surveyor. lock-up stage means the stage when a homes external wall cladding and roof covering is fixed, the flooring is laid and external doors and external windows are fixed (even if those doors or windows are only temporary). fixing stage means the stage when all internal cladding, architraves, skirting, doors, built-in shelves, baths, basins, troughs, sinks, cabinets and cupboards of a home are fitted and fixed in position. [Form begins] Initial here that you have read Clause40(2)Building Owner:Builder[Form ends] (2) A builder must not demand or recover or retain under a major domestic building contract of a type listed in column 1 of the Table more than the percentage of the contract price listed in column 2 at the completion of a stage referred to in column 3. Penalty: 50 penalty units. (3) In the case of a major domestic building contract that is not listed in the Table, a builder must not demand or receive any amount or instalment that is not directly related to the progress of the building work being carried out under the contract. Penalty: 50 penalty units. (4) Subsections (2) and (3) do not apply if the parties to a contract agree that it is not to apply and do so in the manner set out in the regulations. (5) If a court finds proven a charge under subsection (2) or (3) against a builder, it may order the builder to refund to the building owner some or all of the amount the building owner has paid the builder under the contract. (6) This power is in addition to the power the court has to impose any other penalty. (7) Despite section 7, this section does not apply to a contract between a builder and the Crown or a public statutory authority. Table: Limits on progress payments Type of contractPercentage of contract priceStageContract to build to lock-up stage20%Base stage25%Frame stageContract to build to fixing stage12%Base stage18%Frame stage40%Lock-up stageContract to build all stages10%Base stage15%Frame stage35%Lock-up stage25%Fixing stageClause 12: General conditions of contract Section 30 Builder must obtain information concerning foundations (1) This section applies if proposed domestic building work under a major domestic building contract will require the construction or alteration of the footings of a building, or may adversely affect the footings of a building. (2) Before entering into the contract, the builder must obtain foundations data in relation to the building site on which the work is to be carried out. Penalty: 50 penalty units. (3) In this section foundations data means (a) the information concerning the building site that a builder exercising reasonable care and skill would need to prepare (i) a proper footings design for the site; and (ii) an adequate estimate of the cost of constructing those footings; and (b) any reports, surveys, test results, plans, specifications, computations or other information required by the regulations for the purposes of this section. (4) In deciding whether he, she or it has obtained all the information required by subsection (2), a builder must have regard to (a) the relevant standards published by Standards Australia; and (b) the need for a drainage plan or engineers drawings and computations; and (c) the need for information on the fall of the land on the site. (5) It is not necessary for a builder to commission the preparation of foundations data under this section to the extent that such data already exists and it is reasonable for the builder to rely on that data. (6) A builder must give a copy of any foundations data obtained by the builder to the building owner (unless the building owner supplied the data to the builder) on payment by the building owner of the amount owing in relation to the obtaining of that data by the builder. Penalty: 10 penalty units. (7) After entering into a major domestic building contract, a builder cannot seek from the building owner an amount of money not already provided for in the contract if the additional amount could reasonably have been ascertained had the builder obtained all the foundations data required by this section. (8) Nothing in this section prevents a builder from exercising any right given by this Act to the builder to claim an amount of money not already provided for in the contract if the need for the additional amount could not reasonably have been ascertained from the foundations data required by this section. Clause 18: Permits, prescribed approvals and third-party requirements Section 26 Builder must supply copies of relevant reports etc. (1) A builder must give to a building owner a copy of any report, notice, order or other document that the builder is given in relation to the building work being carried out by the builder for the building owner by any public statutory authority, provider of services such as gas, electricity, telephone, water and sewerage or person registered under the Building Act 1993, and must do so as soon as practicable after receiving the report, notice, order or document. Penalty: 20 penalty units. Clause 23: Variations Section 37 Variation of plans or specifications by builder [Form begins] Initial here that you have read section 37Building Owner:Builder[Form ends] (1) A builder who wishes to vary the plans or specifications set out in a major domestic building contract must give the building owner a notice that (a) describes the variation the builder wishes to make; and (b) states why the builder wishes to make the variation; and (c) states what effect the variation will have on the work as a whole being carried out under the contract and whether a variation to any permit will be required; and (d) if the variation will result in any delays, states the builders reasonable estimate as to how long those delays will be; and (e) states the cost of the variation and the effect it will have on the contract price. (2) A builder must not give effect to any variation unless (a) the building owner gives the builder a signed consent to the variation attached to a copy of the notice required by subsection (1); or (b) the following circumstances apply (i) a building surveyor or other authorised person under the Building Act 1993 requires in a building notice or building order under that Act that the variation be made; and (ii) the requirement arose as a result of circumstances beyond the builders control; and (iii) the builder included a copy of the building notice or building order in the notice required by subsection (1); and (iv) the building owner does not advise the builder in writing within five business days of receiving the notice required by subsection (1) that the building owner wishes to dispute the building notice or building order. (3) A builder is not entitled to recover any money in respect of a variation unless (a) the builder (i) has complied with this section; and (ii) can establish that the variation is made necessary by circumstances that could not have been reasonably foreseen by the builder at the time the contract was entered into; or (b) the Tribunal is satisfied (i) that there are exceptional circumstances or that the builder would suffer a significant or exceptional hardship by the operation of paragraph (a); and (ii) that it would not be unfair to the building owner for the builder to recover the money. (4) If subsection (3) applies, the builder is entitled to recover the cost of carrying out the variation plus a reasonable profit. (5) This section does not apply to contractual terms dealing with prime cost items or provisional sums. Section 38 Variation of plans or specifications by building owner [Form begins] Initial here that you have read section 38Building Owner:Builder[Form ends] (1) A building owner who wishes to vary the plans or specifications set out in a major domestic building contract must give the builder a notice outlining the variation the building owner wishes to make. (2) If the builder reasonably believes the variation will not require a variation to any permit and will not cause any delay and will not add more than 2% to the original contract price stated in the contract, the builder may carry out the variation. (3) In any other case, the builder must give the building owner either (a) a notice that (i) states what effect the variation will have on the work as a whole being carried out under the contract and whether a variation to any permit will be required; and (ii) if the variation will result in any delays, states the builders reasonable estimate as to how long those delays will be; and (iii) states the cost of the variation and the effect it will have on the contract price; or (b) a notice that states that the builder refuses, or is unable, to carry out the variation and that states the reason for the refusal or inability. (4) The builder must comply with subsection (3) within a reasonable time of receiving a notice under subsection(1). (5) A builder must not give effect to any variation asked for by a building owner unless (a) the building owner gives the builder a signed request for the variation attached to a copy of the notice required by subsection (3)(a); or (b) subsection (2) applies. (6) A builder is not entitled to recover any money in respect of a variation asked for by a building owner unless (a) the builder has complied with this section; or (b) the Tribunal is satisfied (i) that there are exceptional circumstances or that the builder would suffer a significant or exceptional hardship by the operation of paragraph (a); and (ii) that it would not be unfair to the building owner for the builder to recover the money. (7) If subsection (6) applies, the builder is entitled to recover the cost of carrying out the variation plus a reasonable profit. (8) This section does not apply to contractual terms dealing with prime cost items or provisional sums. Section 39 Effect of a variation on the contract price Unless the contrary intention appears, if the plans or specifications set out in a major domestic building contract are varied in accordance with section 37 or 38, any reference in this Act, the regulations or the contract to (a) those plans or specifications is to be read as a reference to them as varied; and (b) the contract price is to be read as a reference to the contract price as adjusted to take account of the variation; and (c) the completion date, or the number of days required to finish the work, is to be read as a reference to that date, or number of days, as adjusted to take account of the variation. Clause 38: Termination other than after notice of default Section 41 Ending a contract if completion time or cost blows out for unforeseeable reasons (1) A building owner may end a major domestic building contract if (a) either (i) the contract price rises by 15% or more after the contract was entered into; or (ii) the contract has not been completed within 1 times the period it was to have been completed by; and (b) the reason for the increased time or cost was something that could not have been reasonably foreseen by the builder on the date the contract was made. (2) For the purposes of subsection (1), any increased time or cost that arises as a result of a prime cost item or a provisional sum or that is caused by a variation made under section 38 is to be ignored in calculating any price rise or increase in time. (3) To end the contract, the building owner must give the builder a signed notice stating that the building owner is ending the contract under this section and giving details of why the contract is being ended. (4) The Director may specify that the notice is to be given in a form approved by him or her. If the Director does this, the building owner must give the notice in that form. (5) If a contract is ended under this section, the builder is entitled to a reasonable price for the work carried out under the contract to the date the contract is ended. (6) However, a builder may not recover under subsection (5) more than the builder would have been entitled to recover under the contract. Part D: Forms Form A Notice of commencement of Work For use by: Builder Related to:  HYPERLINK \l "Clause_6_2" Clause 6.2 When to use this form The deposit under this contract is to be paid in two parts. The first 80% of the deposit is due at the later of: a) the signing of the contract; or b) five Business Days after the Building Owner receives a copy of: i) a copy of the Domestic Building Insurance policy ii) the certificate of insurance iii) a summary of the insurance product. The final 20% of the deposit is due within five Business Days of the Building Owner receiving a notice from the Builder stating that they have substantially commenced the Work and stating the date of commencement. This form can be used for this purpose. This request should be given to the Building Owner either in person or using one of the preferred methods nominated in  HYPERLINK \l "_4._Contract_Details_14" Clause 4 of the contract entitled Contract Details. [Form begins] To [insert name of Building Owner]:Postal address:Postcode:Contact person:Telephone:From [insert name of Builder]:Postal address:Postcode:Contact person:Telephone:Regarding construction at [insertaddress of Building Site]:Notice to the Building Owner I wish to advise that the Work has substantially commenced. The Work commenced on [insertdate]:Please pay the remaining 20% of the deposit within five Business Days of receiving this notice. The remaining 20% of the deposit is equal to:$ Date: Signed by (there are two options mark the option which applies with an X): Builder:Builders Representative: Signature:Important note to the Building Owner The Domestic Building Contracts Act 1995 states that the Builder must not demand or receive a deposit that is more than: a) 5% of the Contract Price, if the Contract Price is $20,000 or more b) 10% of the Contract Price, if the Contract Price is less than $20,000. If the Builder demands a deposit greater than the relevant amount above, the Building Owner may void the Contract at any time before it is completed. [Form ends] Form B Request for evidence of title and site dimensions For use by: Builder Related to:  HYPERLINK \l "Clause_12_4" Clause 12.4 When to use this form Under the contract, the Builder must ensure that the Building Site is on land owned by the Building Owner and be certain of the location of the sites boundaries. The Builder can use this form to request evidence from the Building Owner of their title to the Building Site and the dimensions of the Building Site. This request should be given to the Building Owner either in person or using one of the preferred methods nominated in  HYPERLINK \l "_4._Contract_Details_15" Clause 4 of the contract entitled Contract Details. [Form begins] To [insert name of Building Owner]:Postal address:Postcode:Contact person:Telephone:From [insert name of Builder]:Postal address:Postcode:Contact person:Telephone:Regarding construction at [insertaddress of Building Site]:Request to the Building Owner Please provide satisfactory evidence of: a) your title to the Building Site b) the dimensions of the Building Site. Date: Signed by (there are two options mark the option which applies with an X):Builder:Builders Representative: Signature:[Form ends] Form C Notification of requirement for a boundary survey For use by: Builder Related to:  HYPERLINK \l "_4._Contract_Details_16" Clause 12.5 When to use this form If the boundaries of the Building Site can only be determined by a licensed land surveyor, the Builder must provide a boundary survey. Before obtaining the survey, the Builder must notify the Building Owner that they intend to obtain a survey, and the estimated cost of that survey. The Builder can use this form to provide this information to the Building Owner. This notice should be given to the Building Owner either in person or using one of the preferred methods nominated in  HYPERLINK \l "_4._Contract_Details_17" Clause 4 of the contract entitled Contract Details. [Form begins] To [insert name of Building Owner]:Postal address:Postcode:Contact person:Telephone:From [insert name of Builder]:Postal address:Postcode:Contact person:Telephone:Regarding construction at [insertaddress of Building Site]:Notice to the Building Owner I intend to obtain a boundary survey from a licensed land surveyor. In accordance with the contract, you (the Building Owner) will be responsible for paying the reasonable cost of this survey, which I estimate to be [Builder to insert reasonable estimate of cost of survey]:$ Date: Signed by (there are two options mark the option which applies with an X):Builder:Builders Representative: Signature:Important note to the Building Owner In accordance with the contract, as the Building Owner you will be responsible for paying the reasonable cost of the survey. [Form ends] Form D Request for evidence of capacity to meet contract terms For use by: Builder or Building Owner Related to: Clause 20.10 When to use this form At any time during the term of the contract, either party may request evidence from the other party that they have the capacity to meet the terms of the contract (e.g. that the Builder is able to complete the Work, or the Building Owner is able to pay). Either party may use this form to request evidence from the other party that they are able to meet the terms of the contract. This request should be delivered either in person or using one of the preferred methods nominated in  HYPERLINK \l "_4._Contract_Details_17" Clause 4 of the contract entitled Contract Details. Important note Where the other party provides evidence in response to this request, the party who issued this request will be responsible for paying the reasonable costs incurred in obtaining and providing this evidence. These costs should be added to, or deducted from, the Contract Price. [Form begins] To [insert name]:Postal address:Postcode:Contact person:Telephone:From [insert name]:Postal address:Postcode:Contact person:Telephone:Regarding construction at [insertaddress of Building Site]:Request Please provide reasonable evidence of your capacity to meet the terms of this contract. Date: Signed by (there are four options mark the option which applies with an X):Builder:Builders Representative:Building Owner(s):Building Owners Representative: Signature:Important note to the recipient of this request You must respond to this request within 10 Business Days of receiving it. Failure to respond within this timeframe may result in suspension of Work or termination of the contract. Any reasonable costs incurred in obtaining or providing this evidence should be added to, or deducted from, the Contract Price. [Form ends] Form E Notification of new representative For use by: Builder or Building Owner Related to:  HYPERLINK \l "Clause_12_12" Clause 12.12 and  HYPERLINK \l "Clause_12_13" Clause 12.13 When to use this form The parties to this contract may nominate a representative who is authorised to communicate with the other party. At the time the contract was entered into, the names of representatives were specified in the Contract Details in  HYPERLINK \l "_4._Contract_Details_17" Clause4. If a party wishes to appoint a new representative during the term of the contract, they must notify the other party of the new representative. This form can be used for this purpose. This notice should be either given in person or using one of the preferred methods nominated in  HYPERLINK \l "_4._Contract_Details_17" Clause4 of the contract entitled Contract Details. [Form begins] To [insert name]:Postal address:Postcode:Contact person:Telephone:From [insert name]:Postal address:Postcode:Contact person:Telephone:Regarding construction at [insertaddress of Building Site]:Notice I have appointed a new representative. The new representatives details are: Contact details Name:Address:Postal address:Postcode:Business phone:After hours:Mobile:Fax:Email:The preferred method of delivery of a demand, notice or other document to the new representative is: Date: Signed by (there are four options mark the option which applies with an X):Builder:Builders Representative:Building Owner(s):Building Owners Representative: Signature:[Form ends] Form F Notification of whether loan has been approved For use by: Building Owner Related to:  HYPERLINK \l "_19._Loan_approvals_4" Clause 19 When to use this form In most cases, the contract will be conditional on the Building Owner obtaining loan approval on or before the Loan Approval Date specified in  HYPERLINK \l "_4._Contract_Details_17" Clause4 of the contract. Within three Business Days after the Loan Approval Date, the Building Owner must notify the Builder whether or not the loan has been approved. This form can be used for this purpose. This notice should be given to the Builder either in person or using one of the preferred methods nominated in  HYPERLINK \l "_4._Contract_Details_17" Clause4 of the contract entitled Contract Details. [Form begins] To [insert name of Builder]:Postal address:Postcode:Contact person:Telephone:From [insert name of Building Owner]:Postal address:Postcode:Contact person:Telephone:Regarding construction at [insertaddress of Building Site]:Notice to the Builder I notify you that (there are two options either provide information for the first option or mark the second option with an X):I have obtained loan approval from [insert name of Lender]:I have not obtained loan approval.Important note to the Building Owner If you fail to notify the Builder within three Business Days after the Loan Approval Date, you will continue to be bound by the contract, regardless of whether your loan has been approved. Date: Signed by (there are two options mark the option which applies with an X):Building Owner:Building Owners Representative: Signature:Important note If, on or before three Business Days after the Loan Approval Date, the Building Owner gives the Builder notice that the Lender has refused to approve the loan, the contract is at an end.  HYPERLINK \l "Clause_19_6" Clause 19.6,  HYPERLINK \l "Clause_19_7" Clause 19.7 and  HYPERLINK \l "Clause_19_8" Clause 19.8 specify the liability of each of the parties in these circumstances. [Form ends] Form G Notification of likely delay/claim for Extension of Time For use by: Builder Response by: Building Owner Related to:  HYPERLINK \l "_22._Extension_of_3" Clause 22 When to use this form If the Builder becomes aware of a likely delay in completing the Work by the Finish Date, they are required (as soon as practical) to give the Building Owner notice of the likely delay, its cause and, as far as possible, its duration. This form can be used for this purpose. If there has been a delay, the Builder can claim an Extension of Time by stating the reason for the delay and its duration. The Builder must make this claim within 15 Business Days of the delay ceasing. This form can be used for this purpose. If the Builder makes a claim for an Extension of Time, the Building Owner may accept or reject (wholly or in part) the claim. This form can be used for this purpose. This notice should be delivered either in person or using one of the preferred methods nominated in  HYPERLINK \l "_4._Contract_Details_17" Clause4 of the contract entitled Contract Details. [Form begins] Section A Claim by Builder Regarding construction at [insertaddress of Building Site] Builders (there are two options mark the option which applies with an X):notification of likely delayclaim for Extension of Time for Completion of Work. The reason for the delay/likely delay is (there are six options mark the option/s which apply with an X, and provide details where applicable):Inclement Weatherindustrial disputerectification of minor Defectssuspension of Work (advised previously) (see  HYPERLINK \l "_35._Suspension_of_3" Clause 35 of the contract)other reason beyond the Builders control [specify]:an act or omission of the Building Owner [if so, specify]:(Note: If an act or omission of the Building Owner is the cause of the delay, the Builder must notify the Building Owner within two Business Days of the delay commencing.) The length of the likely delay or claimed Extension of Time is (enter number of days): Date: Signed by (there are two options mark the option which applies with an X):Builder:Builders Representative: Signature:Important note to the Builder The Extension of Time must be fair and reasonable in the circumstances. [Form continues next page] Form G continued Section B Building Owners response (needed only if the Builder is claiming an Extension of Time). Response (there are three options mark the option which applies with an X and provide the reasons for your response where applicable):I accept all of the Builders claim for an Extension of TimeI partially accept the Builders claim for an Extension of Time. The Extension of Time accepted is (specify number of days and provide the reason for rejecting part of the claim):I reject all of the Builders claim for an Extension of Time. The reason for rejecting the claim is: Date: Signed by (there are two options mark the option which applies with an X):Building Owner(s):Building Owners Representative: Signature:Important note to the Building Owner Accepting a claim for an Extension of Time will result in the Finish Date being adjusted accordingly. If you do not respond to the Builders claim within 10 Business Days, you will be deemed to have accepted the claimed extension in full. [Form ends] Form H Variation to plans and specifications For use by: Builder or Building Owner Related to:  HYPERLINK \l "_23._Variations_7" Clause 23 When to use this form During the term of the contract, either party may wish to vary the plans or specifications. Section A should be completed by the party wishing to initiate a Variation. If the Builder initiates a Variation, they must provide a reason. Section B should be completed by the Builder, stating the effect the Variation will have on the Work as a whole, whether a Variation to any permit will be required, the cost of the Variation and effect on the Contract Price, and whether it will result in any delays. Section C provides for the Building Owners approval or rejection of the proposed Variation. This form should not be used for Variations regarding Prime Cost Items or Provisional Sums. This notice should be delivered either in person or using one of the preferred methods nominated in  HYPERLINK \l "_4._Contract_Details_17" Clause4 of the contract entitled Contract Details. [Form begins] Section A Initiation of Variation Regarding construction at [insertaddress of Building Site] Party initiating Variation (there are two options mark the option which applies with an X and provide details where applicable):Building Owner:Builder [insert reason for variation]: Description of Variation to plans and specifications [attach additional page(s) if insufficient space]: Date: Signed by (there are four options mark the option which applies with an X):Builder:Builders Representative:Building Owner(s):Building Owners Representative: Signature:Important note The Builder and Building Owner should read  HYPERLINK \l "_Section_37__4" sections 37 and 38 of the Act carefully before completing this form. These sections of the Act are reproduced in the Legislation Extracts in Part C of the contract. [Form continues next page] Form H continued Section B Effect of Variation (to be completed by the Builder at the same time as section A or within a reasonable time of receiving section A from the Building Owner). Complete either Part I or Part II below: Part I The Builder refuses, or is unable, to carry out the Variation. The reason for refusal or inability is: Part II The effect the Variation will have on the Work as a whole is (include whether any variation to permits will be required): The Variation will result in a delay of [insert reasonable estimate of the number of days]:The cost of the Variation will be:$ The effect on the Contract Price will be (there are three options mark the option which applies with an X and enter a value where applicable):no change in pricea decrease in the Contract Price of:$an increase in the Contract Price of:$ Date: Signed by (there are two options mark the option which applies with an X):Builder:Builders Representative: Signature:Important note In some circumstances, the Builder can proceed with the Variation without first obtaining the Building Owners consent. These circumstances are outlined in  HYPERLINK \l "_Section_37__5" sections 37 and 38 of the Act, which are reproduced in the Legislation Extracts in Part C of the contract. [Form continues next page] Form H continued Section C Building Owners consent to Variation Tick as appropriate below:I agree to the Variation described in section A aboveI do not agree to the Variation described in section A above. Date: Signed by (there are two options mark the option which applies with an X):Building Owner(s):Building Owners Representative: Signature:Important note to the Building Owner If you do not provide a response to the Builder within five Business Days, the Builder may still proceed with the Variation if the Variation is required in a building notice or building order and the requirement arose as a result of circumstances beyond the Builders control. [Form ends] Form I Notification of Provisional Sum or Prime Cost Item Work For use by: Builder Related to:  HYPERLINK \l "Clause_24_3" Clause 24.3 and  HYPERLINK \l "Clause_25_3" Clause 25.3 When to use this form If the contract includes items in the Provisional Sum Schedule or the Prime Cost Item Schedule, the Builder must give the Building Owner adequate notice of when this Work is to be undertaken. As the cost of these items may vary from the amounts included in the schedules, the Building Owner may wish to be present at the time the Work is undertaken to verify the actual cost of the Work. This notice should be given to the Building Owner either in person or using one of the preferred methods nominated in  HYPERLINK \l "_4._Contract_Details_17" Clause4 of the contract entitled Contract Details. [Form begins] To [insert name of Building Owner]:Postal address:Postcode:Contact person:Telephone:From [insert name of Builder]:Postal address:Postcode:Contact person:Telephone:Regarding construction at [insertaddress of Building Site]:Notice to the Building Owner I notify you that [insert detailed description of the item from the Schedule]:will be undertaken on [insert date and time]:This Work is included in the contract as (there are two options mark the option which applies with an X): Provisional Sum WorkPrime Cost Item Work Date: Signed by (there are two options mark the option which applies with an X):Builder:Builders Representative: Signature:Important note If the Building Owner is unable to attend at the time the Work is to be done, or does not attend, the Builder can proceed with the Work without delay, even though the Building Owner is absent. [Form ends] Form J Progress payments For use by: Builder Response by: Building Owner Related to:  HYPERLINK \l "_7._Progress_payments_3" Clause 7 When to use this form At certain defined stages, the Builder may demand and recover or retain amounts by way of progress payments for the Work done. These payments must not be a greater percentage of the Contract Price than allowed under the Act. This form can be used by the Builder to claim a progress payment. This notice should be delivered either in person or using one of the preferred methods nominated in  HYPERLINK \l "_4._Contract_Details_17" Clause4 of the contract entitled Contract Details. [Form begins] To [insert name of Building Owner]:Postal address:Postcode:Contact person:Telephone:Regarding construction at [insertaddress of Building Site]:Notice of completion of stage The Builder advises that the Work is at the stage indicated below (there are five options mark the option which applies with an X): Contract to build all stagesBase stage 10%Frame stage 15%Lock-up stage 35%Fixing stage 25%Final stage 10%Claim for progress payment The Builder claims a progress paymentof:$which is equal to [percentage of the Contract Price] (insert relevant percentage from above):The amount due is (insert amount; if this is the first progress payment, the amount of the deposit paid should be deducted from the progress payment amount):$ This progress payment claim takes into account the following adjustments to the Contract Price, which have been made since the contract was signed/the last progress payment claim was made: (Complete points 1-3 below only if applicable)1. An overall adjustment to the Contract Price as a result of an agreed Variation to plans and specifications:2. Variation in the actual price of the following Provisional Sum items:3. Variation in the actual price of the following Prime Cost Items:(increase/decrease)$See  HYPERLINK \l "_24._Provisional_Sums_4" Clause 24 and the Provisional Sum Schedule(increase/decrease)$(increase/decrease)$(increase/decrease)$See  HYPERLINK \l "_25._Prime_Cost_4" Clause 25 and the Prime Cost Item Schedule(increase/decrease)$(increase/decrease)$(increase/decrease)$Important note to the Builder Copies of invoices, receipts or other documentation relating to Prime Cost Items or Provisional Sums must be given to the Building Owner as soon as practicable after receiving the invoice, receipt or document. The progress payment claimed must not exceed the relevant percentage of the Contract Price set out above. Date: Signed by (there are two options mark the option which applies with an X):Builder:Builders Representative: Signature:Important note to the Building Owner Before making a progress payment, it is important you ensure that the relevant stage has been completed as claimed. [Form ends] Form K Loss, expense or damage caused to the Building Owner For use by: Building Owner Response by: Builder Related to:  HYPERLINK \l "_29._Building_Owners_2" Clause 29 When to use this form If there is a delay in completing the Work beyond the Finish Date, the Building Owner is entitled to recover from the Builder loss, expense or damage caused to the Building Owner by the delay. This form can be used to make this claim. The Building Owner must provide the Builder with a detailed claim for loss, expense or damage within 15 Business Days after the Finish Date. This notice should be delivered either in person or using one of the preferred methods nominated in  HYPERLINK \l "_4._Contract_Details_17" Clause4 of the contract entitled Contract Details. [Form begins] Section A Building Owners claim for loss, expense or damage Regarding construction at [insertaddress of Building Site]:Building Owners claim for loss, expense or damage caused by a delay The Building Owner claims the following amount of for loss, expense or damage caused by a delay in completing the Work (insert amount). $Details of this claim are [attach additional page(s) if insufficient space]: Date: Signed by (there are two options mark the option which applies with an X):Building Owner(s):Building Owners Representative: Signature:Important note to the Building Owner Attach copies of all relevant documents that support your claim. [Form continues next page] Form K continued Section B Builders response Builders response to the Building Owners claim (there are three options mark the option which applies with an X or provide details where applicable):The claim in section A is accepted.The claim in section A is accepted in part. Specify the part accepted (in dollars) and the reason for rejecting part of the claim:$The claim in section A is rejected. The reason for rejecting the claim is: Date: Signed by (there are two options mark the option which applies with an X):Builder:Builders Representative: Signature:Important note to the Builder The Builder should respond to the claim within 10 Business Days of receiving this notice. Important note to the Building Owner and the Builder Any dispute about the Building Owners claim will be dealt with under the Dispute Resolution Procedure. If the Building Owner has made a claim for loss, expense or damage, the Building Owner is not obliged to make a final payment to the Builder until five Business Days after the claim is accepted or a dispute as to the claim is resolved. Any claim owed to the Building Owner will be deducted from the final payment due to the Builder. If the final payment is insufficient to satisfy the claim, the Builder will pay the balance to the Building Owner within five Business Days of the claim being accepted or resolved. [Form ends] Form L Completion of Work and Opinion Procedure For use by: Builder Response by: Building Owner Related to:  HYPERLINK \l "_32._Completion_notifications_2" Clause 32 When to use this form When the Builder is of the opinion that that Completion of Work has been achieved they must notify the Building Owner. This form can be used for this purpose. This form also may be used for the Opinion Procedure. This notice should be delivered either in person or using one of the preferred methods nominated in  HYPERLINK \l "_4._Contract_Details_17" Clause4 of the contract entitled Contract Details. [Form begins] Section A Completion of Work notice Notice to the Building Owner To [insert name of Building Owner]:Postal address:Postcode:Contact person:Telephone:Regarding construction at [insertaddress of Building Site]:From [insert name of Builder]:Postal address:Postcode:Contact person:Telephone:I am of the opinion that Completion of Work has been achieved. Date: Signed by (there are two options mark the option which applies with an X):Builder:Builders Representative: Signature:Important note to the Building Owner You must respond within 10 Business Days of receiving this notice.  HYPERLINK \l "Clause_32_1" Clause 32.1 of the contract states that after the Builder has given the Building Owner the Builders opinion that they have completed the Work, the parties will from that point follow the Opinion Procedure. The remaining sections of this form relate to the Opinion Procedure. [Form continues next page] Form L continued Section B Building Owners response to opinion about Completion of Work To [insert name of Builder]:Postal address:Postcode:Contact person:Telephone:From [insert name of Building Owner]:Postal address:Postcode:Contact person:Telephone:Regarding construction at [insertaddress of Building Site]: My response to the opinion you have given to me is that (there are two options mark the option which applies with an X or provide details where applicable):I accept the opinion that Completion ofWork has been achieved and the remaining sections of this form are notneeded.I do not accept the opinion [insert reasons]: I request that you meet with me at the Building Site to reach agreement about Completion of Work [insert time and date]: Date: Signed by the Building Owner:[Form continues next page] Form L continued Section C Builders record of Completion of Work meeting To [insert name of Building Owner]:Postal address:Postcode:Contact person:Telephone:Regarding construction at [insertaddress of Building Site]:From [insert name of Builder]:Postal address:Postcode:Contact person:Telephone: Set out below is a record of the meeting held between us at the Building Site on [insert time and date]: Date: Signed by the Builder:[Form continues next page] Form L continued Section D Resubmitted Completion of Work notice To [insert name of Building Owner]:Postal address:Postcode:Contact person:Telephone:Regarding construction at [insertaddress of Building Site]:From [insert name of Builder]:Postal address:Postcode:Contact person:Telephone: I am of the opinion that Completion of Work has been achieved. This notice is resubmitted. Since the previous notice, the following actions have occurred: Date: Signed by (there are two options mark the option which applies with an X):Builder:Builders Representative: Signature:Important note to the Building Owner You must respond within 10 Business Days of receiving this notice. [Form continues next page] Form L continued Section E Building Owners response to resubmitted opinion about Completion of Work To [insert name of Builder]:Postal address:Postcode:Contact person:Telephone:From [insert name of Building Owner]:Postal address:Postcode:Contact person:Telephone:Regarding construction at [insertaddress of Building Site]: My response to the resubmitted opinion you have given to me is that (there are two options mark the option which applies with an X or provide details where applicable):I accept the opinion that Completion ofWork has been achieved and the remaining sections of this form are notneeded.I do not accept the opinion [insert reasons]: Select one of the two options below by marking with an X or provide details where applicableI request that you meet with me at the Building Site again to reach agreement about Completion of Work and I agree to repeat the Opinion Procedure [insert time and date]:Completion of Work will now be dealt with under the Dispute Resolution Procedure. Date: Signed by the Building Owner:[Form ends] Form M Rectification requirement For use by: Building Owner Response by: Builder Related to:  HYPERLINK \l "_33._Rectification_period_1" Clause 33 When to use this form If, within three calendar months after the date of final payment a Defect in the Work appears that is not a result of misuse or ordinary wear and tear, the Building Owner can request the Builder to perform this rectification. This form can be used for this purpose. This form may be also used by the Builder to respond to the rectification request. After any section of this form has been completed, it should be delivered either in person or using one of the preferred methods nominated in  HYPERLINK \l "_4._Contract_Details_17" Clause4 of the contract entitled Contract Details. [Form begins] Section A Building Owners rectification request Regarding construction at [insertaddress of Building Site]:Building Owners Defect Rectification Request I request that you rectify the following Defects, which have become apparent in the Work within three calendar months of Final Completion [attach additional page(s) if insufficient space]: Date: Signed by (there are two options mark the option which applies with an X):Building Owner(s):Building Owners Representative: Signature:Important note to the Building Owner If you require the Builder to rectify the Defect, you must notify them of the Defect within 10 Business Days of the expiry of the three calendar month period following Final Completion. [Form continues next page] Form M continued Section B Builders response Builders response to the Defect Rectification Request I agree to rectify the following Work [attach additional page(s) if insufficient space]:I do not agree to rectify the following Work [attach additional page(s) if insufficient space]: Date: Signed by (there are two options mark the option which applies with an X):Builder:Builders Representative: Signature:Important note to the Builder You must respond to the above Defect Rectification Request within 10 Business Days of receiving this request. Unless you have reasonable grounds for doing so, you must rectify the item or items in the above Defect Rectification Request at your cost within 20 Business Days of receiving this request. Important note to the Builder and the Building Owner If a dispute arises between the parties as to whether there is a Defect or as to its extent or whether it has been rectified so as to accord with the contract, the dispute will be dealt with under the Dispute Resolution Procedure. [Form ends] Form N Notice of dispute For use by: Building Owner or Builder Related to:  HYPERLINK \l "_34._Dispute_Resolution_2" Clause 34 When to use this form If either party considers that a dispute has arisen about any matter covered by this contract, that party must promptly give the other notice of the items of dispute. The notice must identify both the matter and the claim being made. This form can be used for this purpose. Matters in dispute can be those that arose during the progress of the Work, arose after Completion of Work or arose after the contract was terminated. [Form begins] Notification of dispute Regarding construction at [insertaddress of Building Site]:Notice of dispute To [insert name and address]: I consider that a dispute has arisen regarding our contract. The items I consider to be in dispute are as follows [insert details of matter and claim being made. Attach additional page(s) if insufficient space]: Date: Signed by (there are four options mark the option which applies with an X):Builder:Builders Representative:Building Owner(s):Building Owners Representative: Signature:Important note The Builders Representative and the Building Owners Representative may only represent their principal in a dispute if they have been authorised in writing. Following receipt of this notice, a meeting is to be arranged between the parties to negotiate in an honest and genuine attempt to resolve the dispute by discussion. If the dispute is not resolved within 10 Business Days, the parties may lodge a complaint with Building Advice and Conciliation ɫƵ or ask for an inspector to be appointed under the Act. Where a dispute exists, each of the parties must continue to perform its obligations under this contract unless the other party evinces an intention not to comply with  HYPERLINK \l "_34._Dispute_Resolution_3" Clause 34 of the contract. This notice should be delivered either in person or using one of the preferred methods nominated in  HYPERLINK \l "_4._Contract_Details_17" Clause4 of the contract entitled Contract Details. [Form ends] Form O Suspension of Work For use by: Builder Related to:  HYPERLINK \l "_35._Suspension_of_4" Clause 35 and  HYPERLINK \l "_36._Consequences_of_1" Clause 36 When to use this form In circumstances where the Building Owner has failed to do certain things required by this contract, the Builder may suspend the Work. Before suspending Work, the Builder must give the Building Owner five Business Days notice of their intention to suspend the Work. The notice must specify clearly the failure or failures that caused the Builder to give it. This form can be used for this purpose. This notice should be given to the Building Owner either in person or using one of the preferred methods nominated in  HYPERLINK \l "_4._Contract_Details_17" Clause4 of the contract entitled Contract Details. [Form begins] Notice of intention to suspend Work Regarding construction at [insertaddress of Building Site]:Notice of suspension of Work I intend to suspend Work because you (the Building Owner) have failed to do the following in accordance with the terms of this contract (there are five options mark the option which applies with an X):provide satisfactory evidence of the title to the Building Site after being required to do so under  HYPERLINK \l "Clause_12_4" Clause 12.4pay any amount due and payable to the Builderprovide satisfactory evidence of its capacity to pay the Contract Price, including any Variations after being required to do so under  HYPERLINK \l "Clause_12_10" Clause 12.10provide the Builder or the Builders sub-contractors access to the BuildingSitean event of insolvency has occurred (see  HYPERLINK \l "Clause_36_1" Clause 36.1 of the contract). Details of the Building Owners default [insert sufficient details of the Building Owners action/inaction to enable them to remedy the reason for the intended suspension of Work]: Details of the Building Owners insolvency: Date: Signed by (there are two options mark the option which applies with an X):Builder:Builders Representative: Signature:Important note If the Building Owner remedies the default within five Business Days, the Builder must recommence the Work within 10 Business Days unless the Builder has terminated the contract. [Form ends] Form P Termination of contract by Builder For use by: Builder Related to:  HYPERLINK \l "Clause_18_6" Clause 18.6 and  HYPERLINK \l "_38._Termination_other_1" Clause 38 When to use this form The contract includes a number of clauses that provide for the termination of the contract. This form can be used by the Builder to terminate the contract. This notice should be delivered either in person or using one of the preferred methods nominated in  HYPERLINK \l "_4._Contract_Details_17" Clause4 of the contract entitled Contract Details. [Form begins] To [insert name of Building Owner]:Postal address:Postcode:Contact person:Telephone:Regarding construction at [insertaddress of Building Site]:From [insert name of Builder]:Postal address:Postcode:Contact person:Telephone:Notice of intention to terminate the contract I give notice that the contract is terminated for the following reason(s) (there are six options mark the option/s which apply with an X and provide details where applicable)failure by the Building Owner to respond to the Builders request to provide evidence of title or capacity to pay the Contract Price (see  HYPERLINK \l "Clause_12_4" Clause 12.4 and  HYPERLINK \l "Clause_12_10" Clause 12.10)failure by the Building Owner to pay a progress payment or any other amount due and payable to the Builder (see  HYPERLINK \l "_7._Progress_payments_4" Clause 7)the Building Owners substantial or persistent obstruction of the Builder in the performance of the Work (see  HYPERLINK \l "Clause_21_5" Clause 21.5)other substantial breach of the contract by the Building Owner [specify]:the Building Owner (although responsible for doing so) has not secured a building permit within 60 calendar days from the date of the contract (see  HYPERLINK \l "Clause_18_6" Clause 18.6)the Building Owner (although responsible for doing so) has not given the Builder notice of the appointment of a private building surveyor or given the Builder instructions to apply to a municipal building surveyor for a building permit within 60 calendar days from the date of the contract (see  HYPERLINK \l "Clause_18_6" Clause 18.6)the Building Owner has committed an act of bankruptcy, has been made bankrupt, has assigned assets for the benefit of creditors generally, has made a composition or other arrangement with creditors, or has gone into liquidation or receivership or otherwise lost full capacity (see  HYPERLINK \l "Clause_36_1" Clause 36.1). Date: Signed by (there are two options mark the option which applies with an X):Builder:Builders Representative: Signature:[Form ends] Form Q Termination of contract by Building Owner For use by: Building Owner Related to:  HYPERLINK \l "Clause_18_6" Clause 18.6,  HYPERLINK \l "Clause_23_5" Clause 23.5,  HYPERLINK \l "_38._Termination_other_2" Clause 38 and  HYPERLINK \l "_39._Builders_entitlement_2" Clause 39 When to use this form The contract includes a number of clauses that provide for the termination of the contract. This form can be used by the Building Owner to terminate the contract. This notice should be delivered either in person or using one of the preferred methods nominated in  HYPERLINK \l "_4._Contract_Details_17" Clause4 of the contract entitled Contract Details. [Form begins] To [insert name of Builder]:Postal address:Postcode:Contact person:Telephone:From [insert name of Building Owner]:Postal address:Postcode:Contact person:Telephone:Regarding construction at [insertaddress of Building Site]:Notice of intention to terminate the contract I give notice that the contract is terminated for the following reason(s) (there are eight options mark the option/s which apply with an X and provide details where applicable):failure by the Builder to perform or progress the Work or the Approval Work in accordance with the contract (see  HYPERLINK \l "Clause_37_5" Clause 37.5)failure by the Builder to provide materials that comply with the contract (see  HYPERLINK \l "Clause_37_5" Clause 37.5)unreasonable failure by the Builder to replace or remedy defective Work or materials (see  HYPERLINK \l "Clause_37_5" Clause 37.5)failure by the Builder to take out or maintain any insurance required by the contract (see  HYPERLINK \l "Clause_37_5" Clause 37.5)other substantial breach of the contract by the Builder [specify]:the Builder (although responsible for doing so) has not secured a building permit within 60 calendar days from the date of being given notice of the appointment of a private building surveyor or instructions to apply to a municipal building surveyor for a building permit (see  HYPERLINK \l "Clause_18_5" Clause18.6)the Contract Price has risen by 15% or more (see  HYPERLINK \l "Clause_38_1" Clause 38.1)the contract has not been completed within one and a half (1.5) times the period by which it was to have been completed (see  HYPERLINK \l "Clause_38_1" Clause 38.1). Date: Signed by (there are two options mark the option which applies with an X):Building Owner(s):Building Owners Representative: Signature:[Form ends] Form R Notice to Builder of appointment of private building surveyor or instructions to apply to municipal building surveyor for building permit For use by: Building Owner Related to:  HYPERLINK \l "Clause_18_2" Clause 18.2 When to use this form Use this form if the Builder is responsible for applying for a building permit under the contract. The Building Owner must, as soon as practicable: appoint a private building surveyor and give notice to the Builder of the appointment, or give instructions to the Builder for the Builder to apply to a municipal building surveyor for a building permit. [Form begins] To [insert name of Builder]:Postal address:Postcode:Contact person:Telephone:From [insert name of Building Owner]:Postal address:Postcode:Contact person:Telephone:Regarding construction at [insertaddress of Building Site]:Notice of appointment of private building surveyor I give notice that I have appointed a private building surveyor whose details are listed below. I instruct and authorise you (the Builder) to apply to the private building surveyor on my behalf for a building permit. Name of building surveyor:Registration number:Postal address:Postcode:Telephone:Fax:Email:OR Instructions to apply to a municipal building surveyor for a building permit I instruct and authorise you (the Builder) to apply to a municipal building surveyor on my behalf for a building permit.  Date: Signed by (there are two options mark the option which applies with an X):Building Owner(s):Building Owners Representative: Signature:[Form ends] Publisher information Published by Consumer Affairs ɫƵ Department of Justice & Regulation 121 Exhibition Street Melbourne VIC 3000 Services from Consumer Affairs ɫƵ are available at Justice Service Centres in Ballarat, Bendigo, Box Hill, Broadmeadows, Dandenong, Geelong, Mildura, Morwell, Wangaratta and Warrnambool. Our mobile service regularly visits rural communities. Call 1300 55 81 81 or visit the  HYPERLINK "http://www.consumer.vic.gov.au" Consumer Affairs ɫƵ website for more information. TIS Telephone Interpreting Service 131 450 TTY Textphone or modem users only, ring the NRS on 133 677, then quote 1300 55 81 81 Callers who use Speech to Speech Relay dial 1300 555 727, then quote 1300 55 81 81  HYPERLINK "http://www.consumer.vic.gov.au" Consumer Affairs ɫƵ website 1300 55 81 81  HYPERLINK "mailto:consumer@justice.vic.gov.au" Email Consumer Affairs ɫƵ  1. S. 30(4)(a): Examples of relevant standards include AS 1726 1993 and AS 28701995.     (26/07/2016) HYPERLINK "http://consumer.vic.gov.au"consumer.vic.gov.au/ Page  PAGE 87 of  NUMPAGES 128  (22/06/2016) HYPERLINK "http://consumer.vic.gov.au"consumer.vic.gov.au/ Page  PAGE 1 of  NUMPAGES 3   '()*LMUVWqrstuv⾭uaPa j}h6w6UmHnHu&hr=h6w65CJaJmHnHtH u jh6w6UmHnHujh6w6UmHnHuh6w6mHnHuh zh6w6OJQJmHnHu hUhpCJOJQJ^JaJ)jhUhpCJOJQJU^JaJhUhoCJ"OJQJaJ"hUh1CJ"OJQJaJ"hUh1CJ&OJQJaJ& )v% P  X  V  Z = Nedq7~Egd6w6edq7~Egd6w6edq7~Egdo edq7~Egd1   ! " # $ % / 0 1 K L M N O P ĴأĴؒĴ؁o]"h zh6w66OJQJmHnHu#hr=h6w6CJaJmHnHtH u jqh6w6UmHnHu jh6w6UmHnHu jwh6w6UmHnHuh zh6w6OJQJmHnHu&hr=h6w65CJaJmHnHtH uh6w6mHnHujh6w6UmHnHu jh6w6UmHnHu$       7 8 9 S T U V W X ƶƶƶqƶ jeh6w6UmHnHu jh6w6UmHnHu jkh6w6UmHnHu"h zh6w66OJQJmHnHuh zh6w6OJQJmHnHu#hr=h6w6CJaJmHnHtH u jh6w6UmHnHuh6w6mHnHujh6w6UmHnHu'      5 6 7 Q R S T U V Y t u v ƶإƶؔƶqƶ jYh6w6UmHnHu"h zh6w66OJQJmHnHu jh6w6UmHnHu j_h6w6UmHnHuh zh6w6OJQJmHnHu#hr=h6w6CJaJmHnHtH uh6w6mHnHujh6w6UmHnHu jh6w6UmHnHu%    8 9 : T U V X Y Z u v w ƶؓƶ؂ƶqƶ jMh6w6UmHnHu jh6w6UmHnHu jSh6w6UmHnHu"h zh6w66OJQJmHnHuh zh6w6OJQJmHnHu#hr=h6w6CJaJmHnHtH uh6w6mHnHujh6w6UmHnHu jh6w6UmHnHu&    7 8 9 ; < = k l m ĴأĴؒĴ؁o#hr=h6w6CJaJmHnHtH u jA h6w6UmHnHu j h6w6UmHnHu jG h6w6UmHnHuh zh6w6OJQJmHnHu&hr=h6w65CJaJmHnHtH uh6w6mHnHujh6w6UmHnHu jh6w6UmHnHu$,-.HIJLMN_`a{|}Ĵأᑴ؀ᑴnn]ᑴ j5 h6w6UmHnHu"h zh6w66OJQJmHnHu j h6w6UmHnHu#hr=h6w6CJaJmHnHtH u j; h6w6UmHnHuh zh6w6OJQJmHnHu&hr=h6w65CJaJmHnHtH uh6w6mHnHujh6w6UmHnHu j h6w6UmHnHu$NFr>v$Us-d_aedq7~Egd6w6 $%&@ABDEFPQRlmnpqr״״״q״ j)h6w6UmHnHu j h6w6UmHnHu j/ h6w6UmHnHuh zh6w6OJQJmHnHu#hr=h6w6CJaJmHnHtH u j h6w6UmHnHujh6w6UmHnHuh6w6mHnHu"h zh6w66OJQJmHnHu*89:<=>TUVpqrtuvƶؓƶ؂ƶqƶ jh6w6UmHnHu jh6w6UmHnHu j#h6w6UmHnHu"h zh6w66OJQJmHnHuh zh6w6OJQJmHnHu#hr=h6w6CJaJmHnHtH uh6w6mHnHujh6w6UmHnHu jh6w6UmHnHu' "#$(345OPQSTUtƶؓƶ؂ƶqƶ jh6w6UmHnHu jh6w6UmHnHu jh6w6UmHnHu"h zh6w66OJQJmHnHuh zh6w6OJQJmHnHu#hr=h6w6CJaJmHnHtH uh6w6mHnHujh6w6UmHnHu jh6w6UmHnHu( QRSmnoqrsƶؓƶ؂ƶqƶ jh6w6UmHnHu jh6w6UmHnHu j h6w6UmHnHu"h zh6w66OJQJmHnHuh zh6w6OJQJmHnHu#hr=h6w6CJaJmHnHtH uh6w6mHnHujh6w6UmHnHu jh6w6UmHnHu'   '()+,-1BCD^_`bcdhrstƶؓƶ؂ƶqƶ jh6w6UmHnHu j|h6w6UmHnHu jh6w6UmHnHu"h zh6w66OJQJmHnHuh zh6w6OJQJmHnHu#hr=h6w6CJaJmHnHtH uh6w6mHnHujh6w6UmHnHu jh6w6UmHnHu((-=>?YZ[]^_ƶؓƶ؂ƶqƶ jh6w6UmHnHu jph6w6UmHnHu jh6w6UmHnHu"h zh6w66OJQJmHnHuh zh6w6OJQJmHnHu#hr=h6w6CJaJmHnHtH uh6w6mHnHujh6w6UmHnHu jvh6w6UmHnHu+?@A[\]_`aekstuƶؓƶ؂ƶqƶ jh6w6UmHnHu jdh6w6UmHnHu jh6w6UmHnHu"h zh6w66OJQJmHnHuh zh6w6OJQJmHnHu#hr=h6w6CJaJmHnHtH uh6w6mHnHujh6w6UmHnHu jjh6w6UmHnHu*ai2{iX@wf'pedq7~Egd6w6edq7~Egd6w6GHIcdeghim,ƶإƶ؂ƶqƶ jh6w6UmHnHu jXh6w6UmHnHu"h zh6w66OJQJmHnHu jh6w6UmHnHuh zh6w6OJQJmHnHu#hr=h6w6CJaJmHnHtH uh6w6mHnHujh6w6UmHnHu j^h6w6UmHnHu(,-.012YZ[uvwyz{@GHIcƶإƶؔƶ؃ƶq"h zh6w66OJQJmHnHu jh6w6UmHnHu jLh6w6UmHnHu jh6w6UmHnHuh zh6w6OJQJmHnHu#hr=h6w6CJaJmHnHtH uh6w6mHnHujh6w6UmHnHu jRh6w6UmHnHu%cdeghi678Rƶؓƶ؂ƶqƶ jh6w6UmHnHu j@h6w6UmHnHu jh6w6UmHnHu"h zh6w66OJQJmHnHuh zh6w6OJQJmHnHu#hr=h6w6CJaJmHnHtH uh6w6mHnHujh6w6UmHnHu jFh6w6UmHnHu%RSTVWXjkl  :ƶإƓ؂Ɠqƶ j!h6w6UmHnHu j4!h6w6UmHnHu"h zh6w66OJQJmHnHu j h6w6UmHnHuh zh6w6OJQJmHnHu#hr=h6w6CJaJmHnHtH uh6w6mHnHujh6w6UmHnHu j: h6w6UmHnHu':;<>?@UVWqrsuvwDEF`Ĵأᑴ؀ᑴoᑴ j#h6w6UmHnHu j(#h6w6UmHnHu#hr=h6w6CJaJmHnHtH u j"h6w6UmHnHuh zh6w6OJQJmHnHu&hr=h6w65CJaJmHnHtH uh6w6mHnHujh6w6UmHnHu j."h6w6UmHnHu$`abdefq{|}!"#%&'JNOƶؓƶ؂ƶq]&hr=h6w65CJaJmHnHtH u j%h6w6UmHnHu j%h6w6UmHnHu j$h6w6UmHnHu"h zh6w66OJQJmHnHuh zh6w6OJQJmHnHu#hr=h6w6CJaJmHnHtH uh6w6mHnHujh6w6UmHnHu j"$h6w6UmHnHu$OPjklnop"#$&'(hijƶƶƶƶrƶ j (h6w6UmHnHu j'h6w6UmHnHu j'h6w6UmHnHu j&h6w6UmHnHuh zh6w6OJQJmHnHu#hr=h6w6CJaJmHnHtH u j&h6w6UmHnHuh6w6mHnHujh6w6UmHnHu,p(0E5 z C!!M"}"""*#>#%&'edq7~Egdyedq7~EgdI0 edq7~Egd6w6edq7~Egd6w6edq7~Egd6w6*+,./0`qrs #$%?@ACDE_`a{ŵŵŵpŵ j)h6w6UmHnHu j)h6w6UmHnHu j)h6w6UmHnHu"h zh6w66OJQJmHnHuh zh6w6OJQJmHnHu#hr=h6w6CJaJmHnHtH u j(h6w6UmHnHujh6w6UmHnHuh6w6mHnHu+{|}    . / 0 3 4 5 W X Y s t u x y z ƶؓƶ؂ƶqƶ j+h6w6UmHnHu ju+h6w6UmHnHu j*h6w6UmHnHu"h zh6w66OJQJmHnHuh zh6w6OJQJmHnHu#hr=h6w6CJaJmHnHtH uh6w6mHnHujh6w6UmHnHu j{*h6w6UmHnHu( ! !!!"!!A!B!C!g!u!v!w!!!!!!!!!*"+","F"ƶؓƶ؂ƶqƶ j-h6w6UmHnHu ji-h6w6UmHnHu j,h6w6UmHnHu"h zh6w66OJQJmHnHuh zh6w6OJQJmHnHu#hr=h6w6CJaJmHnHtH uh6w6mHnHujh6w6UmHnHu jo,h6w6UmHnHu)F"G"H"K"L"M"Z"["\"v"w"x"{"|"}"""""""""""""ƶإƶؔm^M hUhyCJOJQJ^JaJhUhpCJ"OJQJaJ"%jhUhpCJ"OJQJUaJ"&hr=h6w65CJaJmHnHtH u j]/h6w6UmHnHu j.h6w6UmHnHuh zh6w6OJQJmHnHu#hr=h6w6CJaJmHnHtH uh6w6mHnHujh6w6UmHnHu jc.h6w6UmHnHu"## #!#"#$#*#>#n#{#####!$($G$H$`$$$$$ %'%+%i%p%%%%%C&J&\&j&((=(޾ޭwf hUh\$xCJOJQJ^JaJ)jhUh\$xCJOJQJU^JaJ$hUh10J,CJOJQJ^JaJh'CJOJQJ^JaJ hUh1CJOJQJ^JaJhUh1CJ"OJQJaJ" hUhCJOJQJ^JaJ hUhyCJOJQJ^JaJ hUhrCJOJQJ^JaJ'=(>(?(E(F(((((/)6)))))**'+++U+\+++@,\,c,x,,,-6-;-ҿҮwwfU hUhzCJOJQJ^JaJ hUh*50CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ)jhUh\$xCJOJQJU^JaJ/j/hUh\$xCJOJQJU^JaJ'()R**+@,d,,-..... $IfgdI0 $Ifgd< edq7~Egd$edq7~EgdB+edq7~EgdB+edq7~EgdI0 ;-<-h-i-j------... .!.4.5.ꮛudLuu7)jhUhVCJOJQJU^JaJ/j 1hUhzCJOJQJU^JaJ hUhzCJOJQJ^JaJ)jhUhzCJOJQJU^JaJ hUh1CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ$hUhz0JCJOJQJ^JaJ/j]0hUhzCJOJQJU^JaJ hUhzCJOJQJ^JaJ)jhUhzCJOJQJU^JaJ5.U.V.W.].^....... ///(/)/¯žq`H5$hUh^*0JCJOJQJ^JaJ/j2hUhVCJOJQJU^JaJ hUh^*CJOJQJ^JaJ#hUh^*5CJOJQJ^JaJhUh1CJ"OJQJaJ"hstCJ"OJQJaJ" hUh1CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ)jhUhVCJOJQJU^JaJ/j1hUhVCJOJQJU^JaJ hUhVCJOJQJ^JaJ..*//1tkkb $IfgdV $IfgdB+kd2$$Ifl440 ~& t0644 lalf4pyt1N)/Z/h/// 00N0\0000000001111&1-11111˸ˣzgTg˸C hUh^*CJOJQJ^JaJ$hUhV0JCJOJQJ^JaJ$hUh0JCJOJQJ^JaJ/jS3hUhVCJOJQJU^JaJ hUhVCJOJQJ^JaJ)jhUhVCJOJQJU^JaJ$hUh0J,CJOJQJ^JaJ hUhCJOJQJ^JaJ$hUh^*0J,CJOJQJ^JaJ hUh^*CJOJQJ^JaJ111G3ull $IfgdB+kd3$$Ifl40 ~& t0644 lalf4pyt1N111111f2t233%3,3G3H3I3k3l3m3s3t3344444444¯žzb¯žzJ/j6hUhVCJOJQJU^JaJ/j5hUhVCJOJQJU^JaJ hUhCJOJQJ^JaJ$hUh0J,CJOJQJ^JaJ hUhCJOJQJ^JaJ$hUh0JCJOJQJ^JaJ)jhUhVCJOJQJU^JaJ/j4hUhVCJOJQJU^JaJ hUhVCJOJQJ^JaJG3H3344ullc $Ifgdw; $IfgdB+kd5$$Ifl40 ~& t0644 lalf4pyt1N444f56ulcZ $IfgdT $IfgdB+ $IfgdVkd:6$$Ifl40 ~& t0644 lalf4pyt1N4444444445555555555고|||kVE hUhTCJOJQJ^JaJ)jhUh<)CJOJQJU^JaJ hUhCJOJQJ^JaJ$hUh\0J,CJOJQJ^JaJ hUh\CJOJQJ^JaJ$hUh0J,CJOJQJ^JaJ hUhCJOJQJ^JaJ$hUhV0JCJOJQJ^JaJ$hUh0JCJOJQJ^JaJ)jhUhVCJOJQJU^JaJ555666666 6!6>6?6@6X6Y6m6u6x6666ҿҮyhPҿҝy=y=y$hUh\0J,CJOJQJ^JaJ/j7hUhTCJOJQJU^JaJ hUhTCJOJQJ^JaJ hUh\CJOJQJ^JaJ$hUh0J,CJOJQJ^JaJ hUhCJOJQJ^JaJ hUh<)CJOJQJ^JaJ$hUhT0JCJOJQJ^JaJ)jhUh<)CJOJQJU^JaJ/jn7hUhTCJOJQJU^JaJ66666666677777778ɸɍ|kZIZk4I)jhUhC CJOJQJU^JaJ hUh.CJOJQJ^JaJ hUhECJOJQJ^JaJ hUhC CJOJQJ^JaJ hUh\CJOJQJ^JaJ$hUh\0JCJOJQJ^JaJ/j9hUhVCJOJQJU^JaJ hUhVCJOJQJ^JaJ)jhUhVCJOJQJU^JaJ hUhCJOJQJ^JaJ hUhCJOJQJ^JaJ666w8ulc $IfgdC $IfgdB+kdl8$$Ifl40 ~& t0644 lalf4pyt1N88828388898`8a8b8t8u8v8w8x88888^9b999ҿҮp_pLpLpLp:#hUh\6CJOJQJ^JaJ$hUh\0J,CJOJQJ^JaJ hUh\CJOJQJ^JaJ hUh\CJOJQJ^JaJ/jC:hUh.CJOJQJU^JaJ)jhUh.CJOJQJU^JaJ hUh.CJOJQJ^JaJ$hUh.0JCJOJQJ^JaJ)jhUhC CJOJQJU^JaJ/j9hUh.CJOJQJU^JaJw8x8~8?99ulll $IfgdB+kd:$$Ifl40 ~& t0644 lalf4pyt1N999999:W:[:::!;/;<<&<'<7<= =A=B=g=h=i=========ﶥzfU hUhc!CJOJQJ^JaJ'hUh\0J6CJOJQJ^JaJ$hUh\0JCJOJQJ^JaJ/j<hUh.CJOJQJU^JaJ hUh.CJOJQJ^JaJ)jhUh.CJOJQJU^JaJ hUh\CJOJQJ^JaJ$hUh\0J,CJOJQJ^JaJ hUh\CJOJQJ^JaJ 9:::;<ullll $IfgdB+kdu;$$Ifl40 ~& t0644 lalf4pyt1N<<'<?==ullc $Ifgd. $IfgdB+kd<$$Ifl40 ~& t0644 lalf4pyt1N===>?ullc $Ifgd. $IfgdB+kdH=$$Ifl40 ~& t0644 lalf4pyt1N==[>_>>>>>)?*?+?R?a?f?g?????ǶNjwfUD hUh1CJOJQJ^JaJ hUh\CJOJQJ^JaJ hUh\CJOJQJ^JaJ'hUhc!0J6CJOJQJ^JaJ$hUhc!0JCJOJQJ^JaJ/j=hUh.CJOJQJU^JaJ hUh.CJOJQJ^JaJ)jhUh.CJOJQJU^JaJ hUhc!CJOJQJ^JaJ$hUhc!0J,CJOJQJ^JaJ???@7@]@m@AAumdYYYQF $a$edq7~EgdB+edq7~EgdB+ $a$edq7~EgdYB $edq7~Egd:edq7~EgdI0 kd>$$Ifl40 ~& t0644 lalf4pyt1N????????????????????ɶɣɐ{jR{?$hUh10JCJOJQJ^JaJ/j-?hUh.CJOJQJU^JaJ hUh.CJOJQJ^JaJ)jhUh.CJOJQJU^JaJ$hUh1@CJOJQJ^JaJ$hUh1@CJOJQJ^JaJ$hUh1@CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh1@CJOJQJ^JaJ$hUh1@CJOJQJ^JaJ???????????????@7@خؙ؄o^O=#hUh15CJOJQJ^JaJhUh1CJ"OJQJaJ" hUh1CJOJQJ^JaJ)jhUh.CJOJQJU^JaJ(hUh10J@CJOJQJ^JaJ(hUh10J@CJOJQJ^JaJ(hUh10J@CJOJQJ^JaJ(hUh10J@CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ(hUh10J@CJOJQJ^JaJ7@\@AAAAAAAABBBBCCCD!D"D?D@DBDީީޘraO=#hUh15CJOJQJ^JaJ#hUh.c5CJOJQJ^JaJ hUh:CJOJQJ^JaJ hUhnB>CJOJQJ^JaJ)j?hUh(CJOJQJU^JaJ h6w6h'CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUhjCJOJQJ^JaJ hUh.cCJOJQJ^JaJ hUh1CJOJQJ^JaJ hUh\CJOJQJ^JaJAABBPCCCCD"D@DD1ll$d %d&d 'dN OP Q]l^ledq7~Egdedq7~Egd: $a$edq7~EgdnB>]^edq7~Egd(T^T`edq7~Egd'edq7~Egd2` $a$edq7~EgdB+ BDPD{D~DDDDDDDDD-E1E[E^EbEpEEEEEEFF F FFFFFFFܸܥܸܔ܃p___p_ hUh:CJOJQJ^JaJ$hUh:0J,CJOJQJ^JaJ hUh:CJOJQJ^JaJ hUh'6CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ hUh3tuCJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10J1CJOJQJ^JaJ D[EEFFF2kd2H$$Ifedq7~El40Q % t0$644 lalf4itq7~Epyt: K$Ifgd:1Dl$d %d&d 'dN OP Q]l^edq7~EgdF F F FFdkdH$$Ifedq7~El40Q % t0$644 lalf4itq7~Epyt: K$Ifgd:FFFF|| $Ifgd:zkdI$$Ifedq7~El4% t0$644 lalf4itq7~Ep yt:FFFFmdd K$Ifgd:kd_K_Q___s_z___``'`5`7`8`?```b`ud h&.h2;CJOJQJ^JaJhu*WCJOJQJ^JaJh?%CJOJQJ^JaJh1CJOJQJ^JaJh_CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ h&.h_CJOJQJ^JaJh&.CJOJQJ^JaJh"U6CJOJQJ^JaJ&b`f`t`z`````````a a:aGaKaOa^afagakaraaaaaaaaaaaabbbĶħĶĊ|n\#h]h2;6CJOJQJ^JaJh/CJOJQJ^JaJhDvCJOJQJ^JaJh&CJOJQJ^JaJh?%6CJOJQJ^JaJh2;6CJOJQJ^JaJh?%CJOJQJ^JaJh2;CJOJQJ^JaJ h&.h2;CJOJQJ^JaJh"U6CJOJQJ^JaJh"UCJOJQJ^JaJ$bDbEbbbbbbcc&c'c*cEcFcNcickccϺݧϙψygyXFX3$hUh10J,CJOJQJ^JaJ#hUh10J15CJOJQJaJhUh1CJOJQJaJ#hUh10J15CJOJQJaJhUh1CJOJQJaJ hUh2;CJOJQJ^JaJh"UCJOJQJ^JaJ$h&.h2;0JCJOJQJ^JaJ)jOh2;CJOJQJU^JaJh2;CJOJQJ^JaJ#jh2;CJOJQJU^JaJ h&.h2;CJOJQJ^JaJcccccccccZd[ddddeeAeBeCeKeLe^e_eﮠzbO> hUho"'CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ/jzPhUhfeCJOJQJU^JaJ hUhfeCJOJQJ^JaJ)jhUhfeCJOJQJU^JaJh?%CJOJQJ^JaJh'CJOJQJ^JaJhCJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ#hUh15CJOJQJ^JaJ hUh1CJOJQJ^JaJ_egeeeeeeeeeeef!f=fXfwffffffffffg7gPgQgmgλλΪλλλΙλλu`u)jhUhzCJOJQJU^JaJ hUhzCJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUh uCJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ#hUh10J15CJOJQJaJhUh1CJOJQJaJmgngogvgygzgggggggggghh-h;hRh`hhhhhҿқwfUfC#hUh10J5CJOJQJaJ hUh uCJOJQJ^JaJ hUh CJOJQJ^JaJ hUhJ$WCJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ$hUhz0JCJOJQJ^JaJ)jhUhzCJOJQJU^JaJ/j QhUhzCJOJQJU^JaJh)hhh{iiii^jj kkk!lllm:mm nnpr(redq7~Egd]$edq7~Egd]edq7~Egd]edq7~Egd]edq7~Egd B@edq7~EgdJ$Whhhhhi#iIiWi{iiiiiii-j1jmjtjjjj kk%k'kBkkk!l?lZlllm:mtm{mmmmʷʷʷʦʷʷʓʷʓuʷʷhUh1CJOJQJaJhUh1CJOJQJaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ#hUh10J5CJOJQJaJ#hUh10J15CJOJQJaJ)mmmmmmmmmmm nnnn$nFnJngnhnnnnnnnnnnٝ|iiiQٝi/jRhUho"'CJOJQJU^JaJ$hUh10J,CJOJQJ^JaJ#hUh10J15CJOJQJaJhUh1CJOJQJaJ hUh1CJOJQJ^JaJ$hUho"'0JCJOJQJ^JaJ/jQhUho"'CJOJQJU^JaJ hUho"'CJOJQJ^JaJ)jhUhfeCJOJQJU^JaJnnnn$oVoooppRpYpbppppppppp/q_qdqrqqqqqqqr'r(r,r:rCrJrurrrrrᱢ| hUhH-KCJOJQJ^JaJ)jhUhH-KCJOJQJU^JaJhUh1CJOJQJaJhUh1CJOJQJaJ$hUh10J,CJOJQJ^JaJh?%CJOJQJ^JaJ hUh1CJOJQJ^JaJhCJOJQJ^JaJ)rrrrrrss)sttttBtCtDtLtMtOtktotttҿҮu]J;hUh1CJOJQJaJ$hUh10JCJOJQJ^JaJ/j+ShUhOrCJOJQJU^JaJ hUhOrCJOJQJ^JaJ)jhUhOrCJOJQJU^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUhH-K0JCJOJQJ^JaJ)jhUhH-KCJOJQJU^JaJ/jRhUhH-KCJOJQJU^JaJ(rr\sOtkt7uovwwwxAx~x'y~y?zzzz xx$Ifgd2;$xx$Ifa$gd2;d((edq7~Egdedq7~Egdedq7~Egd edq7~Egd $edq7~Egdzedq7~Egdedq7~Egdtttttt uuuuuuvvvvvvvvvvwrwwwwwAxXx~x'yUyYyösdh"U5CJOJQJ\^J"hok1h5CJOJQJ\^Jhok1hCJOJQJ^J"hok1h56CJOJQJ^Jhok1h5CJOJQJ^Jhok1hCJ OJQJhok1CJ OJQJhUh1CJ"OJQJaJ" hUh1CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ Yyhymy~yq||.R ./6AFJJeοοΟwn_P? hUh1CJOJQJ^JaJhUh1CJOJQJaJh5CJOJQJ^JaJhok1hCJh"UhCJOJQJ^Jh"U6CJOJQJ^Jh"UCJOJQJ^Jhok1h5CJOJQJ^Jhok1h6CJOJQJ^Jhok1hCJOJQJ^J"hok1h5CJOJQJ\^Jh"U5CJOJQJ\^Jh"U56CJOJQJ\^JzzzzS{W{X{5kdS$$Ifedq7~Elgr[C"'?@&644 laitq7~Ep2yt xx$Ifgd2;$xx$Ifa$gd2;X{[{\{]{{g|k|5kdT$$Ifedq7~Elr[C"'?@&644 laitq7~Ep2yt xx$Ifgd2;$xx$Ifa$gd2;k|l|o|p|q||5kdU$$Ifedq7~Elr[C"'?@&644 laitq7~Ep2yt$xx$Ifa$gd2; xx$Ifgd2;||7};}<}?}@} xx$Ifgd2;$xx$Ifa$gd2;LkdV$$Ifedq7~El'&&644 laitq7~Ep yt@}A}}}}}}RBB5B5 xx$Ifgd2;$xx$Ifa$gd2;kd.$xx$Ifa$gd2; xxedq7~Egdedq7~Egdkd|f$$Ifedq7~Elr[C"'?@&644 laitq7~Ep2yt/016ABym Z$$Ifa$gd2;$x$Ifa$gd2;hkdg$$Ifedq7~ETl0F&^'644 laitq7~EpytT xx$Ifgd2;BCDJ CQ`}uuh 2dd$IfgdVedq7~Egd $edq7~Egdzedq7~Egdzedq7~Egdhkd9h$$Ifedq7~ETl0F&^'644 laitq7~EpytT el˅CPQhtuv˺tatL; hUhyCJOJQJ^JaJ)jhUhyCJOJQJU^JaJ$hUhRG0J,CJOJQJ^JaJ hUhRGCJOJQJ^JaJ hUhRGCJOJQJ^JaJ#hUhUv5CJOJQJ^JaJ#hUhRG5CJOJQJ^JaJ hUhzCJOJQJ^JaJ hUh\CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ`uvۆ܆VI< dd$IfgdV 2dd$IfgdVkdh$$Ifedq7~El440~& t0644 lalf4itq7~Epyt2dd$If^`gdVʆˆچ܆݆!=>[\]hi̇ҿҮyyhPҿҮyh/jjhUhyCJOJQJU^JaJ hUhyCJOJQJ^JaJ$hUhRG0J,CJOJQJ^JaJ hUhxCJOJQJ^JaJ hUhxCJOJQJ^JaJ hUhRGCJOJQJ^JaJ$hUhRG0JCJOJQJ^JaJ)jhUhyCJOJQJU^JaJ/jihUhyCJOJQJU^JaJ܆݆هڇm`S dd$IfgdV 2dd$IfgdVkdj$$Ifedq7~El40~& t0644 lalf4itq7~Epyṫ͇·ևׇڇۇ!"45aoΈҿҮudLuuud/jlhUhCJOJQJU^JaJ hUhCJOJQJ^JaJ)jhUhCJOJQJU^JaJ$hUhRG0J,CJOJQJ^JaJ hUhRGCJOJQJ^JaJ hUhRGCJOJQJ^JaJ$hUhRG0JCJOJQJ^JaJ)jhUhyCJOJQJU^JaJ/jGkhUhyCJOJQJU^JaJڇۇ34m`S dd$IfgdV 2dd$IfgdVkdk$$Ifedq7~El40~& t0644 lalf4itq7~Epyt45݈ވm`S dd$IfgdV 2dd$IfgdVkdm$$Ifedq7~El40~& t0644 lalf4itq7~EpytΈψЈڈۈވ߈!/TUqrs}~ҿҮyhP=Ҍ$hUhz0JCJOJQJ^JaJ/jnhUhCJOJQJU^JaJ hUhCJOJQJ^JaJ$hUhz0J,CJOJQJ^JaJ hUhzCJOJQJ^JaJ hUhRGCJOJQJ^JaJ hUhRGCJOJQJ^JaJ$hUhRG0JCJOJQJ^JaJ)jhUhCJOJQJU^JaJ/jmhUhCJOJQJU^JaJވ߈m`S dd$IfgdV 2dd$IfgdVkd0n$$Ifedq7~El40~& t0644 lalf4itq7~Epytm`S dd$IfgdV 2dd$IfgdVkd]o$$Ifedq7~El40~& t0644 lalf4itq7~EpytՉ։׉#A\NJȊɊ޶zeT dd$IfgdV$ dd$If^gdV 2dd$IfgdVkdr$$Ifedq7~El40~& t0644 lalf4itq7~EpytԌՌklҿҮҊrҿҮaaNa9)jhUh&4CJOJQJU^JaJ$hUhz0J,CJOJQJ^JaJ hUhzCJOJQJ^JaJ/jthUh&4CJOJQJU^JaJ hUh&4CJOJQJ^JaJ$hUhz0J,CJOJQJ^JaJ hUhzCJOJQJ^JaJ$hUhz0JCJOJQJ^JaJ)jhUh&4CJOJQJU^JaJ/jshUh&4CJOJQJU^JaJm`S dd$IfgdV 2dd$IfgdVkdt$$Ifedq7~El40~& t0644 lalf4itq7~Epytl΍ύЍ"267T¯žx`O<<$hUhz0J,CJOJQJ^JaJ hUhzCJOJQJ^JaJ/juhUh#CJOJQJU^JaJ hUh#CJOJQJ^JaJ)jhUh#CJOJQJU^JaJ hUhzCJOJQJ^JaJ$hUhz0JCJOJQJ^JaJ)jhUh&4CJOJQJU^JaJ/j>uhUh&4CJOJQJU^JaJ hUh&4CJOJQJ^JaJdem`S dd$IfgdV 2dd$IfgdVkdPv$$Ifedq7~El40~& t0644 lalf4itq7~EpytTUVabefsz֎׎؎ҿҮyhP=Үh$hUh&40JCJOJQJ^JaJ/j5xhUh&4CJOJQJU^JaJ hUh&4CJOJQJ^JaJ hUh CJOJQJ^JaJ$hUhz0J,CJOJQJ^JaJ hUhzCJOJQJ^JaJ hUhzCJOJQJ^JaJ$hUhz0JCJOJQJ^JaJ)jhUh&4CJOJQJU^JaJ/jwhUh&4CJOJQJU^JaJefm`S dd$IfgdV 2dd$IfgdVkdw$$Ifedq7~El40~& t0644 lalf4itq7~Epyt =A^nߏҿқwwbQ9bbbQ/jyhUh#CJOJQJU^JaJ hUh#CJOJQJ^JaJ)jhUh#CJOJQJU^JaJ$hUhz0J,CJOJQJ^JaJ hUhzCJOJQJ^JaJ hUhzCJOJQJ^JaJ$hUhz0JCJOJQJ^JaJ$hUh 0JCJOJQJ^JaJ)jhUh&4CJOJQJU^JaJ/jxhUh&4CJOJQJU^JaJm`S dd$IfgdV 2dd$IfgdVkd)y$$Ifedq7~El40~& t0644 lalf4itq7~Epytߏ9JlmҿҮyaҿҮL)jhUh9@CJOJQJU^JaJ/j{hUh#CJOJQJU^JaJ hUh#CJOJQJ^JaJ$hUhz0J,CJOJQJ^JaJ hUhzCJOJQJ^JaJ hUhzCJOJQJ^JaJ$hUhz0JCJOJQJ^JaJ)jhUh#CJOJQJU^JaJ/jnzhUh#CJOJQJU^JaJm`S dd$IfgdV 2dd$IfgdVkdz$$Ifedq7~El40~& t0644 lalf4itq7~Epyt78m`S dd$IfgdV 2dd$IfgdVkd|$$Ifedq7~El40~& t0644 lalf4itq7~Epytܐݐސ89EShiϑ֑"-.K¯žzb¯žzzzz/j}hUh9@CJOJQJU^JaJ$hUhz0J,CJOJQJ^JaJ hUhzCJOJQJ^JaJ hUhzCJOJQJ^JaJ$hUhz0JCJOJQJ^JaJ)jhUh9@CJOJQJU^JaJ/j|hUh9@CJOJQJU^JaJ hUh9@CJOJQJ^JaJ89m`S dd$IfgdV 2dd$IfgdVkdE}$$Ifedq7~El40~& t0644 lalf4itq7~Epytm`S dd$IfgdV 2dd$IfgdVkdt~$$Ifedq7~El40~& t0644 lalf4itq7~EpytKLMXYĒҒ(1?@LZҿҮyaҿҮy/jYhUh9@CJOJQJU^JaJ hUh9@CJOJQJ^JaJ hUhzCJOJQJ^JaJ$hUhz0J,CJOJQJ^JaJ hUhzCJOJQJ^JaJ$hUhz0JCJOJQJ^JaJ)jhUh9@CJOJQJU^JaJ/j*hUh9@CJOJQJU^JaJ>?m`S dd$IfgdV 2dd$IfgdVkd$$Ifedq7~El40~& t0644 lalf4itq7~Epyt?@ABm`S dd$IfgdV 2dd$IfgdVkdҀ$$Ifedq7~El40~& t0644 lalf4itq7~Epyt 345>?BCP^gnҿҮҝҿҮtaaL; hUhNCJOJQJ^JaJ)jhUhNCJOJQJU^JaJ$hUhz0J,CJOJQJ^JaJ hUhzCJOJQJ^JaJ/jhUh9@CJOJQJU^JaJ hUh9@CJOJQJ^JaJ hUhzCJOJQJ^JaJ$hUhz0JCJOJQJ^JaJ)jhUh9@CJOJQJU^JaJ/jhUh9@CJOJQJU^JaJBC67m`S dd$IfgdV 2dd$IfgdVkd$$Ifedq7~El40~& t0644 lalf4itq7~Epyt”Ŕ͔()*3478DMdnpҿҮҊrҿҮaҊ hUhzCJOJQJ^JaJ/jۃhUhNCJOJQJU^JaJ hUhNCJOJQJ^JaJ$hUhz0J,CJOJQJ^JaJ hUhzCJOJQJ^JaJ$hUhz0JCJOJQJ^JaJ)jhUhNCJOJQJU^JaJ/jZhUhNCJOJQJU^JaJ 78m`S dd$IfgdV 2dd$IfgdVkd`$$Ifedq7~El40~& t0644 lalf4itq7~Epyt#89Z[\rs{~ĖŖҿҮyaҿҮyIҿ/j܆hUhNCJOJQJU^JaJ/j[hUhNCJOJQJU^JaJ hUhNCJOJQJ^JaJ$hUhz0J,CJOJQJ^JaJ hUhzCJOJQJ^JaJ hUhzCJOJQJ^JaJ$hUhz0JCJOJQJ^JaJ)jhUhNCJOJQJU^JaJ/jhUhNCJOJQJU^JaJm`S dd$IfgdV 2dd$IfgdVkd$$Ifedq7~El40~& t0644 lalf4itq7~Epyt  'UVyz{ȗɗﶥziViE4 hUhVCJOJQJ^JaJ hUhVCJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUhz0JCJOJQJ^JaJ/j#hUhuCJOJQJU^JaJ hUhuCJOJQJ^JaJ)jhUhuCJOJQJU^JaJ$hUhz0J,CJOJQJ^JaJ hUhzCJOJQJ^JaJ hUhzCJOJQJ^JaJm`S dd$IfgdV 2dd$IfgdVkdm$$Ifedq7~El40~& t0644 lalf4itq7~EpytǗȗmeXC2dd$If^`gdV 2dd$IfgdVedq7~EgdX kd$$Ifedq7~El40~& t0644 lalf4itq7~EpytȗɗϗЗk^I2dd$If^`gdV 2dd$IfgdVkd^$$Ifedq7~El4n0~& t0644 lalf4itq7~EpytVɗЗї9hw%(3XYfҙ֙NUƚ1ͺީvgvͺͺͺͺYͺͺͺͺhu CJOJQJ^JaJhUh1CJOJQJaJ$hUh10J+CJOJQJ^JaJhUh1CJ"OJQJaJ" hUhzCJOJQJ^JaJ hUh\CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUhVCJOJQJ^JaJ hUhVCJOJQJ^JaJ"ЗїmaXG2$If^`gdV 2$IfgdV  #edq7~EgdRkd$$Ifedq7~El40~& t0644 lalf4itq7~EpytV m`K2dd$If^`gdV 2dd$IfgdVkdΊ$$Ifedq7~El40~& t0644 lalf4itq7~EpytV9hw%me\TLTDedq7~Egd aCedq7~Egdedq7~Egd $edq7~EgdWuedq7~Egdzkd$$Ifedq7~El40~& t0644 lalf4itq7~EpytV%YN1}"gV7$Kӡ6{'$edq7~Egdcedq7~Egdc%edq7~Egd aC$edq7~Egd aCedq7~Egd aC1Iu|Ûʛԛ)9AOaqۜ-\jtםgy۞ܞݞ ܶz$hUh10JCJOJQJ^JaJ/j:hUhuCJOJQJU^JaJ hUhuCJOJQJ^JaJ)jhUhuCJOJQJU^JaJ hUh1CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ0 !IJKSTVd KO]ġšơСѡӡ١ꝊyyyyyffNf/jPhUhuCJOJQJU^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ/jhUhuCJOJQJU^JaJ hUhuCJOJQJ^JaJ)jhUhuCJOJQJU^JaJ١ '()456:OP{˶zgRA hUhACJOJQJ^JaJ)jhUhACJOJQJU^JaJ$hUh10J,CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ/jǍhUhCJOJQJU^JaJ hUhCJOJQJ^JaJ)jhUhCJOJQJU^JaJ hUh1CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ{|}գ֣ף%'CdҿҮu]uJu$hUhW0JCJOJQJ^JaJ/jՎhUhWCJOJQJU^JaJ)jhUhJCJOJQJU^JaJ hUhWCJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ)jhUhACJOJQJU^JaJ/j@hUhACJOJQJU^JaJdeȤӤդ$%'3Pav{%*INYZwꝊrꝊ/jhUhuCJOJQJU^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ/jjhUhuCJOJQJU^JaJ hUhuCJOJQJ^JaJ)jhUhuCJOJQJU^JaJ$'դ')Ʃ?HӫP^p̭Gk֯ʰao2edq7~Egd/'edq7~Egd/' $edq7~Egdbedq7~EgdcwxyѦҦӦ'zҿҮu]I'hUh10J6CJOJQJ^JaJ/jӐhUhECJOJQJU^JaJ hUhECJOJQJ^JaJ)jhUhECJOJQJU^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ)jhUhuCJOJQJU^JaJ/jZhUhuCJOJQJU^JaJާߧ)/qĨۨ#$DRlzƩש1ꝊrꝊ/jߑhUh--CJOJQJU^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ/jPhUh--CJOJQJU^JaJ hUh--CJOJQJ^JaJ)jhUh--CJOJQJU^JaJ$123<=?T̪ժ֪2FHW`aҿҮu]uE/jhUhWCJOJQJU^JaJ/jhUhWCJOJQJU^JaJ hUhWCJOJQJ^JaJ)jhUhWCJOJQJU^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ)jhUh--CJOJQJU^JaJ/jphUh--CJOJQJU^JaJѫӫܫ'()23PTǬȬɬӬǴǴǟvǴaP8a/jhUhHCJOJQJU^JaJ hUhHCJOJQJ^JaJ)jhUhHCJOJQJU^JaJ/jhUh--CJOJQJU^JaJ hUh--CJOJQJ^JaJ)jhUh--CJOJQJU^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ)jhUhWCJOJQJU^JaJ$hUh10JCJOJQJ^JaJӬԬ9=O\^p̭ЭGKko֯گ289ٷٓ~mU~B~ٓٓm~$hUh10JCJOJQJ^JaJ/jhUhWCJOJQJU^JaJ hUhWCJOJQJ^JaJ)jhUhWCJOJQJU^JaJ hUh/'CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJhUh1CJOJQJaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ)jhUhHCJOJQJU^JaJ9fghưǰɰʰΰ aeos¯¯uuuuufWhUhIGCJOJQJaJhUh1CJOJQJaJ hUh/'CJOJQJ^JaJ hUh1CJOJQJ^JaJ/j-hUhWCJOJQJU^JaJ$hUhW0JCJOJQJ^JaJ)jhUhWCJOJQJU^JaJ/jhUhWCJOJQJU^JaJ hUhWCJOJQJ^JaJo< _%9edq7~Egd* $edq7~EgdT6Bedq7~EgdY@edq7~EgdY4edq7~Egd3[2edq7~Egd3[2edq7~Egdc edq7~EgdIGedq7~Egdb2edq7~Egd/'+4;< !RS|}~ѴFɸnVC$hUh10JCJOJQJ^JaJ/jhUh]}CJOJQJU^JaJ hUh]}CJOJQJ^JaJ)jhUh]}CJOJQJU^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUhc CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ hUhIG0J+CJOJQJaJ#hUhIG0J15CJOJQJaJFMah !BK;BJbho÷ٷ8FNU;Kܶz$hUh10JCJOJQJ^JaJ/jKhUh CJOJQJU^JaJ hUh CJOJQJ^JaJ)jhUh CJOJQJU^JaJ hUhc CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ/ʺ˺_b&ab.޼ޫޫޘޫޘ޼ރrZG޼$hUhH-K0JCJOJQJ^JaJ/j—hUhH-KCJOJQJU^JaJ hUhH-KCJOJQJ^JaJ)jhUhH-KCJOJQJU^JaJ$hUh10J,CJOJQJ^JaJ hUhY/xCJOJQJ^JaJ hUhYCJOJQJ^JaJ hUh uCJOJQJ^JaJ hUh1CJOJQJ^JaJ hUh3[CJOJQJ^JaJ.:}ȾԾ#%(89ܼubQ>$hUhV0J6CJOJQJ^JaJ hUhVCJOJQJ^JaJ$hUhAp0J1CJOJQJ^JaJ hUhT6CJOJQJ^JaJ hUh\CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ#hUh10J15CJOJQJaJhUh1CJOJQJaJ hUhYCJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJڿRJKedq7~EgdVkdS$$Ifedq7~El40 ~&  t0644 lalf4itq7~EpytV K$IfgdVedq7~EgdApedq7~EgdT6  $%45>?@AMOPWYZ^_`aܺܖ˩sbsbO> hUhT CJOJQJ^JaJ$hUhT 0J,CJOJQJ^JaJ hUhHpCCJOJQJ^JaJ hUhHpCCJOJQJ^JaJ#hUhV5CJOJQJ^JaJ$hUhV0J1CJOJQJ^JaJ hUhT CJOJQJ^JaJ hUh CJOJQJ^JaJ hUhVCJOJQJ^JaJ hUhVCJOJQJ^JaJ$hUhV0J6CJOJQJ^JaJ#$kbY K$IfgdV K$IfgdT kd$$Ifedq7~El4n0 ~&  t0644 lalf4itq7~EpytV$%5?@kcZZ K$IfgdVKedq7~EgdT kd$$Ifedq7~El4n0 ~&  t0644 lalf4itq7~EpytV@ANOmdd K$IfgdVkd$$Ifedq7~El40 ~&  t0644 lalf4itq7~EpytT OPXYmdd K$IfgdVkdo$$Ifedq7~El40 ~&  t0644 lalf4itq7~EpytT YZ_`mdd K$IfgdVkd3$$Ifedq7~El40 ~&  t0644 lalf4itq7~EpytT `ahimdd K$IfgdVkd$$Ifedq7~El40 ~&  t0644 lalf4itq7~EpytT aghijky=>CDEFJKLMSTUVpq˺p]$hUhT 0J6CJOJQJ^JaJ$hUhT 0J6CJOJQJ^JaJ$hUhHpC0J1CJOJQJ^JaJ$hUhS\0J1CJOJQJ^JaJ hUh#nCJOJQJ^JaJ hUh\CJOJQJ^JaJ hUhT CJOJQJ^JaJ$hUhT 0J,CJOJQJ^JaJ hUhT CJOJQJ^JaJijk=me\ K$IfgdT Medq7~EgdT kd$$Ifedq7~El40 ~&  t0644 lalf4itq7~EpytT =>DEzz K$IfgdT |kd$$Ifedq7~El4~& t0644 lalf4itq7~Ep ytT EFKLkbb K$IfgdT kd/$$Ifedq7~El40 ~&  t0644 lalf4itq7~EpytT LMTUkbb K$IfgdT kd$$Ifedq7~El40 ~&  t0644 lalf4itq7~EpytT UVqkcZQQ K$IfgdT K$edq7~EgdT Kedq7~EgdT kd$$Ifedq7~El40 ~&  t0644 lalf4itq7~EpytT kcZZ K$IfgdT Kedq7~EgdT kd$$Ifedq7~El40 ~&  t0644 lalf4itq7~EpytT kbb K$IfgdT kdO$$Ifedq7~El4n0 ~&  t0644 lalf4itq7~EpytT #$-./0>?HIMNOPVWXYZ{=>CDEFJKLMSTUVp޺ިޕޕނޕޕޕq hUh\CJOJQJ^JaJ$hUh 0J,CJOJQJ^JaJ$hUhT 0J,CJOJQJ^JaJ#hUhT 5CJOJQJ^JaJ$hUhT 0J1CJOJQJ^JaJ hUhT CJOJQJ^JaJ hUhT CJOJQJ^JaJ hUh CJOJQJ^JaJ'$./kcZZ K$IfgdT Kedq7~EgdT kd$$Ifedq7~El4n0 ~&  t0644 lalf4itq7~EpytT /0=>mdd K$IfgdT kdߣ$$Ifedq7~El40 ~&  t0644 lalf4itq7~EpytT >?GHmdd K$IfgdT kd$$Ifedq7~El40 ~&  t0644 lalf4itq7~EpytT HINOmdd K$IfgdT kdg$$Ifedq7~El40 ~&  t0644 lalf4itq7~EpytT OPWXmdd K$IfgdT kd+$$Ifedq7~El40 ~&  t0644 lalf4itq7~EpytT XYZ=me\ K$IfgdT Medq7~EgdT kd$$Ifedq7~El40 ~&  t0644 lalf4itq7~EpytT =>DEzz K$IfgdT |kd$$Ifedq7~El4~& t0644 lalf4itq7~Ep ytT EFKLkbb K$IfgdT kdc$$Ifedq7~El40 ~&  t0644 lalf4itq7~EpytT LMTUkbb K$IfgdT kd+$$Ifedq7~El40 ~&  t0644 lalf4itq7~EpytT UVqykcZQQ K$Ifgd C K$edq7~Egd Kedq7~Egd kd$$Ifedq7~El40 ~&  t0644 lalf4itq7~EpytT pqxy)*WXghqrstɸnn\I$hUh 0J,CJOJQJ^JaJ#hUh 5CJOJQJ^JaJ$hUh 0J1CJOJQJ^JaJ hUh CJOJQJ^JaJ$hUh 0J6CJOJQJ^JaJ$hUh 0J6CJOJQJ^JaJ hUh CJOJQJ^JaJ$hUhS\0J1CJOJQJ^JaJ$hUh0J1CJOJQJ^JaJ hUh#nCJOJQJ^JaJkcZZ K$Ifgd CKedq7~Egd kd$$Ifedq7~El40 ~&  t0644 lalf4itq7~Epyt kbb K$Ifgd Ckd$$Ifedq7~El4n0 ~&  t0644 lalf4itq7~Epyt ()kcZZ K$Ifgd CMedq7~Egd kdK$$Ifedq7~El4n0 ~&  t0644 lalf4itq7~Epyt )*VWmdd K$Ifgd Ckd$$Ifedq7~El40 ~&  t0644 lalf4itq7~Epyt WXhrsmeYP K$Ifgd C K$$$Ifgd Kedq7~Egd kd׭$$Ifedq7~El40 ~&  t0644 lalf4itq7~Epyt stmaX K$Ifgd C K$$$Ifgd kd$$Ifedq7~El40 ~&  t0644 lalf4itq7~Epyt maX K$Ifgd C K$$$Ifgd kd_$$Ifedq7~El40 ~&  t0644 lalf4itq7~Epyt maX K$Ifgd C K$$$Ifgd kd#$$Ifedq7~El40 ~&  t0644 lalf4itq7~Epyt maX K$Ifgd C K$$$Ifgd kd$$Ifedq7~El40 ~&  t0644 lalf4itq7~Epyt ijopqrvwxy5U45Gbk︧zgg$hUh0J,CJOJQJ^JaJhAeCJOJQJ^JaJ hUhCJOJQJ^JaJh 8CJOJQJ^JaJ hUhCJOJQJ^JaJ$hUh 0J1CJOJQJ^JaJ$hUh 0J,CJOJQJ^JaJ hUh CJOJQJ^JaJ hUh CJOJQJ^JaJ(imeY K$$$Ifgd Medq7~Egd kd$$Ifedq7~El40 ~&  t0644 lalf4itq7~Epyt ijpqwn K$Ifgd C K$$$Ifgd |kdo$$Ifedq7~El4~& t0644 lalf4itq7~Ep yt qrwxk_V K$Ifgd C K$$$Ifgd kd$$Ifedq7~El40 ~&  t0644 lalf4itq7~Epyt xykbb K$Ifgd Ckd$$Ifedq7~El40 ~&  t0644 lalf4itq7~Epyt kcWN $Ifgd K$$$Ifgd Medq7~EgdT6kd$$Ifedq7~El40 ~&  t0644 lalf4itq7~Epyt k_V $Ifgd K$$$Ifgd kdw$$Ifedq7~El40 ~&  t0644 lalf4itq7~Epyt34k_V $Ifgd K$$$Ifgd kdE$$Ifedq7~El40 ~&  t0644 lalf4itq7~Epyt45jkk_V $Ifgd K$$$Ifgd kd$$Ifedq7~El40 ~&  t0644 lalf4itq7~Epytklk_V $Ifgd K$$$Ifgd kd$$Ifedq7~El40 ~&  t0644 lalf4itq7~EpytklRSbclͼr_NN;$hUhT60J1CJOJQJ^JaJ hUhT6CJOJQJ^JaJ$hUhT60J6CJOJQJ^JaJ$hUhT60J6CJOJQJ^JaJ hUhT6CJOJQJ^JaJ$hUh0J1CJOJQJ^JaJ$hUhOj0J1CJOJQJ^JaJ hUh#nCJOJQJ^JaJ hUh\CJOJQJ^JaJ hUhCJOJQJ^JaJ hUhCJOJQJ^JaJkbY $Ifgd K$Ifgd kd$$Ifedq7~El40 ~&  t0644 lalf4itq7~EpytkcZQQ K$IfgdT6 K$edq7~Egd CKedq7~EgdT6kd}$$Ifedq7~El40 ~&  t0644 lalf4itq7~EpytkcZZ K$IfgdT6Kedq7~EgdT6kdK$$Ifedq7~El40 ~&  t0644 lalf4itq7~EpytT6QRkbb K$IfgdT6kd$$Ifedq7~El4n0 ~&  t0644 lalf4itq7~EpytT6RScmnkcZZ K$IfgdT6Kedq7~EgdT6kdۻ$$Ifedq7~El4n0 ~&  t0644 lalf4itq7~EpytT6lmno}~uv{|}~ܸܸܸܸܸܸ˧p$hUhOj0J+CJOJQJ^JaJ$hUhQ:0J+CJOJQJ^JaJ hUh#nCJOJQJ^JaJ hUh\CJOJQJ^JaJ$hUhT60J,CJOJQJ^JaJ hUhT6CJOJQJ^JaJ hUhT6CJOJQJ^JaJ#hUhT65CJOJQJ^JaJ$no|}mdd K$IfgdT6kd$$Ifedq7~El40 ~&  t0644 lalf4itq7~EpytT6}~mdd K$IfgdT6kdg$$Ifedq7~El40 ~&  t0644 lalf4itq7~EpytT6mdd K$IfgdT6kd+$$Ifedq7~El40 ~&  t0644 lalf4itq7~EpytT6mdd K$IfgdT6kd$$Ifedq7~El40 ~&  t0644 lalf4itq7~EpytT6ume\ K$IfgdT6Medq7~EgdT6kd$$Ifedq7~El40 ~&  t0644 lalf4itq7~EpytT6uv|}zz K$IfgdT6|kdw$$Ifedq7~El4~& t0644 lalf4itq7~Ep ytT6}~kbb K$IfgdT6kd'$$Ifedq7~El40 ~&  t0644 lalf4itq7~EpytT6kbb K$IfgdT6kd$$Ifedq7~El40 ~&  t0644 lalf4itq7~EpytT6kcZcQQ K$IfgdT6 K$edq7~EgdT6Kedq7~EgdT6kd$$Ifedq7~El40 ~&  t0644 lalf4itq7~EpytT6?FGHIXYkl˸ܖܖܖ܃ܖr`rOrOr hUh-CJOJQJ^JaJ#hUhT6>*CJOJQJ^JaJ hUh-CJOJQJ^JaJ$hUhT60J6CJOJQJ^JaJ hUhT6CJOJQJ^JaJ hUhQ:CJOJQJ^JaJ$hUhQ:0J6CJOJQJ^JaJ hUhQ:CJOJQJ^JaJ hUhT6CJOJQJ^JaJ$hUhT60J+CJOJQJ^JaJkbb K$IfgdT6kd$$Ifedq7~El40 ~&  t0644 lalf4itq7~EpytT6kbb K$IfgdT6kdG$$Ifedq7~El40 ~&  t0644 lalf4itq7~EpytT6kbb K$IfgdT6kd$$Ifedq7~El40 ~&  t0644 lalf4itq7~EpytT6kbb K$IfgdT6kd$$Ifedq7~El40 ~&  t0644 lalf4itq7~EpytT6?GHkcZZ K$IfgdT6Kedq7~EgdT6kd$$Ifedq7~El40 ~&  t0644 lalf4itq7~EpytT6HIWXkbb K$IfgdT6kdg$$Ifedq7~El40 ~&  t0644 lalf4itq7~EpytT6XYjkkbb K$IfgdT6kd/$$Ifedq7~El40 ~&  t0644 lalf4itq7~EpytT6klkbY K$IfgdT6 K$Ifgd-kd$$Ifedq7~El40 ~&  t0644 lalf4itq7~EpytT6 +,-89=>Ios˸ܐxeR?ܐ$hUh-0J,CJOJQJ^JaJ$hUh-0J1CJOJQJ^JaJ$hUh-0JCJOJQJ^JaJ/jhUh-CJOJQJU^JaJ)jhUh-CJOJQJU^JaJ$hUhT60J+CJOJQJ^JaJ$hUh-0J+CJOJQJ^JaJ hUh-CJOJQJ^JaJ hUh-CJOJQJ^JaJ#hUh->*䴳ϴ<=kcZZ K$Ifgd-Kedq7~Egd-kd$$Ifedq7~El40 ~&  t0644 lalf4itq7~EpytT6=>kbb K$Ifgd-kd$$Ifedq7~El40 ~&  t0644 lalf4itq7~Epyt-ҿҮwfU@/ hUh CJOJQJ^JaJ)jhUh CJOJQJU^JaJ hUhB"CJOJQJ^JaJ hUhrCJOJQJ^JaJ$hUhOj0J+CJOJQJ^JaJ$hUh]1J0J+CJOJQJ^JaJ hUh-CJOJQJ^JaJ hUh-CJOJQJ^JaJ$hUh-0JCJOJQJ^JaJ)jhUh-CJOJQJU^JaJ/jhUh-CJOJQJU^JaJ :;kcZZ K$Ifgd-Kedq7~Egd-kdA$$Ifedq7~El40 ~&  t0644 lalf4itq7~Epyt- !*+,8:;<XZ[cijlmҿҮyhhUDh1$hUhD+0J,CJOJQJ^JaJ hUhD+CJOJQJ^JaJ$hUhB"0J,CJOJQJ^JaJ hUhrCJOJQJ^JaJ$hUhr0J6CJOJQJ^JaJ hUhrCJOJQJ^JaJ hUh-CJOJQJ^JaJ hUhB"CJOJQJ^JaJ$hUhB"0JCJOJQJ^JaJ)jhUh CJOJQJU^JaJ/jhUh CJOJQJU^JaJ;<YZmdd K$Ifgd-kd$$Ifedq7~El40 ~&  t0644 lalf4itq7~Epyt-Z[klmdd K$Ifgd-kdf$$Ifedq7~El40 ~&  t0644 lalf4itq7~Epyt-lmmdd K$Ifgd-kd*$$Ifedq7~El40 ~&  t0644 lalf4itq7~Epyt-˸n[H55$hUhIgg@CJOJQJ^JaJ$hUhIgg@CJOJQJ^JaJ$hUhIgg@CJOJQJ^JaJ$hUhIgg0J6CJOJQJ^JaJ$hUhIgg0J6CJOJQJ^JaJ$hUhIgg0J,CJOJQJ^JaJ hUhIggCJOJQJ^JaJ$hUh]1J0J+CJOJQJ^JaJ$hUh=a0J+CJOJQJ^JaJ hUhD+CJOJQJ^JaJ hUhD+CJOJQJ^JaJmd[[ K$Ifgdk K$edq7~Egd-kd$$Ifedq7~El40 ~&  t0644 lalf4itq7~Epyt-bnkcZZQ K$Ifgd- K$IfgdkKedq7~EgdIggkd$$Ifedq7~El40 ~&  t0644 lalf4itq7~EpytIgg?@AGHJKLTUܶxePe=*$hUhk@CJOJQJ^JaJ$hUhk@CJOJQJ^JaJ(hUhk0J@CJOJQJ^JaJ$hUhk0JCJOJQJ^JaJ/jhUhkCJOJQJU^JaJ hUhkCJOJQJ^JaJ)jhUhkCJOJQJU^JaJ$hUhIgg0J+CJOJQJ^JaJ$hUhIgg@CJOJQJ^JaJ hUhIggCJOJQJ^JaJ$hUhIgg@CJOJQJ^JaJUYZ]^efjkxyɶɶ}jW}ɶ$hUhk@CJOJQJ^JaJ$hUhk@CJOJQJ^JaJ$hUhk@CJOJQJ^JaJ$hUhk@CJOJQJ^JaJ$hUhk@CJOJQJ^JaJ$hUhk0J,CJOJQJ^JaJ$hUhk@CJOJQJ^JaJ$hUhk@CJOJQJ^JaJ hUhkCJOJQJ^JaJ!!"9ܶܶܣܕugRu?u$h}h_0JCJOJQJ^JaJ)jh}CJOJQJU^JaJh}CJOJQJ^JaJ#jh}CJOJQJU^JaJh_CJOJQJ^JaJhu CJOJQJ^JaJ$hUhk@CJOJQJ^JaJ$hUhk@CJOJQJ^JaJ$hUhk@CJOJQJ^JaJ hUhkCJOJQJ^JaJ$hUhk@CJOJQJ^JaJ9@xabeftuyz|}òyfSyf$hUhk@CJOJQJ^JaJ$hUhk@CJOJQJ^JaJ$hUhk@CJOJQJ^JaJ$hUhk0J,CJOJQJ^JaJ$hUhk@CJOJQJ^JaJ hUhkCJOJQJ^JaJ h_hkCJOJQJ^JaJhCJOJQJ^JaJh_CJOJQJ^JaJh_6CJOJQJ^JaJǶ펶vcNc;$hUhk@CJOJQJ^JaJ(hUhk0J@CJOJQJ^JaJ$hUhk0JCJOJQJ^JaJ/jhUhkCJOJQJU^JaJ)jhUhkCJOJQJU^JaJ$hUhk@CJOJQJ^JaJ hUhkCJOJQJ^JaJ$hUhk@CJOJQJ^JaJ$hUhk0J,CJOJQJ^JaJ$hUhk@CJOJQJ^JaJmnowxﵤ~~m\K hUh=aCJOJQJ^JaJ hUh3CJOJQJ^JaJ hUh=aCJOJQJ^JaJ$hUhk@CJOJQJ^JaJ$hUhk@CJOJQJ^JaJ hUhkCJOJQJ^JaJ'hUhk0J6>*CJOJQJ^JaJ$hUhk@CJOJQJ^JaJ$hUhk@CJOJQJ^JaJ hUhkCJOJQJ^JaJnozz K$Ifgd-|kd$$Ifedq7~El4~& t0644 lalf4itq7~Ep ytkmdd K$Ifgd-kd$$Ifedq7~El40 ~&  t0644 lalf4itq7~Epytkmdd K$Ifgd-kdy$$Ifedq7~El40 ~&  t0644 lalf4itq7~Epytk-.kccZQ K$Ifgdk K$Ifgd Kedq7~Egdkkd=$$Ifedq7~El40 ~&  t0644 lalf4itq7~Epytk ܶܣܐ}jjܐYH hUh CJOJQJ^JaJ hUhIggCJOJQJ^JaJ$hUhk@CJOJQJ^JaJ$hUhk@CJOJQJ^JaJ$hUhk@CJOJQJ^JaJ$hUhk@CJOJQJ^JaJ$hUhk@CJOJQJ^JaJ$hUhk@CJOJQJ^JaJ hUhkCJOJQJ^JaJ$hUhk0J,CJOJQJ^JaJ  )*./569:@AGHklmsǶǶǶ}ǶhPh=$hUh 0JCJOJQJ^JaJ/jhUh CJOJQJU^JaJ)jhUh CJOJQJU^JaJ$hUh @CJOJQJ^JaJ$hUh @CJOJQJ^JaJ$hUh @CJOJQJ^JaJ hUh CJOJQJ^JaJ$hUh @CJOJQJ^JaJ$hUh 0J,CJOJQJ^JaJ$hUh @CJOJQJ^JaJstvwxyðu\u@\)\,hUh 0J@CJOJQJRHa^JaJ7jhUh @CJOJQJRHaU^JaJ1jhUh @CJOJQJRHaU^JaJ(hUh @CJOJQJRHa^JaJ$hUh 0J,CJOJQJ^JaJ$hUh CJOJQJRHa^JaJ$hUh @CJOJQJ^JaJ)jhUh CJOJQJU^JaJ$hUh 0JCJOJQJ^JaJ(hUh 0J@CJOJQJ^JaJ ɶܣܐy_yJ7y$hUh 0JCJOJQJ^JaJ(hUh 0J@CJOJQJ^JaJ3jhUh @CJOJQJU^JaJ-jhUh @CJOJQJU^JaJ$hUh @CJOJQJ^JaJ$hUh @CJOJQJ^JaJ$hUh @CJOJQJ^JaJ$hUh 0J,CJOJQJ^JaJ hUh CJOJQJ^JaJ$hUh @CJOJQJ^JaJ ,./:;>LMw˺wdQdQd@/ hUh1CJOJQJ^JaJ hUhRLCJOJQJ^JaJ$hUh10J1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ#hUh10J15CJOJQJaJhUh1CJOJQJaJ hUh#nCJOJQJ^JaJ hUh\CJOJQJ^JaJ hUhIggCJOJQJ^JaJ hUhIggCJOJQJ^JaJ hUh CJOJQJ^JaJ$hUh @CJOJQJ^JaJ./;M!/kcZRJBedq7~Egdt=2edq7~EgdRLedq7~Egde $edq7~Egd#nKedq7~Egd-kd|$$Ifedq7~El40 ~&  t0644 lalf4itq7~EpytIgg!./>EGST_`˺˅wfUD2D#hUh10J15CJOJQJaJ hUh10J+CJOJQJaJ h&.h 80J+CJOJQJaJ hAh 80J+CJOJQJaJh 80J+CJOJQJaJ hUhr:CJOJQJ^JaJ hUht=CJOJQJ^JaJ$hUht=0JCJOJQJ^JaJ hUht=CJOJQJ^JaJ hUh\CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ/>QST`ZRJBedq7~Egd&.edq7~Egd%edq7~Egdr:kdD$$Ifedq7~El4S0 ~&  t0644 lalf4itq7~Epytt= K$IfgdHedq7~EgdRL~:ohU: $IfgdWf 2$edq7~Egdr:edq7~Egd("$edq7~Egdedq7~Egdedq7~Egd%  0o޺zgޥOlɸppp[H5$hUh*0J+CJOJQJ^JaJ$hUhWf0J+CJOJQJ^JaJ)hUh1B*CJOJQJ^JaJph$hUh10J1CJOJQJ^JaJ hUhCJOJQJ^JaJ hUh\CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUh("CJOJQJ^JaJ$hUh("0J+CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ:;l=4 $IfgdWfkd $$Ifedq7~El44\ >~& t044 lalf4itq7~Ep(ytWflmqrst}ttt $IfgdY| $$IfgdQ%xkd$$Ifedq7~El4~& t044 lalf4itq7~Ep ytWflmqrtuƵ|kV|kV|kV|kV|kVC$hUhWf0J+CJOJQJ^JaJ)hUh#xxB*CJOJQJ^JaJph hUh#xxCJOJQJ^JaJ$hUh#xx0J6CJOJQJ^JaJ hUh#xxCJOJQJ^JaJ)hUh1B*CJOJQJ^JaJph hUh1CJOJQJ^JaJ$hUh10J6CJOJQJ^JaJ hUh1CJOJQJ^JaJ)hUh*B*CJOJQJ^JaJphtu>5,, $Ifgd#xx $$IfgdQ%kd}$$Ifedq7~El4\ >~& t044 lalf4itq7~Ep(ytY|5, $$IfgdQ%kdB$$Ifedq7~El4\ >~& t044 lalf4itq7~Ep(ytY| $Ifgd#xx5, $$IfgdQ%kd$$Ifedq7~El4\ >~& t044 lalf4itq7~Ep(ytY| $Ifgd#xx5kd$$Ifedq7~El4\ >~& t044 lalf4itq7~Ep(ytY| $Ifgd#xx $Ifgd#xx $$IfgdQ%>5,, $Ifgd#xx $$IfgdQ%kd$$Ifedq7~El4\ >~& t044 lalf4itq7~Ep(ytY|5, $IfgdWfkdV$$Ifedq7~El4\ >~& t044 lalf4itq7~Ep(ytY| $Ifgd#xx}ttt $Ifgd#xx $$IfgdQ%xkd$$Ifedq7~El4~& t044 lalf4itq7~Ep ytWf "#JKMNYZ^bpƵƵƵƵƵ~m\I\$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUh("CJOJQJ^JaJ hUh*CJOJQJ^JaJ hUh\CJOJQJ^JaJ)hUh#xxB*CJOJQJ^JaJph hUh#xxCJOJQJ^JaJ$hUh#xx0J6CJOJQJ^JaJ hUh#xxCJOJQJ^JaJ)hUhWfB*CJOJQJ^JaJph>5,, $Ifgd#xx $$IfgdQ%kd$$Ifedq7~El4\ >~& t044 lalf4itq7~Ep(yt35, $$IfgdQ%kd{$$Ifedq7~El4\ >~& t044 lalf4itq7~Ep(yt3 $Ifgd#xx5, $$IfgdQ%kd@$$Ifedq7~El4\ >~& t044 lalf4itq7~Ep(yt3 $Ifgd#xx !"#5kd$$Ifedq7~El4\ >~& t044 lalf4itq7~Ep(yt3 $Ifgd#xx#JKLM $Ifgd#xx $IfgdY|MNZ2>6-%edq7~Egd^ 2$edq7~Egdr:edq7~Egd*kd$$Ifedq7~El4\ >~& t044 lalf4itq7~Ep(yt302<BCcq7Emp~)*˸ޔޔޔޔޔރr_J)hUh1B*CJOJQJ^JaJph$hUh10J1CJOJQJ^JaJ hUhr:CJOJQJ^JaJ hUh\CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh^CJOJQJ^JaJ$hUh^0J+CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUh2CJOJQJ^JaJ)*+B9 $IfgdAxmkd$$Ifedq7~El44F ~& t06    44 lalf4itq7~EpytAxm $Ifgd3edq7~Egdr:*+-./1235679:;=>?ABCEFGIJKMN[lpqǴ}j}U)hUhQCB*CJOJQJ^JaJph$hUhQC0J,CJOJQJ^JaJ hUhQCCJOJQJ^JaJ)hUhO$B*CJOJQJ^JaJph hUhO$CJOJQJ^JaJ$hUhO$0J6CJOJQJ^JaJ)hUhAxmB*CJOJQJ^JaJph hUhAxmCJOJQJ^JaJ$hUhAxm0J6CJOJQJ^JaJ+,-./01Lkd`$$Ifedq7~El4F ~& t06    44 lalf4itq7~EpytAxm $IfgdAxm12345ULLL $IfgdHkd&$$Ifedq7~El4F ~& t06    44 lalf4itq7~EpytAxm56789ULLL $IfgdHkd$$Ifedq7~El4F ~& t06    44 lalf4itq7~EpytAxm9:;<=ULLL $IfgdHkd$$Ifedq7~El4F ~& t06    44 lalf4itq7~EpytAxm=>?@AULLL $IfgdHkdx$$Ifedq7~El4F ~& t06    44 lalf4itq7~EpytAxmABCDEULLL $IfgdHkd>$$Ifedq7~El4F ~& t06    44 lalf4itq7~EpytAxmEFGHIULLL $IfgdHkd$$Ifedq7~El4F ~& t06    44 lalf4itq7~EpytAxmIJKLMULLL $IfgdAxmkd$$Ifedq7~El4F ~& t06    44 lalf4itq7~EpytAxmMNnopULCC $IfgdQC $Ifgd3kd$$Ifedq7~El4F ~& t06    44 lalf4itq7~EpytAxmpq} UMEEEE2edq7~Egd5hedq7~Egdr:kdV$$Ifedq7~El4F ~& t06    44 lalf4itq7~EpytQCq|}6: +9HU ͼͼkXͼͼ$hUh10JCJOJQJ^JaJ/jhUh2CJOJQJU^JaJ hUh2CJOJQJ^JaJ)jhUh2CJOJQJU^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUh5hCJOJQJ^JaJ hUhr:CJOJQJ^JaJ hUh\CJOJQJ^JaJ"#txǶNjwhUD hUhXyCJOJQJ^JaJ$hUh10J+CJOJQJ^JaJhUh1CJOJQJaJ'hUh10J6CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ/jhUhsCJOJQJU^JaJ hUhsCJOJQJ^JaJ)jhUhsCJOJQJU^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ#tBkd"$$Ifedq7~El4S0 ~&  t0644 lalf4itq7~Epytv> K$IfgdH2edq7~Egdv>2edq7~EgdXyedq7~EgdXyedq7~Egdb 5PQcdz޺縉vcP?v hUh!*CJOJQJ^JaJ$hUhH0J6CJOJQJ^JaJ$hUh0J6CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUhXyCJOJQJ^JaJ hUhtCJOJQJ^JaJ hUhv>CJOJQJ^JaJ$hUhv>0JCJOJQJ^JaJ hUhv>CJOJQJ^JaJ hUh\CJOJQJ^JaJ 5'Wedq7~EgdI9B2edq7~EgdM $$edq7~Egdr:edq7~Egd_@edq7~Egdb6;edq7~Egdb6;2edq7~Egdb6;edq7~Egdvz2edq7~Egdt$ ^edq7~Egdvz2edq7~EgdXy2edq7~Egdtz,?@[hp~&ǶNjxgV hUh\CJOJQJ^JaJ hUh!*CJOJQJ^JaJ$hUhH0J6CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ/jhUh}uCJOJQJU^JaJ hUh}uCJOJQJ^JaJ)jhUh}uCJOJQJU^JaJ hUh1CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ&'(CDEKL%DR_l¦֒n[n[n[n[n[n[nL=hUhb6;CJOJQJaJhUh1CJOJQJaJ$hUhb6;0J,CJOJQJ^JaJ hUhb6;CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ'hUh10J5CJOJQJ^JaJ6jahUhm0J+5CJOJQJU^JaJ'hUhm0J+5CJOJQJ^JaJ0jhUhm0J+5CJOJQJU^JaJ hUhtCJOJQJ^JaJ#+9U\%Gb)89UVWabว|mhUh1CJOJQJaJ$hUh10JCJOJQJ^JaJ/jhUh}uCJOJQJU^JaJ hUh}uCJOJQJ^JaJ)jhUh}uCJOJQJU^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJhUh1CJOJQJaJ&9:W[}~HV{~ɸzgS@@@@$hUh10J,CJOJQJ^JaJ'hUh10J6CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ/jMhUhsCJOJQJU^JaJ hUhsCJOJQJ^JaJ)jhUhsCJOJQJU^JaJ hUh1CJOJQJ^JaJ hUhMCJOJQJ^JaJ$hUhI9B0J+CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ YZ{ӷn[n[nF5 hUhsCJOJQJ^JaJ)jhUhsCJOJQJU^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUhACJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ'hUh10J5CJOJQJ^JaJ6jhUhs0J+5CJOJQJU^JaJ'hUhs0J+5CJOJQJ^JaJ0jhUhs0J+5CJOJQJU^JaJ{|}>LY`%,ҿҮudLuu/jhUhNsCJOJQJU^JaJ hUhNsCJOJQJ^JaJ)jhUhNsCJOJQJU^JaJ hUhACJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ)jhUhsCJOJQJU^JaJ/jChUhsCJOJQJU^JaJ * $Ifgd : $edq7~Egdr:edq7~EgdAedq7~EgdA2edq7~EgdA ,q9:cde7>;縉mY'hUh10J6CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ/j=hUh=CJOJQJU^JaJ hUh=CJOJQJ^JaJ)jhUh=CJOJQJU^JaJhUhACJOJQJaJhUh1CJOJQJaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ *+TUfgyz˸p_p_p_p_p_p_p_PhUh1CJOJQJaJ hUh CJOJQJ^JaJ hUh CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUhk~.0J+CJOJQJ^JaJ$hUh10J1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ$hUh :0J+CJOJQJ^JaJ hUhI>CJOJQJ^JaJ hUh\CJOJQJ^JaJ*+HKLT=4444 $Ifgd :kd$$Ifedq7~El4\ >~& t0644 lalf4itq7~Ep(yt :TUVZ[f=4444 $Ifgd :kd$$Ifedq7~El4\ >~&` t0644 lalf4itq7~Ep(yt :fghlmy=4444 $Ifgd :kdW$$Ifedq7~El4\ >~&  t0644 lalf4itq7~Ep(yt :yz{=4444 $Ifgd :kd$$Ifedq7~El4\ >~&  t0644 lalf4itq7~Ep(yt :=4444 $Ifgd :kd$$Ifedq7~El4\ >~&  t0644 lalf4itq7~Ep(yt :=4444 $Ifgd :kd$$Ifedq7~El4\ >~&  t0644 lalf4itq7~Ep(yt :=4444 $Ifgd :kds$$Ifedq7~El4\ >~&  t0644 lalf4itq7~Ep(yt :I=5,$edq7~Egdh $edq7~EgdI>edq7~EgdI>kd:$$Ifedq7~El4\ >~&  t0644 lalf4itq7~Ep(yt :,GIMQXe7R_`bmq˸˧rarP hUh?CJOJQJ^JaJ hUhI#CJOJQJ^JaJ hUh>CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUhhCJOJQJ^JaJ$hUh10J1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJhUh1CJOJQJaJ#hUh10J15CJOJQJaJI_uW K$Ifgd&Kedq7~Egd|Q $edq7~EgdI>2edq7~Egdggedq7~Egdggedq7~Egdggedq7~Egd?edq7~Egd?2edq7~Egd?@edq7~Egd>2edq7~EgdhLP'MZl#1We޺ީީީޚra hUhNsCJOJQJ^JaJ)jhUhNsCJOJQJU^JaJ$hUh?0J,CJOJQJ^JaJhUh?CJOJQJaJ hUhI#CJOJQJ^JaJ hUh?CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUhzpCJOJQJ^JaJ" U\esuy}ҿҮzgzgzVE2E$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUhggCJOJQJ^JaJ$hUh10J1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ#hUh10J15CJOJQJaJhUh1CJOJQJaJ hUh?CJOJQJ^JaJ$hUh?0JCJOJQJ^JaJ)jhUhNsCJOJQJU^JaJ/jhUhNsCJOJQJU^JaJW[z~ܺq^qMqM hUh2gCJOJQJ^JaJ$hUh2g0J,CJOJQJ^JaJ hUh2gCJOJQJ^JaJ'hUh10J+6CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ hUhI>CJOJQJ^JaJ hUh\CJOJQJ^JaJ hUhggCJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ| K$Ifgd&zkdx$$Ifedq7~El4~& t0644 lalf4itq7~Ep yt2gJpZ {rjbbbjZ2edq7~EgdM2edq7~Egdaedq7~Egda $edq7~Egd4eQedq7~Egd4eQ|kd$$$Ifedq7~El4(~& t0644 lalf4itq7~Ep yt2g JO<=>ͼt\It1/jWhUhkVCJOJQJU^JaJ$hUh10JCJOJQJ^JaJ/jhUhkVCJOJQJU^JaJ hUhkVCJOJQJ^JaJ)jhUhkVCJOJQJU^JaJ hUhWT,CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUhaCJOJQJ^JaJ$hUh10J+CJOJQJ^JaJhUh1CJOJQJaJ hUh4eQCJOJQJ^JaJ>)*ضǍdzضbDz< hUh==CJOJQJ^JaJ)jhUh==CJOJQJU^JaJ/jhUhkVCJOJQJU^JaJ$hUh10J,CJOJQJ^JaJ hUhaCJOJQJ^JaJ/jhUhkVCJOJQJU^JaJ hUhkVCJOJQJ^JaJ hUh1CJOJQJ^JaJ)jhUhkVCJOJQJU^JaJ$hUh10JCJOJQJ^JaJxyz%&STUmnp{ҿҮyaҿҮN;$hUha0J+CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ/jhUh==CJOJQJU^JaJ hUh==CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUhaCJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ)jhUh==CJOJQJU^JaJ/j$hUh==CJOJQJU^JaJ  "#Z_ ޶ziXG hUh4eQCJOJQJ^JaJ hUh\CJOJQJ^JaJ hUhMCJOJQJ^JaJ$hUh10JCJOJQJ^JaJ/jJhUh==CJOJQJU^JaJ hUh==CJOJQJ^JaJ)jhUh==CJOJQJU^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUhaCJOJQJ^JaJ 'nSzkdf$$Ifedq7~El4~& t0644 lalf4itq7~Ep yt& K$IfgdKL|edq7~EgdOYedq7~Egd4eQedq7~EgdMedq7~Egd4eQ $edq7~Egd4eQ 'nͼkXE4 hUh&CJOJQJ^JaJ$hUh&0J,CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ/jhUh==CJOJQJU^JaJ hUh==CJOJQJ^JaJ)jhUh==CJOJQJU^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUh10J+CJOJQJaJ$hUh10J+CJOJQJ^JaJhUh1CJOJQJaJ     8 C D F G Z [ b c o p  ͼީ͔r]rr]rr]ͼͼͼ)hUh1B*CJOJQJ^JaJph hUhktCJOJQJ^JaJ hUh1CJOJQJ^JaJ)hUhKL|B*CJOJQJ^JaJph$hUhKL|0J,CJOJQJ^JaJ hUhKL|CJOJQJ^JaJ hUhKL|CJOJQJ^JaJ hUh&CJOJQJ^JaJ hUh&CJOJQJ^JaJ$mdW  $Ifgd& $Ifgd&kd$$Ifedq7~El40 ~& t0644 lalf4itq7~Epyt&kbb K$IfgdKL|kd$$Ifedq7~El4S0 ~& t0644 lalf4itq7~EpytKL|mdW  $Ifgd& $Ifgd&kdt$$Ifedq7~El40 ~& t0644 lalf4itq7~Epyt&kbb K$IfgdKL|kd*$$Ifedq7~El4S0 ~& t0644 lalf4itq7~EpytKL|me\ K$IfgdKL|Medq7~EgdKL|kd$$Ifedq7~El40 ~& t0644 lalf4itq7~EpytKL||| K$IfgdKL|zkd$$Ifedq7~El4~& t0644 lalf4itq7~Ep ytKL|  mdd K$IfgdKL|kd8$$Ifedq7~El40 ~& t0644 lalf4itq7~Epyt4eQ  E F mdd K$IfgdKL|kd$$Ifedq7~El40 ~& t0644 lalf4itq7~Epyt4eQF G H Z me\ K$IfgdOMedq7~EgdKL|kd$$Ifedq7~El40 ~& t0644 lalf4itq7~Epyt4eQZ [ a b || K$IfgdOzkdZ$$Ifedq7~El4~& t0644 lalf4itq7~Ep ytKL|b c n o mdd K$IfgdOkd$$Ifedq7~El40 ~& t0644 lalf4itq7~EpytKL|o p   mdd K$IfgdOkd$$Ifedq7~El40 ~& t0644 lalf4itq7~EpytKL|    mdd K$IfgdOkdd $$Ifedq7~El40 ~& t0644 lalf4itq7~EpytKL|           V ] |     ͼxexexexP? hUh]CJOJQJ^JaJ)jhUh]CJOJQJU^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUhOYCJOJQJ^JaJ$hUh10J+CJOJQJ^JaJhUh1CJOJQJaJ hUhktCJOJQJ^JaJ hUh\CJOJQJ^JaJ hUhKL|CJOJQJ^JaJ hUhKL|CJOJQJ^JaJ     3   me\TLLDedq7~Egdt2edq7~EgdOYedq7~EgdOY $edq7~Egdktedq7~Egdktkd $$Ifedq7~El40 ~& t0644 lalf4itq7~EpytKL|           3 8 < C ` p       ҿҮwfUB$hUh10J+CJOJQJ^JaJ hUhtCJOJQJ^JaJ hUh\CJOJQJ^JaJ hUhOYCJOJQJ^JaJ$hUh]0J,CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ)jhUh]CJOJQJU^JaJ/j hUh]CJOJQJU^JaJ    G H K L O P S T W X [ \ _ ` c d g h k l o p { ڲ{jUjUjUjUjUjUjUjUD hUh\CJOJQJ^JaJ)hUhxCB*CJOJQJ^JaJph hUhxCCJOJQJ^JaJ)hUhktB*CJOJQJ^JaJph hUhktCJOJQJ^JaJ hUh1CJOJQJ^JaJ)hUh1B*CJOJQJ^JaJph$hUh u0J+CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ$hUh10J1CJOJQJ^JaJ  ; G H I J K JAAA $IfgdktkdQ $$Ifedq7~El44F ~& t06    44 lalf4itq7~Epytkt $Ifgdr:K L M N O SJJJ $Ifgdktkd $$Ifedq7~El4F ~& t06    44 lalf4itq7~EpytLRY ＫhUh1CJOJQJaJ$hUhd,0J,CJOJQJ^JaJ hUhd,CJOJQJ^JaJhUhd,CJOJQJaJ hUhr&CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ6  VZjopsz{|˸˧p_pJ9 hUhCJOJQJ^JaJ)jhUhCJOJQJU^JaJ hUhI#CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10J3CJOJQJ^JaJ hUhDCJOJQJ^JaJ$hUh10J1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJhUh1CJOJQJaJ#hUh10J15CJOJQJaJj|=   !"H"""###,$$&%%&&edq7~Egdbedq7~EgdFZ@edq7~EgdpO $edq7~Egdy-edq7~Egd6edq7~Egd62edq7~Egd6Bedq7~Egdy/>@edq7~EgdI#2edq7~EgdD    = @ M T z ~          !4!5!R!ҿҮyyhW hUhCJOJQJ^JaJ hUh6CJOJQJ^JaJ hUhy/>CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUhI#CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ)jhUhCJOJQJU^JaJ/j hUhCJOJQJU^JaJR!S!T!b!c!i!p!!!!!!!""-"8"H"K"M"Q"X"j"n""""ҿҮzgTgCC hUh6CJOJQJ^JaJ$hUh10J1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ#hUh10J15CJOJQJaJhUh1CJOJQJaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ)jhUhCJOJQJU^JaJ/jhUhCJOJQJU^JaJ""""""""""####?#@#A#J#K#Q#\#d#e#v###########ܶziX hUhbCJOJQJ^JaJ hUh\CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ/jhUhECJOJQJU^JaJ hUhECJOJQJ^JaJ)jhUhECJOJQJU^JaJ hUh6CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ!##$$ $$,$/$B$C$$$$$$$&%1%7%8%<%C%e%h%%&˺˺ܖp_N hUh\CJOJQJ^JaJ hUhFZCJOJQJ^JaJ$hUhFZ0J+CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ hUhOCJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUhNICJOJQJ^JaJ$hUhO0J6CJOJQJ^JaJ hUhgB:CJOJQJ^JaJ&&&&&&6&=&&&&&&&&&&&&&&ͼ͔ͩkXͩG6 hUh+CJOJQJ^JaJ hUh+CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ/jhUhECJOJQJU^JaJ hUhECJOJQJ^JaJ)jhUhECJOJQJU^JaJ$hUh10J,CJOJQJ^JaJ hUhFZCJOJQJ^JaJ hUh1CJOJQJ^JaJ hUh\CJOJQJ^JaJ hUhbCJOJQJ^JaJ&&&&&+'''((rjaYjQ2edq7~EgdtPedq7~EgdtP $edq7~Egdy-edq7~Egdy-|kd$$Ifedq7~El4 ~& t0644 lalf4itq7~Ep yt+ $Ifgd\2edq7~EgdFZ &&'*'+''''''''''''''(,(`(g(~(((((໨q`M`M`M`M`M`$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUhtPCJOJQJ^JaJ hUh\CJOJQJ^JaJ)hUh1B*CJOJQJ^JaJph$hUh10J1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ#hUh10J15CJOJQJaJhUh1CJOJQJaJ hUhy-CJOJQJ^JaJ((((((((;)?))) **~**6+D++++++++˸raRBRhUh16CJOJQJaJhUh1CJOJQJaJ hUhy-CJOJQJ^JaJ hUh\CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUhtPCJOJQJ^JaJ$hUhtP0J+CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ hUhDCJOJQJ^JaJ hUhDCJOJQJ^JaJ((+++,,S-T-{sjbsZQ $Ifgd\2edq7~Egdedq7~Egd $edq7~Egdy-edq7~Egdy-edq7~EgdtP|kd$$Ifedq7~El4 ~& t0644 lalf4itq7~Ep ytD+++,,,,,,*,9,B,w,{,,,,,C-Q-S-T-U-`-ڵoooooo^M hUh\CJOJQJ^JaJ hUh\CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUhCJOJQJ^JaJ hUhy-CJOJQJ^JaJ hUh\CJOJQJ^JaJ'hUh10J+6CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ$hUh10J1CJOJQJ^JaJT-U-V.b.{...//{sj{bZRedq7~Egd:@edq7~Egd2edq7~Egd $edq7~Egd:edq7~Egdy-edq7~Egd|kd]$$Ifedq7~El4 ~& t0644 lalf4itq7~Ep yt\`-f-g-k-y---V.a.b.f.o.{...........//˸˸˧wdQd˸@˸˧ hUhCJOJQJ^JaJ$hUh10J1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJhUh16CJOJQJaJhUh1CJOJQJaJ hUhy-CJOJQJ^JaJ hUh\CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUhCJOJQJ^JaJ$hUh0J+CJOJQJ^JaJ////////0000000000000111111111'222324262d2v2w2x2z2~22222ͼvͼͼͼͼ hUh\CJOJQJ^JaJ hUh\CJOJQJ^JaJ hUh\CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUhgB:CJOJQJ^JaJ hUhCJOJQJ^JaJ hUh:CJOJQJ^JaJ,/f00000132w23f^edq7~Egd:|kd$$Ifedq7~El4 ~& t0644 lalf4itq7~Ep yt\ $Ifgd\ ^edq7~Egd:@edq7~EgdgB: 2233333333333C4P4Q4V4Z4a4~4444445ꝌyyhWyyyy hUh7CJOJQJ^JaJ hUh\CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh[CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ/jhUhECJOJQJU^JaJ hUhECJOJQJ^JaJ)jhUhECJOJQJU^JaJ3C4Q45$6%6&6czkd"$$Ifedq7~El4~& t0644 lalf4itq7~Ep yt\ $Ifgd\2edq7~Egd7 $edq7~Egd72edq7~Egd[55556575B5C5d5r5555555555555$6%6&6ꝊraNa=a hUh\CJOJQJ^JaJ$hUh\0J,CJOJQJ^JaJ hUh\CJOJQJ^JaJ/jhUh68CJOJQJU^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ/j&hUh68CJOJQJU^JaJ hUh68CJOJQJ^JaJ)jhUh68CJOJQJU^JaJ&6'636D6B7989;;<}ummmmd\2edq7~Egd[ $edq7~Egd&xedq7~Egd[edq7~Egd[edq7~EgdS%zkd$$Ifedq7~El4~& t0644 lalf4itq7~Ep yt\ &6'62636>6C6D6H6V666s77770878=8K8e8s88888889%909>9k9x99999::":;;zg$hUh10JCJOJQJ^JaJ hUh uCJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJhUh[CJOJQJaJhUh1CJOJQJaJ hUhS%CJOJQJ^JaJ hUh\CJOJQJ^JaJ hUh\CJOJQJ^JaJ(;!;;;;;<<o<}<<<<<<<======.>/>0>;><>{>>˺ܘ܇v܇v˺gT$hUh10J+CJOJQJ^JaJhUh1CJOJQJaJ hUh\CJOJQJ^JaJ hUh\CJOJQJ^JaJ hUh",CJOJQJ^JaJ hUh[CJOJQJ^JaJ hUh&xCJOJQJ^JaJ hUh\CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ<===.>/>r|kd^$$Ifedq7~El4 ~& t0644 lalf4itq7~Ep yt\ $Ifgd\@edq7~Egd",/>0><>{>>X??>@@{rjbZOO 2 & Fedq7~Egdu*W2edq7~EgdA2edq7~Egdu edq7~Egd[ $edq7~EgdYzedq7~Egd&x|kd$$Ifedq7~El4 ~& t0644 lalf4itq7~Ep yt\>>?*?0?7?I?V?W?X?]?d?k?o????????? @޽vgVEV hI?h {CJOJQJ^JaJ hI?hCJOJQJ^JaJh {6CJOJQJ^JaJh/CJOJQJ^JaJh {CJOJQJ^JaJh]6CJOJQJ^JaJh]CJOJQJ^JaJhACJOJQJ^JaJhu CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUhMzCJOJQJ^JaJ @@@@%@8@=@>䰪°尪ڰ԰@@@@@@@ͻ͜ދyދyͳ<h}hwCY0J5aJ&jh}hV*L0J+5UaJh}hV*L0J+5aJ jh}hV*L0J+5UaJ#h*h2;6CJOJQJ^JaJ hI?hwCYCJOJQJ^JaJ hI?h {CJOJQJ^JaJhI?CJOJQJ^JaJ#h*h6CJOJQJ^JaJ hI?hCJOJQJ^JaJ hI?h2;CJOJQJ^JaJ hI?hI?CJOJQJ^JaJ@@9A@AIAPAAAAAAAAAAAB BB'BmBzBBB亩n`nOMhI?6CJOJQJ^JaJhI?CJOJQJ^JaJ h}hV*LCJOJQJ^JaJhACJOJQJ^JaJ hUhMzCJOJQJ^JaJ$hUh10JCJOJQJ^JaJ/j hUh!/CJOJQJU^JaJ hUh!/CJOJQJ^JaJ)jhUh!/CJOJQJU^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJGDUD\D]DzD{D|DDDDDDDDDDDDDDE E­КЌ}o`oK8$hV*Lh: e0JCJOJQJ^JaJ)j!hV*LCJOJQJU^JaJh: e6CJOJQJ^JaJh: eCJOJQJ^JaJh.f6CJOJQJ^JaJh.fCJOJQJ^JaJ$hV*LhI?0JCJOJQJ^JaJ)j hV*LCJOJQJU^JaJhV*LCJOJQJ^JaJ#jhV*LCJOJQJU^JaJhI?CJOJQJ^JaJhI?6CJOJQJ^JaJ E E EEE=EDEEEEEEFFFGG&G/GbGoG}G~Gο߱n[n[n[n[nB0jhUh\0J+5CJOJQJU^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ#hI?hI?6CJOJQJ^JaJ hI?hI?CJOJQJ^JaJh.f6CJOJQJ^JaJh.fCJOJQJ^JaJh: e6CJOJQJ^JaJ h: eh: eCJOJQJ^JaJh: eCJOJQJ^JaJ#jhV*LCJOJQJU^JaJ~GGGGGGGGGGGGNDNRNfNmNNNNOO(O+O>OOOO˸˸˸˸˸˸˸˸˸˸˸˸˸˸˸˸˩$hUh10J1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJhUh1CJOJQJaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ,+O>OOPQRSS UVWWXUXhYYYZp[t\]3]]edq7~Egd>7edq7~Egd>72edq7~Egd&4@edq7~EgdB2edq7~EgdMzedq7~EgdMzedq7~EgdMzOOOOP#P@PRPbPpPPPPPP QQ"QKQXQQQQQQRR%R+R9RKRRRpRvRRRRRRRR޲n'hUh10J5CJOJQJ^JaJ6jv"hUh\0J+5CJOJQJU^JaJ'hUh\0J+5CJOJQJ^JaJ0jhUh\0J+5CJOJQJU^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUhMzCJOJQJ^JaJ(RSSS S.S5SCSPSXSjStSzSSSSTT!T'T5T@TGTXT^TTTTT UUFUMUaUoUUUUUUUVVV˸˸˸˸˸˸˸˸˸˸˸˸˸˸˸˸ˣz/j"hUhzCJOJQJU^JaJ hUhzCJOJQJ^JaJ)jhUhzCJOJQJU^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUhMzCJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ+VVV7VDVLVSVlVzVVVVVVVVVWWWWW;WBWWWǴǴǴǟǎǴyhPyyǴǴ/jd#hUhv7=CJOJQJU^JaJ hUhv7=CJOJQJ^JaJ)jhUhv7=CJOJQJU^JaJ hUhMzCJOJQJ^JaJ)hUh1B* CJOJQJ^JaJphG$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ)jhUhzCJOJQJU^JaJ$hUh10JCJOJQJ^JaJWWWWWWW XXXX/X6XFXSXYXZXXXXXXXXXXXXYY:Yͺͺͺͺ͔ͩkXͺͺͺ$hUh10JCJOJQJ^JaJ/j#hUhzCJOJQJU^JaJ hUhzCJOJQJ^JaJ)jhUhzCJOJQJU^JaJ hUhMzCJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUhBCJOJQJ^JaJ hUhYzCJOJQJ^JaJ:Y;YXYYYZYeYfYhY~YYYYYYYZZ6ZCZZꝎ|iViE22$hUh10J,CJOJQJ^JaJ hUhMzCJOJQJ^JaJ$hUh10J1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ#hUh10J15CJOJQJaJhUh1CJOJQJaJ hUh1CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ/jV$hUhv7=CJOJQJU^JaJ hUhv7=CJOJQJ^JaJ)jhUhv7=CJOJQJU^JaJZZZZZZZZ[Q[U[p[s[[[\\:\A\J\X\t\w\{\\\\]%]2]3]]]]˺ܩܩܚubu$hUh10J1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ#hUh10J15CJOJQJaJhUh1CJOJQJaJ hUhBCJOJQJ^JaJ hUhMzCJOJQJ^JaJ hUh&4CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ!]]]]]]]]^^!^/^b^o^q^v^^^^^^^^^^ __\_i_q_z_____ ``3`<`y`}```aa!a&a*a1a޶z$hUh10JCJOJQJ^JaJ/j$hUhB.CJOJQJU^JaJ hUhB.CJOJQJ^JaJ)jhUhB.CJOJQJU^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUh>7CJOJQJ^JaJ0]q^_!aabccd;eQeekff^gghidjMll no)pedq7~EgdY2edq7~EgdY@edq7~EgdBedq7~Egd>7edq7~Egd>7edq7~Egd>72edq7~Egd>71aBaPaqaaaaaaaaab'b5bgbkbbbbbbbbbbbbbb6c7cTcﶥzeT hUhWCJOJQJ^JaJ)jhUhWCJOJQJU^JaJ$hUh10JCJOJQJ^JaJ/jJ%hUhB.CJOJQJU^JaJ hUhB.CJOJQJ^JaJ)jhUhB.CJOJQJU^JaJ hUh>7CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ TcUcVcacbcpcwccccccccccc-d4dIdWdydddddddee,e9e;e?eҿҮ}l]hUh1CJOJQJaJ hUhk{CJOJQJ^JaJhUh>7CJOJQJaJhUh1CJOJQJaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ)jhUhWCJOJQJU^JaJ/j%hUhWCJOJQJU^JaJ!?ePeQeeeeeeeee$f+fDfVf^fifkfnfffffff˸˧raLa)jhUhB.CJOJQJU^JaJ hUhB.CJOJQJ^JaJ hUhBCJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUh>7CJOJQJ^JaJ$hUh10J1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJhUh1CJOJQJaJ#hUh10J15CJOJQJaJfffffffg1g>gVg]g^gagggggggg hh*h.hphwhhhhhhii'i7i8iҿқwwwwwwwwwwwb)jhUhDCJOJQJU^JaJ$hUh10J,CJOJQJ^JaJ hUhBCJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ$hUhB.0JCJOJQJ^JaJ)jhUhB.CJOJQJU^JaJ/j<&hUhB.CJOJQJU^JaJ$8iUiViWibiciiiiiiiijjj!j(j/j0jVjWjXjajbjdjijjjjjj¯žzb¯žQ hUhYCJOJQJ^JaJ/j.'hUhDCJOJQJU^JaJ hUhBCJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ)jhUhDCJOJQJU^JaJ/j&hUhDCJOJQJU^JaJ hUhDCJOJQJ^JaJjjk kk&kkkkklll&lMlNliljlklqlrlllllll>mBm|mmmm nn+nïl[[ hUhYCJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ'hUh10J5CJOJQJ^JaJ6j'hUh\0J+5CJOJQJU^JaJ'hUh\0J+5CJOJQJ^JaJ0jhUh\0J+5CJOJQJU^JaJ hUh1CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ#+n9nrnvn|nnnnnn=oKocoqooooo)p,pbp{p|pppppܺܩkX$hUhD0JCJOJQJ^JaJ/j.(hUh@q@CJOJQJU^JaJ hUh@q@CJOJQJ^JaJ)jhUh@q@CJOJQJU^JaJ hUhDCJOJQJ^JaJ hUhDKCJOJQJ^JaJ hUhYCJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJppppppppppppppppqqq+q.qJqUqVqYqqqqض؋ضs؋bObض$hUh10J,CJOJQJ^JaJ hUhDKCJOJQJ^JaJ/j )hUh@q@CJOJQJU^JaJ$hUhD0JCJOJQJ^JaJ/j(hUh@q@CJOJQJU^JaJ hUh@q@CJOJQJ^JaJ hUh1CJOJQJ^JaJ)jhUh@q@CJOJQJU^JaJ$hUh10JCJOJQJ^JaJ)p+qVqqSrorrstuvwwcwJxxyvzl{I|#}R~~r edq7~Egdedq7~EgdEoedq7~EgdEo2edq7~EgdEo@edq7~EgdDKqqqqqqqqqqqqqrr$r1rSrVrorrrrrrrrrrrrrsҿҮyhhW hUh@q@CJOJQJ^JaJ hUhDKCJOJQJ^JaJ hUhDCJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUhEoCJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ)jhUh@q@CJOJQJU^JaJ/j)hUh@q@CJOJQJU^JaJssssss#sPs^sysssssssst&t4tEtKtYthtotttttttuuu/u4uBuluwuuuuuuuuuvvAvJvSvdvnv|vҿҮ hUhEoCJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ)jhUh@q@CJOJQJU^JaJ/j*hUh@q@CJOJQJU^JaJ6|vvvvvvvvww wwwcwhwlwsw|wwwwwwwwwwxxxＪqY/j*hUh/.CJOJQJU^JaJ hUh/.CJOJQJ^JaJ)jhUh/.CJOJQJU^JaJ$hUh10J+CJOJQJ^JaJ#hUh10J15CJOJQJaJhUh1CJOJQJaJ$hUh10J,CJOJQJ^JaJ hUhEoCJOJQJ^JaJ hUh1CJOJQJ^JaJx1x4x5xJxKxfxgxhxnxoxxxxijjVC0C$hUh10J1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ'hUh10J5CJOJQJ^JaJ6j +hUh0J+5CJOJQJU^JaJ'hUh0J+5CJOJQJ^JaJ0jhUh0J+5CJOJQJU^JaJ hUh1CJOJQJ^JaJ)jhUh/.CJOJQJU^JaJ'hUh10J6CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ xxxxxxyyy6y7y8yRyUyVyWyiy}yyyyyyyy޺zfS@$hUhEo0J+CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ'hUh/.0J6CJOJQJ^JaJ$hUh/.0JCJOJQJ^JaJ/j+hUh/.CJOJQJU^JaJ)jhUh/.CJOJQJU^JaJ hUh/.CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUhEoCJOJQJ^JaJyy zz1z2z3zTzUzVzpzsztzvz{zzzzzzzzzN{j{l{w{˶˞wfS$hUh10J+CJOJQJ^JaJ hUhEoCJOJQJ^JaJ'hUh/.0J6CJOJQJ^JaJ$hUh/.0JCJOJQJ^JaJ/j,hUh/.CJOJQJU^JaJ)jhUh/.CJOJQJU^JaJ hUh/.CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJw{}{~{{{{{{{{{{{{>|G|I|N|s|z|||||||#}ǶNjwfSfSfSffSfSfSfSf$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ'hUh60J6CJOJQJ^JaJ$hUh60JCJOJQJ^JaJ/j,hUh6CJOJQJU^JaJ hUh6CJOJQJ^JaJ)jhUh6CJOJQJU^JaJ hUhEoCJOJQJ^JaJ$hUhEo0J+CJOJQJ^JaJ#}.}4}5}D}M}U}c}x}}}}}}~~R~W~[~i~~~~~~~~~~~Y]ruy  $ɸɸn$hUh10J1CJOJQJ^JaJ hUhoCJOJQJ^JaJ$hUh10J3CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUhEoCJOJQJ^JaJ$hUhEo0J+CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ($%BCDJK <ӷn[n[n[n[nF5 hUh6CJOJQJ^JaJ)jhUh6CJOJQJU^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUhCJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ'hUh10J5CJOJQJ^JaJ6j-hUh\0J+5CJOJQJU^JaJ'hUh\0J+5CJOJQJ^JaJ0jhUh\0J+5CJOJQJU^JaJ<=>PQg{} '6GNVҿҮzgTgC hUhCJOJQJ^JaJ$hUh10J1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ#hUh10J15CJOJQJaJhUh1CJOJQJaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ)jhUh6CJOJQJU^JaJ/j}-hUh6CJOJQJU^JaJ}g B *bqʍΎledq7~EgdK($edq7~EgdK($2edq7~EgdK($2edq7~EgdTedq7~EgdT@edq7~Egdoedq7~Egdedq7~Egd2edq7~EgdVWXegluà 8Gջ觔p_pppNppNpp hUhoCJOJQJ^JaJ hUhCJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ'hUh10J6CJOJQJ^JaJ3j-hUhN}0J,CJOJQJU^JaJ$hUhN}0J,CJOJQJ^JaJ-jhUhN}0J,CJOJQJU^JaJBGKRao҅ %3HXs͆ۆJSgu޺ޡ'hUh0J+5CJOJQJ^JaJ0jhUh0J+5CJOJQJU^JaJ hUhCJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUhoCJOJQJ^JaJ0 +2GVΈ܈0?M[ÉɉʉΉՉމ(*˷ˤooooooooo\ooo$hUhT0J+CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUhTCJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ'hUh10J5CJOJQJ^JaJ0jhUh0J+5CJOJQJU^JaJ6j.hUh0J+5CJOJQJU^JaJ$*/OPmnoz{P`bgkrɸɍ~l~YFY3$hUh10J,CJOJQJ^JaJ$hUh10J1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ#hUh10J15CJOJQJaJhUh1CJOJQJaJ$hUh10JCJOJQJ^JaJ/j /hUhzCJOJQJU^JaJ hUhzCJOJQJ^JaJ)jhUhzCJOJQJU^JaJ hUh1CJOJQJ^JaJ hUhK($CJOJQJ^JaJNjȋ u|ӌ܌ aoqvʍ͍ Ųńq`O hUhoCJOJQJ^JaJ hUhK($CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ'hUh10J6CJOJQJ^JaJ3j/hUh|[0J,CJOJQJU^JaJ$hUh|[0J,CJOJQJ^JaJ-jhUh|[0J,CJOJQJU^JaJ hUh1CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJBQΎюێ/>lqu|ɏُ -17@O]rĐՐِސ$+BFr{‘ݑ޺ޡ'hUhKI0J+5CJOJQJ^JaJ0jhUhKI0J+5CJOJQJU^JaJ hUhK($CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUhoCJOJQJ^JaJ6ݑޑߑ489SZo~֒NUgvȓד˷ˤo\\\\\\\\\$hUh10J,CJOJQJ^JaJ hUhK($CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ$hUhKI0J+CJOJQJ^JaJ'hUhKI0J5CJOJQJ^JaJ0jhUhKI0J+5CJOJQJU^JaJ6j 0hUhKI0J+5CJOJQJU^JaJ4o&ܕ˗ڗ} `Ĝ͝@edq7~Egdoedq7~Egd*edq7~EgdK($2edq7~EgdK($edq7~EgdK($#1]mot&+KY|ܕ˸˸˸ˣzg˸˸˸XhUh1CJOJQJaJ$hUh10JCJOJQJ^JaJ/j0hUh|[CJOJQJU^JaJ hUh|[CJOJQJ^JaJ)jhUh|[CJOJQJU^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUhK($CJOJQJ^JaJ$hUhK($0J+CJOJQJ^JaJ DMȖ֖#*2AZiov˗ԗٗڗޗ˸˸˸˧raP hUh*0J+CJOJQJaJ hUhK($0J+CJOJQJaJ hUh10J+CJOJQJaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUhK($CJOJQJ^JaJ$hUh10J1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJhUh1CJOJQJaJ#hUh10J15CJOJQJaJ Wgk{}  &4M[ԙ(6DK\qɚ +9@IMQ^`ͻͨ܄܄ hUhK($CJOJQJ^JaJ$hUh10J1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ#hUh10J15CJOJQJaJhUh1CJOJQJaJ hUh1CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ4`dt!(elzĜǜМ(9Y]͝Н<̨̹̹sbsbsb hUhoCJOJQJ^JaJ hUh*CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUhK($CJOJQJ^JaJ$hUh10J1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ#hUh10J15CJOJQJaJhUh1CJOJQJaJ&<@[_֞מ؞(6_lܶzܶbzShUh1CJOJQJaJ/j1hUhR }CJOJQJU^JaJ$hUh10JCJOJQJ^JaJ/j0hUhR }CJOJQJU^JaJ hUhR }CJOJQJ^JaJ)jhUhR }CJOJQJU^JaJ hUhK($CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ˟%3ʠՠ۠ CQ`kqrv˸˸˧p[J hUhR }CJOJQJ^JaJ)jhUhR }CJOJQJU^JaJ$hUhK($0J+CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUhK($CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10J1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJhUh1CJOJQJaJ#hUh10J15CJOJQJaJ`oIɦ[ƨ֫8]S2edq7~Egd+#2edq7~Egd)^edq7~Egd)^edq7~Egd)^2edq7~Egd@edq7~Egd :edq7~EgdK($2edq7~EgdK($ǡȡ5@FT ,-.9:ҿҮu]uJu$hUh[0JCJOJQJ^JaJ/j2hUh[CJOJQJU^JaJ)jhUh[CJOJQJU^JaJ hUh[CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ)jhUhR }CJOJQJU^JaJ/j2hUhR }CJOJQJU^JaJӣԣգۣܣ .?LT_mtWeoӷn[[[[J[J[ hUh :CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUhK($CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ'hUh10J5CJOJQJ^JaJ6j 3hUhKI0J+5CJOJQJU^JaJ'hUhKI0J+5CJOJQJ^JaJ0jhUhKI0J+5CJOJQJU^JaJot#IN]kz{ɦ̦֦NUǧէ"[^t޶ziii hUh :CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ/j3hUh[CJOJQJU^JaJ hUh[CJOJQJ^JaJ)jhUh[CJOJQJU^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUhCJOJQJ^JaJ)tĨƨ˨ݨ#?X_guɩѩة*1N\iv~  +9PV\cΫԫܼ֫s hUh)^CJOJQJ^JaJ$hUh10J1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ#hUh10J15CJOJQJaJhUh1CJOJQJaJ hUhCJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ-֫ګ*8:=AE]`&'DĘ̹ss^M5/j3hUhv6CJOJQJU^JaJ hUhv6CJOJQJ^JaJ)jhUhv6CJOJQJU^JaJ hUh :CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh+#CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10J1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ#hUh10J15CJOJQJaJhUh1CJOJQJaJEFQRSVZavԭ":A\jۮRƵƢƢƢƑƢƢƢƢƢƂp]$hUh10J+CJOJQJ^JaJ#hUh10J15CJOJQJaJhUh1CJOJQJaJ hUh+#CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh :CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ)jhUhv6CJOJQJU^JaJf:sհ22A`ɺ˼edq7~Egd+#@edq7~Egd :2edq7~Egd+#edq7~Egd+#edq7~Egd+#Rdfko}ɯү":=sxհذܰ3Eɱױ <Jnɸɸ hUhCJOJQJ^JaJ hUh :CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUh+#CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ$hUh10J1CJOJQJ^JaJ3167RSpqr}~߳Tb}2ܶziiX hUh0CJOJQJ^JaJ hUh :CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ/jq4hUhzCJOJQJU^JaJ hUhzCJOJQJ^JaJ)jhUhzCJOJQJU^JaJ hUh+#CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ23PQRX]^cdAR}ꮛrꮛaNNN$hUh10J,CJOJQJ^JaJ hUh :CJOJQJ^JaJ/jc5hUh0CJOJQJU^JaJ hUh1CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ$hUh00JCJOJQJ^JaJ/j4hUh0CJOJQJU^JaJ hUh0CJOJQJ^JaJ)jhUh0CJOJQJU^JaJ2;@AP^ӷ}}n_nN;$hUh10JCJOJQJ^JaJ hUh1CJOJQJ^JaJhUh+#CJOJQJaJhUh1CJOJQJaJ$hUh10J1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ'hUh10J5CJOJQJ^JaJ6j5hUhKI0J+5CJOJQJU^JaJ'hUhKI0J+5CJOJQJ^JaJ0jhUhKI0J+5CJOJQJU^JaJ^etַڷ*2HLȸ:L`¹ҹ  )/HLڶp hUh+#CJOJQJ^JaJ$hUh10J1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJhUh1CJOJQJaJ hUh1CJOJQJ^JaJ$hUh0JCJOJQJ^JaJ$hUh10JCJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ,Ǻͺκպ  /6OUwûѻܻ4BT[ɼϼмۼ JWkqϽս mҾ߾޺޺޺޺޺޺޺޺޺޺޺޺޺޺޺޺޺޺޺޺޺޺޺޺޺޺޺$hUh10J,CJOJQJ^JaJ hUh+#CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUh CJOJQJ^JaJBo~߿rB&U,$edq7~EgdR<edq7~EgdR<edq7~EgdR<@edq7~Egdq2edq7~EgdR<edq7~Egd+#edq7~Egd+#edq7~Egd+#2edq7~Egd+# $%&,-ox}~߿ӷ琁raNaNa?-#hUh10J15CJOJQJaJhUh1CJOJQJaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJhUh+#CJOJQJaJhUh1CJOJQJaJ$hUh10J+CJOJQJ^JaJ'hUh10J5CJOJQJ^JaJ6jU6hUhKI0J+5CJOJQJU^JaJ'hUhKI0J+5CJOJQJ^JaJ0jhUhKI0J+5CJOJQJU^JaJrvw=@BELZ^etxͼͩͩͩͩͩͩͩ͘kO6j6hUh![0J+5CJOJQJU^JaJ'hUh![0J+5CJOJQJ^JaJ0jhUh![0J+5CJOJQJU^JaJ hUhqCJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUhR<CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJhUh1CJOJQJaJ&)-4=KYZҿyyj[jJ hUhCJOJQJ^JaJhUhR<CJOJQJaJhUh1CJOJQJaJ hUhR<CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUhqCJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ0jhUh![0J+5CJOJQJU^JaJ'hUh10J5CJOJQJ^JaJ;<&*,01CꝎ||iViViE hUhR<CJOJQJ^JaJ$hUh10J1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ#hUh10J15CJOJQJaJhUh1CJOJQJaJ hUh1CJOJQJ^JaJ$hUh0JCJOJQJ^JaJ/j?7hUhCJOJQJU^JaJ hUhCJOJQJ^JaJ)jhUhCJOJQJU^JaJCP$'Ub!/?IopܶzeT hUhzCJOJQJ^JaJ)jhUhzCJOJQJU^JaJ$hUh10JCJOJQJ^JaJ/j7hUh CJOJQJU^JaJ hUh CJOJQJ^JaJ)jhUh CJOJQJU^JaJ hUhqCJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJKRcdky%,AEP]CDҿҮyyyy hUhR<CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUhqCJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ)jhUhzCJOJQJU^JaJ/jg8hUhzCJOJQJU^JaJ/_?=xHh?g(2edq7~Egd edq7~Egd edq7~Egd @edq7~Egd{ edq7~EgdR<edq7~EgdR<2edq7~EgdR<PW_m=@x{HId޺t[G'hUh![0J+5CJOJQJ^JaJ0jhUh![0J+5CJOJQJU^JaJ$hUh10JACJOJQJ^JaJ hUh^gCJOJQJ^JaJ hUhqCJOJQJ^JaJ hUhR<CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10J1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJhUh1CJOJQJaJdeflmov{|  lm?˷ˤ}a˷ˤP?P?P hUhR<CJOJQJ^JaJ hUh1CJOJQJ^JaJ6jW9hUh![0J+5CJOJQJU^JaJ'hUh![0J+5CJOJQJ^JaJ$hUh10J1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ'hUh10J5CJOJQJ^JaJ0jhUh![0J+5CJOJQJU^JaJ6j8hUh![0J+5CJOJQJU^JaJ?g#()DEFLMO]hűŁn[nű?Łn[n6jA:hUhgR0J+5CJOJQJU^JaJ$hUhgR0J1CJOJQJ^JaJ$hUhgR0J+CJOJQJ^JaJ'hUhgR0J5CJOJQJ^JaJ6j9hUhgR0J+5CJOJQJU^JaJ'hUhgR0J+5CJOJQJ^JaJ0jhUhgR0J+5CJOJQJU^JaJ$hUh10J+CJOJQJ^JaJhUh1CJOJQJaJ,-O\+BP`j凜|i$hUh10JCJOJQJ^JaJ/j:hUh CJOJQJU^JaJ hUh CJOJQJ^JaJ)jhUh CJOJQJU^JaJ hUhCJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh CJOJQJ^JaJ hUh1CJOJQJ^JaJ))/dgSPyedq7~Egdy(edq7~Egdy(2edq7~Egdy(4edq7~Egd^g $$edq7~Egd^gedq7~Egd 2edq7~Egd @edq7~Egdj(),Za|&-/2UYanɱڞzzzzzzizzzz hUh CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUhCJOJQJ^JaJ$hUh10JCJOJQJ^JaJ/j/;hUh CJOJQJU^JaJ hUh CJOJQJ^JaJ)jhUh CJOJQJU^JaJ hUh1CJOJQJ^JaJ) d)*KLM_ＩrZG$hUh10JCJOJQJ^JaJ/j;hUh=CJOJQJU^JaJ hUh=CJOJQJ^JaJ)jhUh=CJOJQJU^JaJ hUh CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJhUh1CJOJQJaJ hUhCJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ_bc~#gj&'=QWXŲŲšŲšŐgTŲC hUhy(CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ/j+<hUh=CJOJQJU^JaJ hUh=CJOJQJ^JaJ hUh^gCJOJQJ^JaJ hUhCJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ)jhUh=CJOJQJU^JaJ'hUh10J6CJOJQJ^JaJ#$6?STrstǶNjveMvv/j%=hUh=CJOJQJU^JaJ hUh=CJOJQJ^JaJ)jhUh=CJOJQJU^JaJ$hUh10JCJOJQJ^JaJ/j<hUh CJOJQJU^JaJ hUh CJOJQJ^JaJ)jhUh CJOJQJU^JaJ hUh1CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJPyӷ}a}N?NhUh1CJOJQJaJ$hUh10J+CJOJQJ^JaJ6j>Ug0+5Cϴ$Ug01䴳ϴ$Ug0+䴳ϴ'Ug05Cϴ6=Ug0+5Cϴ'Ug0+5Cϴ0Ug0+5Cϴ5<MPUbvɸɥɔɔɥɥɥɥɥɥɸɥnV/j>hUhCJOJQJU^JaJ hUhCJOJQJ^JaJ)jhUhCJOJQJU^JaJ hUhZCJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUhy(CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ$hUh10J1CJOJQJ^JaJMv!lYuedq7~Egd`t@edq7~EgdZ2edq7~Egd`tedq7~Egd`tedq7~Egd`t@edq7~Egd2edq7~Egdy(  [b =ǴǟvǴgUgB$hUh10J+CJOJQJ^JaJ#hUh10J15CJOJQJaJhUh1CJOJQJaJ/j?hUhH-KCJOJQJU^JaJ hUhH-KCJOJQJ^JaJ)jhUhH-KCJOJQJU^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ)jhUhCJOJQJU^JaJ$hUh10JCJOJQJ^JaJ=Fvz{#* SZ !"=ɸɥɥɔɥɥɥɥɔɥɥɥɥɥ{g'hUhgR0J+5CJOJQJ^JaJ0jhUhgR0J+5CJOJQJU^JaJ hUhZCJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh`tCJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ$hUh10J1CJOJQJ^JaJ!=>?EFHOTUpqrxy{˷ˤ}a˷ˤN= hUh1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ6j?hUhgR0J+5CJOJQJU^JaJ'hUhgR0J+5CJOJQJ^JaJ$hUhgR0J1CJOJQJ^JaJ$hUhgR0J+CJOJQJ^JaJ'hUhgR0J5CJOJQJ^JaJ0jhUhgR0J+5CJOJQJU^JaJ6j|?hUhgR0J+5CJOJQJU^JaJ ,\jlo)-z (޺ޥ|i޺$hUh10JCJOJQJ^JaJ/jf@hUhCJOJQJU^JaJ hUhCJOJQJ^JaJ)jhUhCJOJQJU^JaJ hUhZCJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUh`tCJOJQJ^JaJ%()FGHVWY 5<@G "0Ꝏ{{{{{{{{{{{{{{lhUh1CJOJQJaJ$hUh10J,CJOJQJ^JaJhUh1CJOJQJaJ hUh1CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ/jAhUh[CJOJQJU^JaJ hUh[CJOJQJ^JaJ)jhUh[CJOJQJU^JaJ&.>M[uyz+|˸˸˧jV'hUhgR0J+5CJOJQJ^JaJ0jhUhgR0J+5CJOJQJU^JaJ$hUh10J,CJOJQJ^JaJ hUh`tCJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10J1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJhUh1CJOJQJaJ#hUh10J15CJOJQJaJ ',-HIJPQSal˷ˤ}a˷ˤN= hUh1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ6jAhUhgR0J+5CJOJQJU^JaJ'hUhgR0J+5CJOJQJ^JaJ$hUhgR0J1CJOJQJ^JaJ$hUhgR0J+CJOJQJ^JaJ'hUhgR0J5CJOJQJ^JaJ0jhUhgR0J+5CJOJQJU^JaJ6jzAhUhgR0J+5CJOJQJU^JaJ)-zkr@CTb29AOelmn޺޺ާz0jhUhY_0J+5CJOJQJU^JaJ'hUh`t0J+5CJOJQJ^JaJ$hUh`t0J+CJOJQJ^JaJ hUhZCJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUh`tCJOJQJ^JaJ+@e;F+aM)H"   edq7~Egd+G,2edq7~Egd+G,edq7~Egd7b2edq7~Egd7bedq7~Egd7b@edq7~EgdZn϶{gK8{$hUh`t0J+CJOJQJ^JaJ6jBhUhY_0J+5CJOJQJU^JaJ'hUh10J+5CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ'hUh10J5CJOJQJ^JaJ'hUh[0J5CJOJQJ^JaJ0jhUhY_0J+5CJOJQJU^JaJ6jdBhUhY_0J+5CJOJQJU^JaJ'hUhY_0J+5CJOJQJ^JaJnu/=?@DK_m|"HQko˸˸˸˸˸˸˸˸˸˸˸˸˸˸˸˸˧z/jVChUhY_CJOJQJU^JaJ)jhUhY_CJOJQJU^JaJ hUhY_CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUh7bCJOJQJ^JaJ$hUh7b0J+CJOJQJ^JaJ* 678?CDJKO]v}ŴvڟeRRRRRR$hUh10J,CJOJQJ^JaJ hUh7bCJOJQJ^JaJ/jChUhdmyCJOJQJU^JaJ hUhdmyCJOJQJ^JaJ)jhUhdmyCJOJQJU^JaJ hUh1CJOJQJ^JaJ)jhUhY_CJOJQJU^JaJ$hUh10JCJOJQJ^JaJ$hUhY_0JCJOJQJ^JaJ()/07E\jefjxQRYg$(),@DJXҿҮyy hUhZCJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh7bCJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ)jhUhdmyCJOJQJU^JaJ/jHDhUhdmyCJOJQJU^JaJ/HK:HN\| ܼp$hUh u0J1CJOJQJ^JaJ$hUh10J1CJOJQJ^JaJ$hUh u0J+CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJhUh1CJOJQJaJ hUhZCJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ)  #'2Dky "%UV޺޺ާnV/jDhUhMfCJOJQJU^JaJ hUhMfCJOJQJ^JaJ)jhUhMfCJOJQJU^JaJ$hUh7b0J+CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ hUhZCJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUh7bCJOJQJ^JaJ!w{2@lm/6 ƳƳƳƳƳƞuמdƳƳƳƳdƳƳƳ hUh7bCJOJQJ^JaJ/j:EhUhfTjCJOJQJU^JaJ hUhfTjCJOJQJ^JaJ)jhUhfTjCJOJQJU^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ)jhUhMfCJOJQJU^JaJ'  # $ % 0 1 = J     C Q         - 1   % 3 7 E b k   ꝊyjhUh1CJOJQJaJ hUh+G,CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ/jEhUhMfCJOJQJU^JaJ hUhMfCJOJQJ^JaJ)jhUhMfCJOJQJU^JaJ" ; ,Jc!. K$Ifgd\edq7~Egd12edq7~Egd n $edq7~Egd{2edq7~Egd+G,edq7~Egd+G, ; @   ,1NU[iz Jc./Z[˸˸˸˸˸˸˸˩˸˘tcc hUh1CJOJQJ^JaJ$hUhED0J+CJOJQJ^JaJ hUh12CJOJQJ^JaJ hUh\CJOJQJ^JaJhUh1CJOJQJaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUh+G,CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ./OVXZ;2222 K$Ifgd\kd,F$$Ifedq7~El44\e~& t0644 lalf4itq7~Ep(yt2bZ[\]^_=4444 K$Ifgd\kdF$$Ifedq7~El4\e~& t0644 lalf4itq7~Ep(yt2b[]_`abdefgijklno~˺p_N_;$hUh_0J6CJOJQJ^JaJ hUh`jCJOJQJ^JaJ hUh`jCJOJQJ^JaJ$hUh`j0J+CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ hUhEDCJOJQJ^JaJ$hUhED0J6CJOJQJ^JaJ hUhEDCJOJQJ^JaJ hUh1CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10J6CJOJQJ^JaJ_`abcd=4444 K$Ifgd\kdG$$Ifedq7~El4\e~& t0644 lalf4itq7~Ep(yt2bdefghi=4444 K$Ifgd\kdH$$Ifedq7~El4\e~& t0644 lalf4itq7~Ep(yt2bijklmn=4444 K$Ifgd\kdWI$$Ifedq7~El4\e~& t0644 lalf4itq7~Ep(yt2bno~=5,, K$Ifgd\edq7~Egd nkd!J$$Ifedq7~El4\e~& t0644 lalf4itq7~Ep(yt2b2kdJ$$Ifedq7~El44\e~& t0644 lalf4itq7~Ep(yt`j K$Ifgd\4kdK$$Ifedq7~El4\e~& t0644 lalf4itq7~Ep(yt`j K$Ifgd\4kdL$$Ifedq7~El4\e~& t0644 lalf4itq7~Ep(yt`j K$Ifgd\)67CDb޺xgRg)jhUhl(CJOJQJU^JaJ hUhl(CJOJQJ^JaJ hUhF CJOJQJ^JaJhUh1CJOJQJaJ hUh1CJOJQJ^JaJ hUh`jCJOJQJ^JaJ hUh\CJOJQJ^JaJ$hUh_0J6CJOJQJ^JaJ hUh_CJOJQJ^JaJ hUh_CJOJQJ^JaJ4kdRM$$Ifedq7~El4\e~& t0644 lalf4itq7~Ep(yt`j K$Ifgd\4kdN$$Ifedq7~El4\e~& t0644 lalf4itq7~Ep(yt`j K$Ifgd\4,edq7~Egd`jkdN$$Ifedq7~El4\e~& t0644 lalf4itq7~Ep(yt`j K$Ifgd\)7a{kdP$$Ifedq7~El44~& t0644 lalf4itq7~Ep yt $Ifgdl(edq7~EgdF $edq7~Egd{edq7~Egd tbcdpqvwҿҮҮҿҮlYF$hUhl(0J+CJOJQJ^JaJ$hUh0J+CJOJQJ^JaJ-hUh0J+5>*CJOJQJ\^JaJ$hUhl(0J,CJOJQJ^JaJ/j+PhUhl(CJOJQJU^JaJ hUhl(CJOJQJ^JaJ$hUhl(0JCJOJQJ^JaJ)jhUhl(CJOJQJU^JaJ/jOhUhl(CJOJQJU^JaJoyp $Ifgdl(Medq7~Egdl(}kdEQ$$Ifedq7~El44~& t0644 lalf4itq7~Ep ytBIJKOVopqr}~޴޴q^J'hUh10J+5CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJhUh1CJOJQJaJ#hUh10J15CJOJQJaJ hUhCJOJQJ^JaJ hUh\CJOJQJ^JaJ-hUhl(0J+5>*CJOJQJ\^JaJ$hUhl(0J,CJOJQJ^JaJ hUhl(CJOJQJ^JaJ hUhUCJOJQJ^JaJopq $Ifgdl(ukdQ$$Ifedq7~El44~& t0644 lalf4itq7~Eytl(qr~Xfwoooog^^ K$Ifgd&edq7~Egd5 edq7~Egdo $edq7~Egd{edq7~Egdwkd~R$$Ifedq7~El44~& t0644 lalf4itq7~Eyt "&ei fo !"ӷ}l}l}l}l}l}l}l}l}l}l}lW)jhUhVCJOJQJU^JaJ hUh1CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ'hUh10J5CJOJQJ^JaJ6jShUhV0J+5CJOJQJU^JaJ'hUhV0J+5CJOJQJ^JaJ0jhUhV0J+5CJOJQJU^JaJ"KLMUVXef¯ž|iViEEEEEEEE hUh1CJOJQJ^JaJ$hUh10J1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ hUh5 CJOJQJ^JaJ hUh\CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ)jhUhVCJOJQJU^JaJ/jShUhVCJOJQJU^JaJ hUhVCJOJQJ^JaJ4kd8T$$Ifedq7~El4\e~& t0644 lalf4itq7~Ep(ytMTm K$Ifgd&4kdU$$Ifedq7~El4\e~& t0644 lalf4itq7~Ep(ytMTm K$Ifgd&4kdU$$Ifedq7~El4\e~& t0644 lalf4itq7~Ep(ytMTm K$Ifgd&4kdV$$Ifedq7~El4\e~& t0644 lalf4itq7~Ep(ytMTm K$Ifgd&4kd`W$$Ifedq7~El4\e~& t0644 lalf4itq7~Ep(ytMTm K$Ifgd&4kd*X$$Ifedq7~El4\e~& t0644 lalf4itq7~Ep(ytMTm K$Ifgd&4kdX$$Ifedq7~El4\e~& t0644 lalf4itq7~Ep(ytMTm K$Ifgd&4kdY$$Ifedq7~El4\e~& t0644 lalf4itq7~Ep(ytMTm K$Ifgd&4kdZ$$Ifedq7~El4\e~& t0644 lalf4itq7~Ep(ytMTm K$Ifgd&  !"&'23CMYZ}~ͼo[?6j`hUhV0J+5CJOJQJU^JaJ'hUhV0J+5CJOJQJ^JaJ0jhUhV0J+5CJOJQJU^JaJ$hUh10J+CJOJQJ^JaJhUh1CJOJQJaJ#hUh10J15CJOJQJaJ hUh$CJOJQJ^JaJ hUh\CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUh1CJOJQJ^JaJ   4kdR[$$Ifedq7~El4\e~& t0644 lalf4itq7~Ep(ytMTm K$Ifgd&   4kd\$$Ifedq7~El4\e~& t0644 lalf4itq7~Ep(ytMTm K$Ifgd&4kd\$$Ifedq7~El4\e~& t0644 lalf4itq7~Ep(ytMTm K$Ifgd&4kd]$$Ifedq7~El4\e~& t0644 lalf4itq7~Ep(ytMTm K$Ifgd&4kdz^$$Ifedq7~El4\e~& t0644 lalf4itq7~Ep(ytMTm K$Ifgd& !"#$4kdD_$$Ifedq7~El4\e~& t0644 lalf4itq7~Ep(ytMTm K$Ifgd&$%&'34,edq7~Egd$kd`$$Ifedq7~El4\e~& t0644 lalf4itq7~Ep(ytMTm K$Ifgd&3M Q[d $Ifgdeaedq7~Egd5 edq7~Egdea $edq7~Egd{ ~qxBPv^vKv$hUhV0JCJOJQJ^JaJ/j]ahUhVCJOJQJU^JaJ)jhUhVCJOJQJU^JaJ hUhVCJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ'hUh10J5CJOJQJ^JaJ0jhUhV0J+5CJOJQJU^JaJ  )3: ͼraR@R1hUh1CJOJQJaJ#hUh10J15CJ"OJQJaJ"hUh1CJ"OJQJaJ" hUheaCJOJQJ^JaJ hUheaCJOJQJ^JaJ$hUhu 0J+CJOJQJ^JaJ$hUhea0J1CJOJQJ^JaJ$hUhea0J+CJOJQJ^JaJ hUh5 CJOJQJ^JaJ hUh\CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUhVCJOJQJ^JaJ=0000 $Ifgdeakda$$Ifedq7~El4\e~& t0644 lalf4itq7~Ep(ytea=0000 $Ifgdeakdb$$Ifedq7~El4\e~& t0644 lalf4itq7~Ep(ytea=0000 $Ifgdeakdc$$Ifedq7~El4\e~& t0644 lalf4itq7~Ep(ytea=0000 $IfgdeakdRd$$Ifedq7~El4\e~& t0644 lalf4itq7~Ep(ytea=0000 $Ifgdeakde$$Ifedq7~El4\e~& t0644 lalf4itq7~Ep(ytea=0000 $Ifgdeakde$$Ifedq7~El4\e~& t0644 lalf4itq7~Ep(ytea=0000 $Ifgdeakdf$$Ifedq7~El4\e~& t0644 lalf4itq7~Ep(ytea=0000 $Ifgdeakdzg$$Ifedq7~El4\e~& t0644 lalf4itq7~Ep(ytea=0000 $IfgdeakdDh$$Ifedq7~El4\e~& t0644 lalf4itq7~Ep(ytea=0000 $Ifgdeakdi$$Ifedq7~El4\e~& t0644 lalf4itq7~Ep(ytea=0000 $Ifgdeakdi$$Ifedq7~El4\e~& t0644 lalf4itq7~Ep(ytea=0000 $Ifgdeakdj$$Ifedq7~El4\e~& t0644 lalf4itq7~Ep(ytea=0000 $Ifgdeakdlk$$Ifedq7~El4\e~& t0644 lalf4itq7~Ep(ytea=0000 $Ifgdeakd6l$$Ifedq7~El4\e~& t0644 lalf4itq7~Ep(ytea=0000 $Ifgdeakdm$$Ifedq7~El4\e~& t0644 lalf4itq7~Ep(ytea =5,$edq7~Egd $edq7~Egdeaedq7~Egdeakdm$$Ifedq7~El4\e~& t0644 lalf4itq7~Ep(ytea CFGN|M[cg      !!!!F!W!]!c!x!}!!!" "̻̻̻̻̻w hUh$FCJOJQJ^JaJ hUh0jCJOJQJ^JaJ hUh $jCJOJQJ^JaJ hUh\yCJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ#hUh10J15CJOJQJaJhUh1CJOJQJaJ. G|Mc N   !!]!x!!!@edq7~Egd0jDedq7~Egd0jedq7~Egd04edq7~Egd0@edq7~Egd $jDedq7~Egd $jedq7~Egdc|Dedq7~Egd\yedq7~Egdedq7~Egd!""e"""" #5##$$%%g&&&'()*edq7~Egdedq7~Egdedq7~Egd'2edq7~Egd$F4edq7~EgdL9@edq7~Egd$F4edq7~Egd"j@edq7~Egd0jDedq7~Egd$F ""#"N"_"e"k""""" #$#5#:#g#x#{##$$$$%%%%g&k&&&&&''''(()* *-*zkhUhCJOJQJaJhUh1CJOJQJaJhUh1CJOJQJaJ hUhS5CJOJQJ^JaJ hUhL9CJOJQJ^JaJ hUh$FCJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh0jCJOJQJ^JaJ hUh1CJOJQJ^JaJ**-*;*h*i*y*z*lzkdn$$Ifedq7~El4~& t0644 lalf4itq7~Ep yt K$Ifgd^!edq7~Egdedq7~Egd-*:*;*h*i*x*z*{***********ͼtcRA.R$hUh10J,CJOJQJ^JaJ hUhS5CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUhhkCJOJQJ^JaJ$hUh0J,CJOJQJ^JaJ hUh^!CJOJQJ^JaJ hUh^!CJOJQJ^JaJ$hUh^!0J,CJOJQJ^JaJ hUhCJOJQJ^JaJ hUhCJOJQJ^JaJ hUhHCJOJQJ^JaJ hUh\CJOJQJ^JaJz*{***mdd K$Ifgd^!kd2o$$Ifedq7~El40 ~& t0644 lalf4itq7~Epyt*****X++J,,me]UMMMM@edq7~Egdhk4edq7~Egd+m;Dedq7~Egdhkedq7~EgdHkdo$$Ifedq7~El40 ~& t0644 lalf4itq7~Epyt**X+\+++J,N,,,D-O---..L/Y/Z////////////000޺ttcR hUh$'CJOJQJ^JaJ hUhX,CJOJQJ^JaJ$hUh0J,CJOJQJ^JaJ hUhCJOJQJ^JaJ hUhCJOJQJ^JaJ hUh2 MCJOJQJ^JaJ hUh\CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUhhkCJOJQJ^JaJ ,D--.L/Z/////dzkdp$$Ifedq7~El4~& t0644 lalf4itq7~Ep yt K$Ifgdedq7~Egd2 M4edq7~Egd+m;@edq7~Egdhk ////mdd K$IfgdkdJ $$$IfgdB $Ifgd*rkdr$$Ifedq7~El44F ~& t06    44 lalf4itq7~Epyt*r44444VMMM $Ifgd*rkdcs$$Ifedq7~El4F ~&` t06    44 lalitq7~Epyt*r44445VJ>> $$$Ifgd3 $$$IfgdBkdt$$Ifedq7~El4F ~&  t06    44 lalitq7~Epyt*r55555VMAA $$$Ifgd3 $Ifgd*rkdt$$Ifedq7~El4F ~&` t06    44 lalitq7~Epyt*r5555(5VMAM $$$IfgdB $Ifgd*rkdu$$Ifedq7~El4F ~&  t06    44 lalitq7~Epyt*r(5)5F5J5U5VJJA $Ifgd*r $$$IfgdBkdKv$$Ifedq7~El4F ~&  t06    44 lalitq7~Epyt*rU5V5W5[5g5VMAM $$$IfgdB $Ifgd*rkdw$$Ifedq7~El4F ~&` t06    44 lalitq7~Epyt*rg5h5i5m5{5VMAM $$$IfgdB $Ifgd*rkdw$$Ifedq7~El4F ~&  t06    44 lalitq7~Epyt*rg5h5{5|55555666z7{77777@8D8o8t888X9\999:::!:":A:|||kkTk-jhUh10J/CJOJQJU^JaJ hUh>CJOJQJ^JaJ hUhTCJOJQJ^JaJ hUh5NCJOJQJ^JaJ hUh1CJOJQJ^JaJ hUhX,CJOJQJ^JaJhUh1CJOJQJaJhUh1CJOJQJaJ hUhCJOJQJ^JaJ hUhCJOJQJ^JaJ {5|5}555VMMM $Ifgd*rkdyx$$Ifedq7~El4F ~&  t06    44 lalitq7~Epyt*r55556{77VNF>>64edq7~Egd5N2edq7~Egd2edq7~Egd+m;edq7~Egd+m;kd3y$$Ifedq7~El4F ~&  t06    44 lalitq7~Epyt*r77@8o88X99:k::;<<=?W??lAAAedq7~Egd M4edq7~EgdX,edq7~Egdedq7~Egd4edq7~Egd5N2edq7~EgdT@edq7~Egd>7ʷ7ʷ27ʷ2:::::;;<<<<==4>7>?W???@ AkAlAAAAAAAAyhW hUh|cCJOJQJ^JaJ hUh\CJOJQJ^JaJ#hUh10J15CJOJQJaJhUh1CJOJQJaJhUh1CJOJQJaJ$hUh10J,CJOJQJ^JaJ hUh5NCJOJQJ^JaJ hUhX,CJOJQJ^JaJ hUh>CJOJQJ^JaJ hUh1CJOJQJ^JaJAAABB&B'Blzkdy$$Ifedq7~El4~& t0644 lalf4itq7~Ep yt K$Ifgdedq7~Egd|cedq7~Egd MABB%B'B(B/B1B2B=B>BBBBBCCOCSCCCxD|DDD EEEEEEEFJFMFnFsFFFAG޺vvvvvvvvccvv$hUh10J,CJOJQJ^JaJ hUhG`CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUhX,CJOJQJ^JaJ hUh|cCJOJQJ^JaJ hUh\CJOJQJ^JaJ$hUh0J,CJOJQJ^JaJ hUhCJOJQJ^JaJ hUhCJOJQJ^JaJ&'B(B0B1Bmdd K$Ifgdkdz$$Ifedq7~El40 ~& t0644 lalf4itq7~Epyt1B2B>BBCOCCxDD Eme]UUUUU]@edq7~EgdG`2edq7~Egd2edq7~Egd|ckdA{$$Ifedq7~El40 ~& t0644 lalf4itq7~Epyt EEEnFFAGHtHHHaIIJyJJdKKKK K$Ifgdedq7~Egdhedq7~Egd#Bedq7~Egd`&@edq7~Egd`&2edq7~Egd2Bedq7~EgdG`@edq7~EgdG`AGFGH"HtHxHHHHHaIeIIIJ!JxJyJ}JJKdKqKzKKKKK޼޼޼޼޼޼ާޘveT hUhCJOJQJ^JaJ hUhhCJOJQJ^JaJ hUh\CJOJQJ^JaJ hUh10J,CJOJQJaJhUh1CJOJQJaJ)hUh1B* CJOJQJ^JaJphG hUh`&CJOJQJ^JaJ hUhX,CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUhG`CJOJQJ^JaJKKKK|| K$Ifgdzkd{$$Ifedq7~El4~& t0644 lalf4itq7~Ep ytKKKKKKKL L LLLLMMN N0N4NNNZO`OOOLPPPPPPPPQﺩvvvvveT hUhCJOJQJ^JaJ hUhDCJOJQJ^JaJ hUhi2CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUhX,CJOJQJ^JaJ hUhhCJOJQJ^JaJ hUh\CJOJQJ^JaJ hUhCJOJQJ^JaJ$hUh0J,CJOJQJ^JaJ hUhCJOJQJ^JaJ KKKKmdd K$Ifgdkd|$$Ifedq7~El40 ~& t0644 lalf4itq7~EpytKL LLMN0NNZOme]]]UMMBedq7~Egdi2@edq7~Egdi22edq7~Egd2edq7~EgdhkdK}$$Ifedq7~El40 ~& t0644 lalf4itq7~EpytZOOLPPQQQ;RnRR)SS TqTTUU`VWRWWedq7~EgdV.)edq7~Egd@edq7~EgdFedq7~EgdKedq7~EgdbsBedq7~EgdI@edq7~EgdI2edq7~Egd2@edq7~Egdi2Bedq7~Egdi2Q QQQQQQ;R?RnRrRRRRS)S.SSS T TqTTdUgUUUUU`VdVWRWW޼ީ޼޼ޘޅtttehUh1CJOJQJaJ hUhFCJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh10J+CJOJQJaJ$hUh10JCCJOJQJ^JaJ hUhX,CJOJQJ^JaJ hUhCJOJQJ^JaJ hUh1CJOJQJ^JaJ hUhICJOJQJ^JaJ!WWWWXXVX[XXX[Y_Y[Z_Z.[2[[[\\]!]%]D]H]I]U]\]i]j]]޾{fU hUh +CJOJQJ^JaJ)jhUh +CJOJQJU^JaJ$hUh10J,CJOJQJ^JaJ#hUh10J15CJOJQJaJhUh1CJOJQJaJhUh\CJOJQJaJhUh1CJ"OJQJaJ" hUhFCJOJQJ^JaJ hUh1CJOJQJ^JaJ hUhICJOJQJ^JaJWWXVXX[Y[Z.[[\]!]I]]]]]^>^^^^^Bedq7~EgdK,edq7~EgdQP$edq7~Egd8V  edq7~Egd1 $edq7~Egd*+Bedq7~EgdF@edq7~EgdF2edq7~Egd2]]]]]]]^^>^^^^^^ν^/<_D_R_o_v___!`/`t`u`ҿҮ{{j{jj{{{{{ hUhK,CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUhFCJOJQJ^JaJhUh1CJOJQJaJ hUh1CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ)jhUh +CJOJQJU^JaJ/j~hUh +CJOJQJU^JaJ"^_`` a a aaa[kd $$Ifl40y ~& t0644 lalf4pyt # K$Ifgd]F2 K$edq7~EgdFedq7~Egd8Vu`````````````aa¯žziVE2E$hUh=t0J,CJOJQJ^JaJ hUh=tCJOJQJ^JaJ$hUh=t0J+CJOJQJ^JaJ hUh*;CJOJQJ^JaJ hUh\CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ)jhUh +CJOJQJU^JaJ/jx~hUh +CJOJQJU^JaJ hUh +CJOJQJ^JaJa a a aaaaa&a'a(a)a8a9a:a;aEaFaGaHaLa]adafagahaiaxayaza{aaaaaaaaaaaaaaܑܷܷܷܷܷܷܷܷܷ~$hUhQ~0J+CJOJQJ^JaJ$hUh=t0J,CJOJQJ^JaJ$hUh=t0J+CJOJQJ^JaJ hUh=tCJOJQJ^JaJ&hUh=t5CJOJQJ\^JaJ hUh=tCJOJQJ^JaJ$hUh=t0J6CJOJQJ^JaJ+aa'a(aull K$Ifgd]F2kd$$Ifl40y ~& t0644 lalf4pyt #(a)a9a:aull K$Ifgd]F2kdS$$Ifl40y ~& t0644 lalf4pyt #:a;aFaGaull K$Ifgd]F2kd$$Ifl40y ~& t0644 lalf4pyt #GaHagahaull K$Ifgd]F2kd$$Ifl40y ~& t0644 lalf4pyt #haiayazaull K$Ifgd]F2kdB$$Ifl40y ~& t0644 lalf4pyt #za{aaaull K$Ifgd]F2kd$$Ifl40y ~& t0644 lalf4pyt #aaaaull K$Ifgd]F2kd$$Ifl40y ~& t0644 lalf4pyt #aaaaull K$Ifgd]F2kd1$$Ifl40y ~& t0644 lalf4pyt #aaaaull K$Ifgd]F2kdք$$Ifl40y ~& t0644 lalf4pyt #aaaaaaaabb b>bBbFbdbebbﺧp_L_;* hUh\CJOJQJ^JaJ hUhNCJOJQJ^JaJ$hUhN0J,CJOJQJ^JaJ hUhNCJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10J1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ hUhQ~CJOJQJ^JaJ$hUhQ~0J,CJOJQJ^JaJ hUh2XCJOJQJ^JaJ hUhQ~CJOJQJ^JaJaab>bcbdbummaX K$Ifgd]F2 K$$$Ifgd~$Kedq7~EgdQkd{$$Ifl40y ~& t0644 lalf4pyt #dbebbbmaX K$Ifgd]F2 K$$$Ifgd~$kd $$Ifedq7~El40~&  t0644 lalf4itq7~EpytU'NbbbbbbbbbcNcOcWcYcZcscucvcwc˺vcRAcRAR hUh4CJOJQJ^JaJ hUh4CJOJQJ^JaJ$hUh40J,CJOJQJ^JaJ hUhCJOJQJ^JaJ hUhWT,CJOJQJ^JaJ hUhWT,CJOJQJ^JaJ hUhCJOJQJ^JaJ hUh\CJOJQJ^JaJ hUh\CJOJQJ^JaJ$hUhTu0J,CJOJQJ^JaJ hUhTuCJOJQJ^JaJbbbbbme\\ K$IfgdWT,Medq7~Egdkdֆ$$Ifedq7~El40~&  t0644 lalf4itq7~EpytU'NbbcNcog[ K$$$Ifgd~$Medq7~Egdkd$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytlNcOcXcYc{r K$Ifgd]F2 K$$$Ifgd~$wkdC$$Ifedq7~El4~& t0644 lalf4itq7~Ep ytv1YcZctcucoff K$Ifgd]F2kd܈$$Ifedq7~El40y ~& t0644 lalf4itq7~Epytv1ucvcwcccocZZ $Ifgd]F2 Kedq7~EgdN kd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epytv1wccccccccccc"d%d/d=dFdTdhdkdvddddddd eHeSeTeXe˸pp_pPhUh\CJOJQJaJ hUh\CJOJQJ^JaJ hUhDNCJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10J1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ hUh:"CJOJQJ^JaJ$hUh:"0J6CJOJQJ^JaJ hUh:"CJOJQJ^JaJccc"dhddHeTeeerjjjjjbYQedq7~EgdLEK $edq7~EgdQP$Kedq7~EgdFKedq7~Egde Jkd>$$Ifedq7~El0y ~& t0644 lalitq7~Epyt] Xeeeeeeeeeeeee ff'f4fMf[ffffffgg*gPg^ggggggว|mวU/jhhUh +CJOJQJU^JaJhUh1CJOJQJaJ$hUh10JCJOJQJ^JaJ/jhUh +CJOJQJU^JaJ hUh +CJOJQJ^JaJ)jhUh +CJOJQJU^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJhUh1CJOJQJaJ!eeef,ghh8h9h K$Ifgd]F2 K$edq7~Egdm]edq7~Egdedq7~EgdLEKgggghhhhh'h5h7h8h9h:hIhJhKhLhUhVhǴǣlYEY4Y hUhm]CJOJQJ^JaJ&hUhm]5CJOJQJ\^JaJ$hUhm]0J6CJOJQJ^JaJ$hUhm]0J,CJOJQJ^JaJ$hUhm]0J+CJOJQJ^JaJ hUhm]CJOJQJ^JaJ hUh\CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ)jhUh +CJOJQJU^JaJ$hUh10JCJOJQJ^JaJ9h:hJhKhoff K$Ifgd]F2kd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt #KhLhVhWhoff K$Ifgd]F2kd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt #VhWhXhghhhihjhthuhvhwh{hhhhhhhhhhhhhhhhhhhhhhhhiiii#i1ipi޸޸ޒn hUhYmCJOJQJ^JaJ$hUhYm0J1CJOJQJ^JaJ$hUhYm0J+CJOJQJ^JaJ$hUhm]0J,CJOJQJ^JaJ$hUhm]0J+CJOJQJ^JaJ$hUhm]0J6CJOJQJ^JaJ hUhm]CJOJQJ^JaJ hUhm]CJOJQJ^JaJ)WhXhhhihoff K$Ifgd]F2kd[$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt #ihjhuhvhoff K$Ifgd]F2kd $$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt #vhwhhhoff K$Ifgd]F2kd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt #hhhhoff K$Ifgd]F2kdn$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt #hhhhoff K$Ifgd]F2kd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt #hhhhoff K$Ifgd]F2kdА$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt #hhhhoff K$Ifgd]F2kd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt #hhiioff K$Ifgd]F2kd2$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt #ii2i[i~iiiiogggg^^ K$Ifgd]F2Kedq7~EgdYmkd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt #pi}iiiiiiiiijjj!j#j$j/j0j1j2j=j>j˺˩tctctPtc?t hUh\CJOJQJ^JaJ$hUhm]0J6CJOJQJ^JaJ hUhm]CJOJQJ^JaJ hUhm]CJOJQJ^JaJ$hUhm]0J,CJOJQJ^JaJ hUhCJOJQJ^JaJ hUhCJOJQJ^JaJ hUhCJOJQJ^JaJ hUhCJOJQJ^JaJ hUhYmCJOJQJ^JaJ$hUhYm0J,CJOJQJ^JaJiiiiog[ K$$$Ifgd~$Medq7~Egdkd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epytiijjyp K$Ifgd]F2 K$$$Ifgd~$zkdE$$Ifedq7~El4~& t0644 lalf4itq7~Ep ytjj"j#jmdd K$Ifgd]F2kd$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytZ-#j$j%j0j1jmaXX $Ifgd]F2 Kedq7~Egdm]kd$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytZ-1j2j>jyjjjjTl-mrjaYYQYYedq7~Egdedq7~Egdc $edq7~EgdKedq7~Egdm]kdO$$Ifedq7~El0y ~& t0644 lalitq7~Epyt]>jBjxjyjjjjjjjjjjjjkkGkNkkkkkllDlƵ|dQBhUh1CJOJQJaJ$hUh10JCJOJQJ^JaJ/jhUh +CJOJQJU^JaJ hUh +CJOJQJ^JaJ)jhUh +CJOJQJU^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ(hUh15B*CJOJQJaJph#hUh10J5CJOJQJaJ#hUh\0J5CJOJQJaJDlRlwlllllllllmm*m-m:m;m>mNm\m^mǶNjǶziViCi$hUh0J,CJOJQJ^JaJ$hUh0J+CJOJQJ^JaJ hUhCJOJQJ^JaJ hUh\CJOJQJ^JaJ$hUhH-K0JCJOJQJ^JaJ/jhUhH-KCJOJQJU^JaJ hUhH-KCJOJQJ^JaJ)jhUhH-KCJOJQJU^JaJ hUh1CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ-m;m_m`mamqmrm[kd"$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt} K$Ifgd]F2 K$edq7~Egd^m_m`mampmqmrmsm|m}m~mmmmmmmmmmmmmmmmmmmmmmmmmmmmmmmmmn)n6n:n;nInܑܑܷܷܷܷܷܷܷܷܷܷ~$hUh`?0J+CJOJQJ^JaJ$hUh0J,CJOJQJ^JaJ$hUh0J+CJOJQJ^JaJ hUhCJOJQJ^JaJ&hUh5CJOJQJ\^JaJ hUhCJOJQJ^JaJ$hUh0J6CJOJQJ^JaJ0rmsm}m~mmdd K$Ifgd]F2kdؘ$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt}~mmmmmdd K$Ifgd]F2kd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt}mmmmmdd K$Ifgd]F2kdD$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt}mmmmmdd K$Ifgd]F2kd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt}mmmmmdd K$Ifgd]F2kd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt}mmmmmdd K$Ifgd]F2kdf$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt}mmmmmdd K$Ifgd]F2kd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt}mmmmmdd K$Ifgd]F2kdҝ$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt}mm9n:nmdd K$Ifgd]F2kd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt}:n;nXnnkomome]TT K$Ifgd]F2Kedq7~EgdYKedq7~Egd`?kd>$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt}InWnnnno/o1o8o^ojokolomonooovowoooooooo˸˧˸˧˧˖˅tcR?cR?c$hUh0J,CJOJQJ^JaJ hUhCJOJQJ^JaJ hUhCJOJQJ^JaJ hUh*CJOJQJ^JaJ hUh*CJOJQJ^JaJ hUhYCJOJQJ^JaJ hUh5CJOJQJ^JaJ$hUhY0J,CJOJQJ^JaJ hUhYCJOJQJ^JaJ hUh`?CJOJQJ^JaJ$hUh`?0J1CJOJQJ^JaJmonooouovoog^^ K$Ifgd]F2Medq7~EgdYkd$$Ifedq7~El40~&  t0644 lalf4itq7~EpytU'Nvowoxooog[ K$$$Ifgd~$Medq7~Egd*kd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt*ooooyp K$Ifgd]F2 K$$$Ifgd~$zkd\$$Ifedq7~El4~& t0644 lalf4itq7~Ep ytoooomd[ K$Ifgd]F2 K$Ifgdkd$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytooooomaXX $Ifgd]F2 Kedq7~Egdkd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epytoooooop pHpVppppppp︥p^L; hUh1CJOJQJ^JaJ#hUh10J5CJOJQJaJ#hUh\0J5CJOJQJaJ hUh\CJOJQJ^JaJ$hUh`?0J,CJOJQJ^JaJ hUh`?CJOJQJ^JaJ$hUh`?0J1CJOJQJ^JaJ$hUh`?0J+CJOJQJ^JaJ$hUh0J6CJOJQJ^JaJ hUhCJOJQJ^JaJ hUhCJOJQJ^JaJoo ppppq)q?qphh`WOOGedq7~EgdAEedq7~Egd% $edq7~Egd(Kedq7~EgdKedq7~Egd`?kdf$$Ifedq7~El0y ~& t0644 lalitq7~Epytppqq)q?qqqrrr+r s!sJsKsLsTsUspsssstttttܸ|kZI hUh*CJOJQJ^JaJ hUhD|CJOJQJ^JaJ hUh"xCJOJQJ^JaJ hUh CJOJQJ^JaJ$hUh 0J+CJOJQJ^JaJ hUh0CJOJQJ^JaJ$hUh00J,CJOJQJ^JaJ hUh0CJOJQJ^JaJ$hUh00J+CJOJQJ^JaJ|||||||me]]QH K$IfgdU'N K$$$Ifgd~$Kedq7~Egd0Kedq7~Egd kd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt}||||maX K$IfgdU'N K$$$Ifgd~$kdF$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytU'N||}}maX K$IfgdU'N K$$$Ifgd~$kd$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytU'N}}}}}}}},}-}.}/};}<}=}>}E}F}G}H}L}M}N}O}U}V}W}X}}}}}}}~~˺˺˺˕˕˄sbsb hUh0CJOJQJ^JaJ hUh0CJOJQJ^JaJ hUh7CJOJQJ^JaJ hUhVCJOJQJ^JaJ'hUh"x0J6>*CJOJQJ^JaJ hUhD|CJOJQJ^JaJ hUh"xCJOJQJ^JaJ hUh"xCJOJQJ^JaJ$hUh"x0J6CJOJQJ^JaJ#}}}}maX K$IfgdU'N K$$$Ifgd~$kd$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytU'N}}-}.}maX K$IfgdU'N K$$$Ifgd~$kdh$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytU'N.}/}<}=}maX K$IfgdU'N K$$$Ifgd~$kd$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytU'N=}>}F}G}maX K$IfgdU'N K$$$Ifgd~$kdԾ$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytU'NG}H}M}N}maX K$IfgdU'N K$$$Ifgd~$kd$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytU'NN}O}V}W}maX K$IfgdU'N K$$$Ifgd~$kd@$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytU'NW}X}}}mdd K$IfgdU'Nkd$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytU'N}}}}}meYP K$IfgdS K$$$IfgdZ#Medq7~Egd"xkd$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytU'N}}}~odX K$$$Ifgd~$ M$$edq7~EgdZ#kdb$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt0~~!~"~yp K$IfgdS K$$$Ifgd~$zkd$$Ifedq7~El4~& t0644 lalf4itq7~Ep yt0~ ~"~#~<~>~?~R~S~T~u~v~w~~~~~~~~~~~~~ܸ˧ܘxexP)jhUh#SCJOJQJU^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJhUh1CJOJQJaJhUh\CJOJQJaJ hUh\CJOJQJ^JaJ$hUh00J6CJOJQJ^JaJ hUh0CJOJQJ^JaJ hUh0CJOJQJ^JaJ$hUh00J,CJOJQJ^JaJ"~#~=~>~maX K$IfgdS K$$$Ifgd~$kd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt0>~?~R~S~maX K$IfgdS K$$$Ifgd~$kdg$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt0S~T~u~v~mdd K$IfgdSkd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt0v~w~x~~~maXX $IfgdS Kedq7~Egd0kd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt0~~~~~%;Ȁph[SSKSSedq7~EgdAEedq7~Egd N $ edq7~EgdI,Kedq7~Egd0kd$$Ifedq7~El0y ~& t0644 lalitq7~Epyt0~#$%;r¯ž||gV>g/jhUhH-KCJOJQJU^JaJ hUhH-KCJOJQJ^JaJ)jhUhH-KCJOJQJU^JaJ$hUh10J,CJOJQJ^JaJhUh1CJOJQJaJ hUh1CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ)jhUh#SCJOJQJU^JaJ/j?hUh#SCJOJQJU^JaJ hUh#SCJOJQJ^JaJ+6HN\mt78abcklǴǴǴǴǴǣؒzǴiXE$hUhrP0J+CJOJQJ^JaJ hUhZ#CJOJQJ^JaJ hUh\CJOJQJ^JaJ/j]hUhH-KCJOJQJU^JaJ hUhH-KCJOJQJ^JaJ hUhhCJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ)jhUhH-KCJOJQJU^JaJ$hUhH-K0JCJOJQJ^JaJȀŁƁǁׁ؁Skd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt} K$IfgdW K$edq7~EgdZ#edq7~Egd NāŁƁǁցׁ؁ف')*+,;<=>GHIJYZ[\fghiɸɸɸɸɸɸɸɸɸɸ$hUhrP0J+CJOJQJ^JaJ hUhZ#CJOJQJ^JaJ&hUhZ#5CJOJQJ\^JaJ hUhZ#CJOJQJ^JaJ$hUhZ#0J6CJOJQJ^JaJ$hUhrP0J,CJOJQJ^JaJ hUhrPCJOJQJ^JaJ-؁فmdd K$IfgdWkd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt}mdd K$IfgdWkdZ$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt}mdd K$IfgdWkd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt}*+mdd K$IfgdWkd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt}+,<=mdd K$IfgdWkd|$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt}=>HImdd K$IfgdWkd2$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt}IJZ[mdd K$IfgdWkd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt}[\ghmdd K$IfgdWkd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt}himdd K$IfgdWkdT$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt}i?@sy{|}ܸp]G6 hUh"CJOJQJ^JaJ*hUh"0J,6CJOJQJ]^JaJ$hUhA'0J,CJOJQJ^JaJ hUhA'CJOJQJ^JaJ hUhA'CJOJQJ^JaJ$hUh#0J1CJOJQJ^JaJ$hUh#0J+CJOJQJ^JaJ hUhZ#CJOJQJ^JaJ$hUhZ#0J,CJOJQJ^JaJ hUhZ#CJOJQJ^JaJ$hUhZ#0J+CJOJQJ^JaJ?meY K$$$Ifgd~$Kedq7~Egd#kd $$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt}?@|}yp K$IfgdW K$$$Ifgd~$zkd$$Ifedq7~El4~& t0644 lalf4itq7~Ep ytA'}~mdd K$IfgdWkd^$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt"}~ȃ!ۄ܄ȷ螺mmm[J9JJ9m hUhZ#CJOJQJ^JaJ hUhZ#CJOJQJ^JaJ#hUh#>*CJOJQJ^JaJ$hUh#0J,CJOJQJ^JaJ hUh#CJOJQJ^JaJ$hUh#0J1CJOJQJ^JaJ$hUh#0J+CJOJQJ^JaJ hUh"CJOJQJ^JaJ*hUh"0J,6CJOJQJ]^JaJ hUhA'CJOJQJ^JaJ hUh"CJOJQJ^JaJȃmee\\ K$IfgdWKedq7~Egd#kd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt"ۄmeY K$$$Ifgd~$Medq7~EgdZ#kd$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytZ#ۄ܄yp K$IfgdW K$$$Ifgd~$zkd$$Ifedq7~El4~& t0644 lalf4itq7~Ep ytZ#-.ER]ouЅܸ˥{h{h{h{h{h{WB)jhUh#SCJOJQJU^JaJ hUh#SCJOJQJ^JaJ$hUhrP0J,CJOJQJ^JaJ hUhrPCJOJQJ^JaJ0hUhrP0J+56CJOJQJ\]^JaJ$hUhrP0J+CJOJQJ^JaJ$hUhZ#0J6CJOJQJ^JaJ hUhZ#CJOJQJ^JaJ hUhZ#CJOJQJ^JaJ$hUhZ#0J,CJOJQJ^JaJmdd K$IfgdWkd$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytZ#me\\ $IfgdWMedq7~Egd#kd$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytZ#.Ɔ8wphh`SKKKedq7~Egd< v $ edq7~EgdIpKedq7~EgdZ#Kedq7~EgdrPkd$$Ifedq7~El0y ~& t0644 lalitq7~EpytZ# 567>BCHIfghost¯‹s¯‹[¯‹H$hUhrP0J,CJOJQJ^JaJ/j2hUh#SCJOJQJU^JaJ/jhUh#SCJOJQJU^JaJ hUhrPCJOJQJ^JaJ$hUhrP0JCJOJQJ^JaJ$hUh#S0JCJOJQJ^JaJ)jhUh#SCJOJQJU^JaJ/j@hUh#SCJOJQJU^JaJ hUh#SCJOJQJ^JaJņƆʆ)7DEjkluvwudLu9u$hUh10JCJOJQJ^JaJ/jhUh#SCJOJQJU^JaJ hUh#SCJOJQJ^JaJ)jhUh#SCJOJQJU^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ#hUh10J15CJOJQJaJhUh1CJOJQJaJhUh\CJOJQJaJ hUhZ#CJOJQJ^JaJ hUh\CJOJQJ^JaJw9+gh K$IfgduKedq7~Egdom K$edq7~Egd0edq7~Egd< vedq7~EgdAE w·҇ڇ*ƈԈ 'GTȉΉ܉NJȊɊъҊ ว|kZ hUhIpCJOJQJ^JaJ hUh\CJOJQJ^JaJ$hUhH-K0JCJOJQJ^JaJ/j4hUhH-KCJOJQJU^JaJ hUhH-KCJOJQJ^JaJ)jhUhH-KCJOJQJU^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJhUh1CJOJQJaJ##*+DEMXehijsԋǶn[J9( hUhfCJOJQJ^JaJ hUhrCJOJQJ^JaJ hUhrCJOJQJ^JaJ$hUhr0J,CJOJQJ^JaJ$hUhjH0J,CJOJQJ^JaJ hUhWCJOJQJ^JaJ$hUhW0J,CJOJQJ^JaJ hUhXCJOJQJ^JaJ hUhWCJOJQJ^JaJ$hUhW0J+CJOJQJ^JaJ$hUh0J1CJOJQJ^JaJ$hUh0J+CJOJQJ^JaJhijme\ K$Ifgd Medq7~EgdjHkd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt1RՋ֋|| K$Ifgd zkd{$$Ifedq7~El4~& t0644 lalf4itq7~Ep yt1Rԋ֋׋   ɌʌͺͺͩvcRARA0 hUh2CJOJQJ^JaJ hUhuCJOJQJ^JaJ hUhuCJOJQJ^JaJ$hUhu0J,CJOJQJ^JaJ hUh>9CJOJQJ^JaJ hUh>9CJOJQJ^JaJ hUhCJOJQJ^JaJ hUhfCJOJQJ^JaJ$hUhf0J,CJOJQJ^JaJ hUhfCJOJQJ^JaJ hUh2CJOJQJ^JaJ hUh2CJOJQJ^JaJ֋׋  mdd K$Ifgd kd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt1R  meUK$$(($Ifgd~$Medq7~Egdukd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt1Ruh K(($Ifgd0K$$(($Ifgd~$zkd$$Ifedq7~El4~& t0644 lalf4itq7~Ep yt1RȌɌm]P K(($Ifgd0K$$(($Ifgd~$kd#$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt1RɌʌm]P K(($Ifgd0K$$(($Ifgd~$kd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt1R?@AJK\^_wЍҍӍ˺|i˺˺X hUhCJOJQJ^JaJ$hUh20JCJOJQJ^JaJ/jEhUh#SCJOJQJU^JaJ hUh#SCJOJQJ^JaJ)jhUh#SCJOJQJU^JaJ hUh2CJOJQJ^JaJ hUhuCJOJQJ^JaJ hUhuCJOJQJ^JaJ$hUh20J,CJOJQJ^JaJ]^m]P K(($Ifgd0K$$(($Ifgd~$kd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt1R^_m]P K(($Ifgd0K$$(($Ifgd~$kd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt1Rэҍk^^ K(($Ifgd0kd$$Ifedq7~El4 0y ~& t0644 lalf4itq7~EpytJxzҍӍ֎׎kcZQ K$Ifgd2 K$Ifgd.e6Kedq7~Egd2kd@$$Ifedq7~El4 0y ~& t0644 lalf4itq7~EpytJxz%,=KWdՎ׎؎َ/08:;TVWbcde˸˖˅ttatatNt$hUhu0J6CJOJQJ^JaJ$hUhu0J,CJOJQJ^JaJ hUhuCJOJQJ^JaJ hUhuCJOJQJ^JaJ hUh2CJOJQJ^JaJ hUh.e6CJOJQJ^JaJ$hUh20J,CJOJQJ^JaJ hUh2CJOJQJ^JaJ hUhCJOJQJ^JaJ$hUh0J,CJOJQJ^JaJ׎؎َߎme\\ K$IfgduMedq7~Egd.e6kd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt1R/meY K$$$Ifgd~$Medq7~Egdukd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epytu/09:yp K$Ifgdu K$$$Ifgd~$zkdf$$Ifedq7~El4~& t0644 lalf4itq7~Ep ytu:;UVmdd K$Ifgdukd$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytuVWXcdmaXX $Ifgdu Kedq7~Egdukd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epytudeˏ\phh`W``K K$$$IfgdJF $edq7~EgdtKedq7~EgduKedq7~Egd2kdp$$Ifedq7~El0y ~& t0644 lalitq7~Epytue{ˏ18HY\ɶɥn]J]J]9 hUhy^CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10J1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ hUhYvWCJOJQJ^JaJ hUh\CJOJQJ^JaJ$hUh0J,CJOJQJ^JaJ hUhCJOJQJ^JaJ$hUh0J1CJOJQJ^JaJ$hUh0J+CJOJQJ^JaJ#$yp K$IfgdUR K$$$IfgdJFzkd&$$Ifedq7~El4~& t0644 lalf4itq7~Ep yt1R"$%<ESdej{ؑڑۑABC޺˩޺tatatP? hUhfvCJOJQJ^JaJ hUh MCJOJQJ^JaJ$hUh M0J,CJOJQJ^JaJ hUh MCJOJQJ^JaJ$hUht 0J,CJOJQJ^JaJ hUht CJOJQJ^JaJ hUhCJOJQJ^JaJ hUhURCJOJQJ^JaJ$hUhUR0J,CJOJQJ^JaJ hUhURCJOJQJ^JaJ hUhy^CJOJQJ^JaJ$%ّڑmd[ K$IfgdUR K$Ifgdt kd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt1Rڑۑ@Akbb K$IfgdURkdz$$Ifedq7~El4 0y ~& t0644 lalf4itq7~Epyt1RABCIJkcZZ K$IfgdsMedq7~Egdfvkd4$$Ifedq7~El4 0y ~& t0644 lalf4itq7~Epyt1RCJKВђҒݒޒߒ/CN˸ޒn[n[n[n[nJ hUh\CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10J1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ$hUhs0J6CJOJQJ^JaJ$hUhUR0J,CJOJQJ^JaJ$hUhs0J,CJOJQJ^JaJ hUhsCJOJQJ^JaJ hUhsCJOJQJ^JaJJKLmeY K$$$IfgdJFMedq7~Egdskd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyts|| K$Ifgdszkd$$Ifedq7~El4~& t0644 lalf4itq7~Ep ytsВђmdd K$IfgdskdB$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytsђҒӒޒߒme\\ $IfgdsMedq7~Egdskd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epytsߒk/Uphhh`W``Oedq7~EgdAE $edq7~Egd:edq7~Egdc Kedq7~Egdukd$$Ifedq7~El0y ~& t0644 lalitq7~Epyts /;BFTabENW^ktו o\MhUh1CJOJQJaJ$hUh10JCJOJQJ^JaJ/jdhUh#SCJOJQJU^JaJ hUh#SCJOJQJ^JaJ)jhUh#SCJOJQJU^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJhUh1CJOJQJaJhUh\CJOJQJaJ hUhc CJOJQJ^JaJV+O K$Ifgd4Kedq7~Egd4 K$edq7~Egd4edq7~Egdc GPcqƖ%0@DT *+EǶNjziV$hUh10J+CJOJQJ^JaJ hUh:CJOJQJ^JaJ hUh\CJOJQJ^JaJ$hUhH-K0JCJOJQJ^JaJ/jhUhH-KCJOJQJU^JaJ hUhH-KCJOJQJ^JaJ)jhUhH-KCJOJQJU^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJENOhiq|!#$+JLMNǶn]nnL hUh1CJOJQJ^JaJ hUhCJOJQJ^JaJ$hUhX0J,CJOJQJ^JaJ hUh4CJOJQJ^JaJ$hUh40J,CJOJQJ^JaJ hUhXCJOJQJ^JaJ hUh4CJOJQJ^JaJ$hUh40J+CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ$hUh10J1CJOJQJ^JaJmeY K$$$IfgdJFMedq7~Egd4kdz$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt1R"#yp K$Ifgd4 K$$$IfgdJFzkd0$$Ifedq7~El4~& t0644 lalf4itq7~Ep yt1R#$KLmdd K$Ifgd4kd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt1RLMNkcW K$$$IfgdJFMedq7~Egdvkd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt1RN]f™689LMNopq|}~ﺩra hUh1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ$hUhv0J6CJOJQJ^JaJ hUhfCJOJQJ^JaJ hUhfCJOJQJ^JaJ hUhvCJOJQJ^JaJ hUhU'NCJOJQJ^JaJ$hUhv0J,CJOJQJ^JaJ hUhvCJOJQJ^JaJ| K$Ifgdvzkd>$$Ifedq7~El4~& t0644 lalf4itq7~Ep ytv{rr K$IfgdtMedq7~Egdf|kd$$Ifedq7~El4 ~& t0644 lalf4itq7~Ep ytU'N™ÙmbV K$$$IfgdJF M$$edq7~Egdvkd~$$Ifedq7~El40y ~& t0644 lalf4itq7~Epytfyp K$Ifgdv K$$$IfgdJFzkd4$$Ifedq7~El4~& t0644 lalf4itq7~Ep ytv78maX K$Ifgdv K$$$IfgdJFkd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epytv89LMmaX K$Ifgdv K$$$IfgdJFkd$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytvMNopmdd K$Ifgdvkd>$$Ifedq7~El40y ~& t0644 lalf4itq7~Epytvpqr}~maXX $Ifgdv Kedq7~Egdvkd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epytv~ϛZphhh_WWWKedq7~Egds K$edq7~EgdsKedq7~Egd4kd$$Ifedq7~El0y ~& t0644 lalitq7~Epytvۚܚݚ"#9<SgǶNjwfUD hUh[oCJOJQJ^JaJ hUh\CJOJQJ^JaJ hUhkLCJOJQJ^JaJ'hUh10J6CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ/j`hUh#SCJOJQJU^JaJ hUh#SCJOJQJ^JaJ)jhUh#SCJOJQJU^JaJ hUh1CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJśΛϛIWZǜ '+wxyzɶɶnnnn] hUhbFCJOJQJ^JaJ hUh~PCJOJQJ^JaJ$hUh~P0J,CJOJQJ^JaJ hUh~PCJOJQJ^JaJ$hUh~P0J+CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10J1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJyp K$Ifgd~Pzkd$$Ifedq7~El4~& t0644 lalf4itq7~Ep yt~P K$$$IfgdJFw{oo K$$$IfgdJFMedq7~Egd~P|kd$$Ifedq7~El4 ~& t0644 lalf4itq7~Ep yt~Pwxy| K$Ifgd~Pzkd!$$Ifedq7~El4~& t0644 lalf4itq7~Ep yt~Pyz{ם؝{of K$IfgdbF K$$$IfgdJFMedq7~EgdbF|kd$$Ifedq7~El4 ~& t0644 lalf4itq7~Ep yt~Pԝ՝֝؝ٝ 49Du~ܺ˧ܺ˖rrraP hUhprCJOJQJ^JaJ hUhprCJOJQJ^JaJ hUhDf|CJOJQJ^JaJ$hUhAP0J,CJOJQJ^JaJ hUhAPCJOJQJ^JaJ$hUhuN0J,CJOJQJ^JaJ hUhbFCJOJQJ^JaJ hUhuNCJOJQJ^JaJ hUhbFCJOJQJ^JaJ$hUhbF0J,CJOJQJ^JaJ؝ٝmaX K$IfgdbF K$$$IfgdbFkda$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytbFmeY K$$$IfgdJFMedq7~EgduNkd$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytbFyp K$Ifgdpr K$$$IfgdJFzkd$$Ifedq7~El4~& t0644 lalf4itq7~Ep ytprǞ̞͞ΞϞOPͺͩ͘ͺ͇ͩ͘veTC hUhCJOJQJ^JaJ hUhCJOJQJ^JaJ hUhfCJOJQJ^JaJ hUhfCJOJQJ^JaJ hUhDf|CJOJQJ^JaJ hUhprCJOJQJ^JaJ hUhAPCJOJQJ^JaJ$hUhpr0J,CJOJQJ^JaJ hUhprCJOJQJ^JaJ hUh]`CJOJQJ^JaJ hUh]`CJOJQJ^JaJ̞ΞmaX K$Ifgdpr K$$$IfgdJFkdk$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytprΞϞmdd K$Ifgdprkd!$$Ifedq7~El40y ~& t0644 lalf4itq7~Epytprme\\ K$IfgdtMedq7~Egdfkd$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytprOmeY K$$$IfgdJFMedq7~Egdkd$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytfOPYZyp K$Ifgd K$$$IfgdJFzkdC$$Ifedq7~El4~& t0644 lalf4itq7~Ep ytPXZ[tvw̟՟01R˺r_r_r_rJ9 hUhcHCJOJQJ^JaJ)jhUhcHCJOJQJU^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ hUhxoCJOJQJ^JaJ$hUhxo0J6CJOJQJ^JaJ hUhxoCJOJQJ^JaJ hUhCJOJQJ^JaJ hUhCJOJQJ^JaJ$hUh0J,CJOJQJ^JaJZ[uvmaX K$Ifgd K$$$Ifgdkd$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytvwxmaXX $Ifgd Kedq7~Egdxokd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt۠9phhh_WK K$$$IfgdJFKedq7~Egdt K$edq7~EgdtKedq7~EgdskdM$$Ifedq7~El0y ~& t0644 lalitq7~EpytxoRSTnqrڠ۠ҿҚveR?,?,?$hUh10J1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ$hUh0J+CJOJQJ^JaJ hUh#sCJOJQJ^JaJ hUh\CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ'hUh10J6CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ)jhUhcHCJOJQJU^JaJ/jhUhcHCJOJQJU^JaJ9:IRqr  @ABMNOPf޺raN$hUh10J+CJOJQJ^JaJ hUhxoCJOJQJ^JaJ$hUhxo0J6CJOJQJ^JaJ hUhxoCJOJQJ^JaJ$hUh.h0J,CJOJQJ^JaJ hUh.hCJOJQJ^JaJ hUh.hCJOJQJ^JaJ$hUhI0J,CJOJQJ^JaJ hUhICJOJQJ^JaJ hUhICJOJQJ^JaJ9:pqyp K$IfgdI K$$$IfgdJFzkd$$Ifedq7~El4~& t0644 lalf4itq7~Ep ytIqrmaX K$IfgdI K$$$IfgdIkd"$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytIme\\ K$Ifgd.hMedq7~Egd.hkd$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytI mbV K$$$IfgdJF M$$edq7~Egd.hkd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt.h  yp K$Ifgd.h K$$$IfgdJFzkdD$$Ifedq7~El4~& t0644 lalf4itq7~Ep yt.h@Amdd K$Ifgd.hkd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt.hABCNOmaXX $Ifgd Kedq7~Egdxokd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt.hOPuףUkphhh_WWOWedq7~EgdAEedq7~Egd\ $edq7~Egd:Kedq7~EgdtkdN$$Ifedq7~El0y ~& t0644 lalitq7~Epytxo ftĢˢw£֣ףܸwwfQf)jhUhcHCJOJQJU^JaJ hUhcHCJOJQJ^JaJ#hUh10J15CJOJQJaJhUh1CJOJQJaJhUh\CJOJQJaJ hUh\CJOJQJ^JaJ hUh\CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10J1CJOJQJ^JaJ"#()FGHOSTUkϤ֤ҿқҊrҿқcPPPPPPPP$hUh10J,CJOJQJ^JaJhUh1CJOJQJaJ/j}hUhcHCJOJQJU^JaJ hUhcHCJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ$hUhcH0JCJOJQJ^JaJ)jhUhcHCJOJQJU^JaJ/jhUhcHCJOJQJU^JaJ efŦȦզ֦٦ǶNjziVE2E$hUh0J,CJOJQJ^JaJ hUhCJOJQJ^JaJ$hUh0J+CJOJQJ^JaJ hUh:CJOJQJ^JaJ hUh\CJOJQJ^JaJ$hUhH-K0JCJOJQJ^JaJ/jhUhH-KCJOJQJU^JaJ hUhH-KCJOJQJ^JaJ)jhUhH-KCJOJQJU^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJȦ֦  Ukd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt K$Ifgd*CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ$hUh 0J,CJOJQJ^JaJ$hUh 0J+CJOJQJ^JaJ hUh CJOJQJ^JaJ&hUh 5CJOJQJ\^JaJ hUh CJOJQJ^JaJ$hUh 0J6CJOJQJ^JaJ)KLVWmdd K$Ifgd kdX$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt WXhimdd K$Ifgd kd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt ijuvmdd K$Ifgd kd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt vwmdd K$Ifgd kdz$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt ԭZwmbVV K$$$Ifgd: K$$edq7~Egd:kd0$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt wxyy K$$$Ifgd:zkd$$Ifedq7~El4~& t0644 lalf4itq7~Ep yt maa K$$$Ifgd:kd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt maa K$$$Ifgd:kd:$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt ®ӮԮAOyz{|n޷ަmަʦ\ hUh:CJOJQJ^JaJ$hUh?DP0J,CJOJQJ^JaJ$hUh 0J6CJOJQJ^JaJ$hUh 0J,CJOJQJ^JaJ hUh?DPCJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ'hUh 0J6>*CJOJQJ^JaJ hUh CJOJQJ^JaJ hUh CJOJQJ^JaJmaa K$$$Ifgd:kd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt ®ҮӮmdd K$Ifgd kd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt ӮԮmbVV K$$$Ifgd: K$$edq7~Egd:kd\$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt z{maa K$$$Ifgd:kd $$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt {|md[ K$Ifgd K$Ifgd?DPkd $$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt  meY K$$$Ifgd:Medq7~Egd:kd~!$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt n|  +9S\yz{|ıűƱDZʱӱ      !"#$()ܴܣܣܣܣj)jhUhOCJOJQJU^JaJ$hUhoR0J,CJOJQJ^JaJ hUhoRCJOJQJ^JaJ hUh:CJOJQJ^JaJ'hUh:0J6>*CJOJQJ^JaJ&hUh:5CJOJQJ\^JaJ hUh:CJOJQJ^JaJ$hUh:0J,CJOJQJ^JaJ"  z{|s K$IfgdoR K$Ifgd:zkd4"$$Ifedq7~El4~& t0644 lalf4itq7~Ep yt:{|űƱmdd K$IfgdoRkd"$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt:ƱDZ  mdd K$IfgdoRkd#$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt:  !#maX K$IfgdoR K$$$Ifgd:kd>$$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt:#$md K$IfgdoRkd$$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt:)RST]^gv²òŲƲʲ˲¯žzfzfzfzN¯ž/j(hUhOCJOJQJU^JaJ'hUhoR0J6>*CJOJQJ^JaJ hUhoRCJOJQJ^JaJ$hUhoR0J,CJOJQJ^JaJ hUhoRCJOJQJ^JaJ$hUhoR0JCJOJQJ^JaJ)jhUhOCJOJQJU^JaJ/j%hUhOCJOJQJU^JaJ hUhOCJOJQJ^JaJyp K$Ifgd, K$$$Ifgd,zkd;&$$Ifedq7~El4~& t0644 lalf4itq7~Ep ytoRmaX K$Ifgd, K$$$Ifgd,kd&$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt:òŲmaX K$Ifgd, K$$$Ifgd,kd'$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt:ŲƲmd K$IfgdoRkdE($$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt:0134GHJK^_abxгԳôĴ޷o^o^ hUh CJOJQJ^JaJ hUh CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10J1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ'hUhoR0J6>*CJOJQJ^JaJ hUhoRCJOJQJ^JaJ hUhoRCJOJQJ^JaJ13yp K$Ifgd, K$$$Ifgd,zkd)$$Ifedq7~El4~& t0644 lalf4itq7~Ep ytoR34HJmaX K$Ifgd, K$$$Ifgd,kd*$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt:JK_amaX K$Ifgd, K$$$Ifgd,kd*$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt:abR´ômeeeYP K$Ifgd K$$$Ifgd Kedq7~Egd kd+$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt:ôĴŴmbV K$$$Ifgd M$$edq7~Egd kd@,$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt yp K$Ifgd K$$$Ifgd zkd,$$Ifedq7~El4~& t0644 lalf4itq7~Ep yt 79:EFGH^l*ܸ˥p_PA/#hUh10J15CJOJQJaJhUh1CJOJQJaJhUh\CJOJQJaJ hUh'%CJOJQJ^JaJ hUh\CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10J1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ$hUh 0J6CJOJQJ^JaJ hUh CJOJQJ^JaJ hUh CJOJQJ^JaJ$hUh 0J,CJOJQJ^JaJ89maX K$Ifgd K$$$Ifgd kd-$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt 9:;FGmaXX $Ifgd Kedq7~Egd kdJ.$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt GHm+F[phhh_WWWOedq7~EgdAEedq7~Egd'% $edq7~EgdKKedq7~Egd kd/$$Ifedq7~El0y ~& t0644 lalitq7~Epyt *+7ESZghڶ޶ *1Xf÷ʷ*۳whhUh1CJOJQJaJ$hUh10JCJOJQJ^JaJ/j/hUhOCJOJQJU^JaJ hUhOCJOJQJ^JaJ)jhUhOCJOJQJU^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ%hUh1B*CJOJQJaJph!,@}~Kkd0$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt, K$Ifgd,Kedq7~Egd, K$edq7~Egd,edq7~Egd'%ĸŸ @YꝊyhUBU/$hUh,0J+CJOJQJ^JaJ$hUh10J1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ hUhKCJOJQJ^JaJ hUh\CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUhH-K0JCJOJQJ^JaJ/jG0hUhH-KCJOJQJU^JaJ hUhH-KCJOJQJ^JaJ)jhUhH-KCJOJQJU^JaJYmz~Ĺȹֹ6:OP   ./0;<=>˸rrrrrrr_r$hUhEjr0J6CJOJQJ^JaJ hUhEjrCJOJQJ^JaJ$hUhEjr0J,CJOJQJ^JaJ hUhEjrCJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh,CJOJQJ^JaJ$hUh,0J,CJOJQJ^JaJ hUh,CJOJQJ^JaJĹMOP\kd1$$Ifedq7~El40~&  t0644 lalf4itq7~EpytEjr K$IfgdEjrKedq7~Egd,| K$IfgdEjrzkdD2$$Ifedq7~El4~& t0644 lalf4itq7~Ep ytEjr{rr K$IfgdEjrMedq7~EgdEjr|kd2$$Ifedq7~El4&~& t0644 lalf4itq7~Ep ytEjrmbV K$$$IfgdEjr M$$edq7~EgdEjrkd3$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytEjr  yp K$IfgdEjr K$$$IfgdEjrzkd:4$$Ifedq7~El4~& t0644 lalf4itq7~Ep ytEjr  ./mdd K$IfgdEjrkd4$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytEjr/01<=maXX $IfgdEjr Kedq7~EgdEjrkd5$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytEjr=>cлphhh_WN K$IfgdVvKedq7~EgdEjr K$edq7~EgdEjrKedq7~Egd,kdD6$$Ifedq7~El0y ~& t0644 lalitq7~EpytEjr>Tbcܻ !23ɸrrarPa?rPa hUh[CJOJQJ^JaJ hUhuCJOJQJ^JaJ hUhVvCJOJQJ^JaJ hUhuCJOJQJ^JaJ$hUhu0J,CJOJQJ^JaJ hUhM.CJOJQJ^JaJ hUh\CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUhxCJOJQJ^JaJ$hUh10J1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJyp K$IfgdVv K$$$IfgdVvzkd6$$Ifedq7~El4~& t0644 lalf4itq7~Ep ytu35mdd K$IfgdVvkd7$$Ifedq7~El40y ~& t0644 lalf4itq7~Epytu3456ڽ۽ &-2﫚taN= hUh1CJOJQJ^JaJ$hUh10J1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ$hUh[0J6CJOJQJ^JaJ$hUh[0J,CJOJQJ^JaJ hUh[CJOJQJ^JaJ hUh[CJOJQJ^JaJ hUhVvCJOJQJ^JaJ hUhuCJOJQJ^JaJ hUhuCJOJQJ^JaJ hUhVvCJOJQJ^JaJ56mdd K$IfgdVvkdN8$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytumeYP K$Ifgd[ K$$$Ifgd[Medq7~EgdVvkd9$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytuڽmbV K$$$Ifgd[ M$$edq7~Egd[kd9$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt[ڽ۽yp K$Ifgd[ K$$$Ifgd[zkdp:$$Ifedq7~El4~& t0644 lalf4itq7~Ep yt[maX K$Ifgd[ K$$$Ifgd[kd;$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt[maXX $Ifgd[ Kedq7~Egd[kd;$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt[.%'3ephhhhhhh[ $ edq7~Egd5UKedq7~EgdEjrkdz<$$Ifedq7~El0y ~& t0644 lalitq7~Epyt[ 29`mӾ#,:m{ʿ'5ip'237<NSdeɶɶܥvdvdv#hUh10J15CJOJQJaJhUh1CJOJQJaJhUh\CJOJQJaJ hUh~CJOJQJ^JaJ hUh\CJOJQJ^JaJ$hUh10J1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ'eqx#5]k/0YǶNj|kVE hUhH-KCJOJQJ^JaJ)jhUhH-KCJOJQJU^JaJ hUhJxzCJOJQJ^JaJhUh1CJOJQJaJ$hUh10JCJOJQJ^JaJ/j0=hUhOCJOJQJU^JaJ hUhOCJOJQJ^JaJ)jhUhOCJOJQJU^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJey K$IfgdD1eKedq7~Egd K$edq7~Egd edq7~EgdAEedq7~Egd'% YZ[cdҿҮyfSffSB/$hUh F0J+CJOJQJ^JaJ hUhGCJOJQJ^JaJ$hUh10J1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ hUh5UCJOJQJ^JaJ hUh\CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUhH-K0JCJOJQJ^JaJ)jhUhH-KCJOJQJU^JaJ/j=hUhH-KCJOJQJU^JaJ $%&'6789CDEF_s螺螺$hUh F0J+CJOJQJ^JaJ hUh FCJOJQJ^JaJ&hUh F5CJOJQJ\^JaJ$hUh F0J6CJOJQJ^JaJ$hUh F0J,CJOJQJ^JaJ hUh FCJOJQJ^JaJ2 mdd K$IfgdD1ekdb>$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt F%&mdd K$IfgdD1ekd?$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt F&'78mdd K$IfgdD1ekd?$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt F89DEmdd K$IfgdD1ekd@$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt FEFmdd K$IfgdD1ekd:A$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt Fmdd K$IfgdD1ekdA$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt Fmdd K$IfgdD1ekdB$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt Fmdd K$IfgdD1ekd\C$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt Fmdd K$IfgdD1ekdD$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt Fmdd K$IfgdD1ekdD$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt F"()meYP K$IfgdD1e K$$$IfgdD1eKedq7~Egd kd~E$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt F")*xy4˺˺˺˺˔˺nYH hUhOCJOJQJ^JaJ)jhUhOCJOJQJU^JaJ$hUh10J1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ$hUhuz0J6CJOJQJ^JaJ$hUhuz0J,CJOJQJ^JaJ hUhuzCJOJQJ^JaJ hUhuzCJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ)*+xmbV K$$$IfgdD1e M$$edq7~Egduzkd4F$$Ifedq7~El40y ~& t0644 lalf4itq7~Epytuzxyyp K$IfgdD1e K$$$IfgdD1ezkdF$$Ifedq7~El4~& t0644 lalf4itq7~Ep ytuzmaX K$IfgdD1e K$$$IfgdD1ekdG$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytuzmaXX $IfgdD1e Kedq7~Egduzkd>H$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytuzKfwphhhh_WN K$IfgdKedq7~EgdD1e K$edq7~EgdD1eKedq7~Egd kdH$$Ifedq7~El0y ~& t0644 lalitq7~Epytuz456ABip8IKefҿҮyfSfSf$hUh10J1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ hUhtWCJOJQJ^JaJ hUh\CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ)jhUhOCJOJQJU^JaJ/jIhUhOCJOJQJU^JaJ !2@BCDETUVW`abcrstuܶܢܑܑܑܑܑܑܑܑܑܑܶܶܶܶܶܶܶܶܶ hUhCJOJQJ^JaJ&hUh5CJOJQJ\^JaJ$hUh0J6CJOJQJ^JaJ$hUh0J,CJOJQJ^JaJ hUhCJOJQJ^JaJ$hUh0J+CJOJQJ^JaJ3dkd#J$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt K$IfgdCJOJQJ^JaJab|s K$Ifgdܸp]p]pJ6&hUhM5CJOJQJ\^JaJ$hUhM0J+CJOJQJ^JaJ$hUh10J1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ$hUho0J+CJOJQJ^JaJ hUhLNCJOJQJ^JaJ hUh\CJOJQJ^JaJ hUhMCJOJQJ^JaJ$hUhM0J6CJOJQJ^JaJ hUhMCJOJQJ^JaJ$hUhM0J,CJOJQJ^JaJ<=ph_WNN K$IfgdMKedq7~EgdM M$edq7~EgdMedq7~EgdLNkdoU$$Ifedq7~El0y ~& t0644 lalitq7~EpytM=>NOmdd K$IfgdMkd%V$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytM>MNOPYZ[\klmnxyz{   Yf˸˸$hUhB 0J,CJOJQJ^JaJ hUhB CJOJQJ^JaJ$hUhM0J,CJOJQJ^JaJ$hUhM0J+CJOJQJ^JaJ hUhMCJOJQJ^JaJ$hUhM0J6CJOJQJ^JaJ hUhMCJOJQJ^JaJ2OPZ[mdd K$IfgdMkdV$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytM[\lmmdd K$IfgdMkdW$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytMmnyzmdd K$IfgdMkdGX$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytMz{mdd K$IfgdMkdX$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytMmdd K$IfgdMkdY$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytMmdd K$IfgdMkdiZ$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytMmdd K$IfgdMkd[$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytM  mdd K$IfgdMkd[$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytM  mdd K$IfgdMkd\$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytMmeYP K$IfgdM K$$$IfgdB Medq7~EgdMkdA]$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytMmd K$IfgdMkd]$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytM (*+޺ާ͖r_L_9޺ާ$hUhB 0J+CJOJQJ^JaJ$hUh10J1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ$hUho0J+CJOJQJ^JaJ hUhoCJOJQJ^JaJ hUh\CJOJQJ^JaJ$hUhB 0J6CJOJQJ^JaJ$hUhB 0J,CJOJQJ^JaJ hUhB CJOJQJ^JaJ hUhB CJOJQJ^JaJ hUhMCJOJQJ^JaJ{of K$IfgdB K$$$IfgdB Medq7~EgdB |kd^$$Ifedq7~El4~& t0644 lalf4itq7~Ep ytB m^UU $IfgdB K$$edq7~EgdB kdO_$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytB +,ph_WNN K$IfgdB Kedq7~EgdB K$edq7~EgdB Kedq7~EgdMkd`$$Ifedq7~El0y ~& t0644 lalitq7~EpytB +,-<=>?HIJKZ[\]ghij!3﷤﷤$hUhB 0J,CJOJQJ^JaJ$hUhB 0J+CJOJQJ^JaJ hUhB CJOJQJ^JaJ$hUhB 0J6CJOJQJ^JaJ&hUhB 5CJOJQJ\^JaJ hUhB CJOJQJ^JaJ2,-=>mdd K$IfgdB kd`$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytB >?IJmdd K$IfgdB kdqa$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytB JK[\mdd K$IfgdB kd'b$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytB \]himdd K$IfgdB kdb$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytB ijmdd K$IfgdB kdc$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytB mdd K$IfgdB kdId$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytB mdd K$IfgdB kdd$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytB mdd K$IfgdB kde$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytB mdd K$IfgdB kdkf$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytB mdd K$IfgdB kd!g$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytB me\ K$IfgdB Medq7~EgdB kdg$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytB | K$IfgdB zkdh$$Ifedq7~El4~& t0644 lalf4itq7~Ep ytB  "$%0123IWXsͼͼͼͼ͖ͼp_N;N$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUhXCJOJQJ^JaJ$hUh10J1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ$hUhB 0J6CJOJQJ^JaJ$hUhB 0J,CJOJQJ^JaJ hUhB CJOJQJ^JaJ hUhB CJOJQJ^JaJ hUhDrstuv}~ܸppp__N__p_p_ hUhIQCJOJQJ^JaJ hUhw+CJOJQJ^JaJ$hUhw+0J,CJOJQJ^JaJ hUhw+CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUhrCJOJQJ^JaJ$hUhr0J,CJOJQJ^JaJ hUhrCJOJQJ^JaJ$hUhr0J+CJOJQJ^JaJrst|s K$Ifgd zkdy|$$Ifedq7~El4~& t0644 lalf4itq7~Ep ytw+ K$Ifgdw+tuv|}{rr K$Ifgd Medq7~Egdw+|kd}$$Ifedq7~El4&~& t0644 lalf4itq7~Ep ytw+}~mbV K$$$Ifgd M$$edq7~Egdw+kd}$$Ifedq7~El40y ~& t0644 lalf4itq7~Epytw+yp K$Ifgd K$$$Ifgd zkdo~$$Ifedq7~El4~& t0644 lalf4itq7~Ep ytw+mdd K$Ifgd kd $$Ifedq7~El40y ~& t0644 lalf4itq7~Epytw+maXX $Ifgd Kedq7~Egdw+kd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epytw+)7KRbh  *3=FW]t˸p_N hUhygCJOJQJ^JaJ hUhFCJOJQJ^JaJ hUh\CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10J1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ hUhw+CJOJQJ^JaJ$hUhw+0J6CJOJQJ^JaJ hUhw+CJOJQJ^JaJ8 =tphhh_WWN K$Ifgd fKedq7~Egd  K$edq7~Egd Kedq7~Egdrkdy$$Ifedq7~El0y ~& t0644 lalitq7~Epytw+01234;<˸˸rr_r_rLr$hUh{k%0J6CJOJQJ^JaJ$hUh{k%0J,CJOJQJ^JaJ hUh{k%CJOJQJ^JaJ hUh{k%CJOJQJ^JaJ hUhSzCJOJQJ^JaJ$hUhyg0J6CJOJQJ^JaJ$hUhyg0J6CJOJQJ^JaJ hUhygCJOJQJ^JaJ hUhygCJOJQJ^JaJ$hUhyg0J,CJOJQJ^JaJ K$Ifgd fqkd/$$Ifl4~& t0644 lalf4p yto80 K$Ifgd fskd$$Ifl4 ~& t0644 lalf4p yto8012 K$Ifgd fqkdM$$Ifl4~& t0644 lalf4p yto8234:;wn K$Ifgd K$$$Ifgd Medq7~EgdSzskdڂ$$Ifl4 ~& t0644 lalf4p yto8;<=mbV K$$$Ifgd M$$edq7~Egd{k%kdk$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt{k%yp K$Ifgd K$$$Ifgd zkd!$$Ifedq7~El4~& t0644 lalf4itq7~Ep yt{k%maX K$Ifgd K$$$Ifgd kd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt{k%maXX $Ifgd Kedq7~Egd{k%kdu$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt{k%L ?&2Msphhhh``WOedq7~Egd%#S $edq7~EgdZKedq7~Egd Kedq7~EgdSzkd+$$Ifedq7~El0y ~& t0644 lalitq7~Epyt{k% #0  &0>$&126MYgkrɶɶɶɶɶɶɥvɶɶaP hUhOCJOJQJ^JaJ)jhUhOCJOJQJU^JaJhUh1CJOJQJaJhUh\CJOJQJaJ hUh{?CJOJQJ^JaJ hUh\CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10J1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ&*8JwҿҮ{jWD3 hUh CJOJQJ^JaJ$hUh 0J+CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ hUh")CJOJQJ^JaJ hUh\CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJhUh1CJOJQJaJ hUh1CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ)jhUhOCJOJQJU^JaJ/jhUhOCJOJQJU^JaJsw K$Ifgd Kedq7~Egd  K$edq7~Egd edq7~EgdAEedq7~Egd%#S >?GIJcefyz{˸˔r_$hUh 0J6CJOJQJ^JaJ hUh68CJOJQJ^JaJ hUh<>CJOJQJ^JaJ hUh<>CJOJQJ^JaJ$hUh 0J+CJOJQJ^JaJ$hUhJxz0J+CJOJQJ^JaJ hUh CJOJQJ^JaJ hUh CJOJQJ^JaJ$hUh 0J,CJOJQJ^JaJ   me\\ K$Ifgd Kedq7~EgdJxzkdv$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt  me\ K$Ifgd<>Medq7~Egd<>kd,$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt y K$$$Ifgdfzkd$$Ifedq7~El4~& t0644 lalf4itq7~Ep yt<>{rr K$Ifgd Medq7~Egd<>|kd$$Ifedq7~El4~& t0644 lalf4itq7~Ep yt<>>og[ K$$$Ifgd Medq7~Egd kd"$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt >?HIyp K$Ifgd K$$$Ifgd zkdӊ$$Ifedq7~El4~& t0644 lalf4itq7~Ep yt IJdemaX K$Ifgd K$$$Ifgd kdq$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt efyzmaX K$Ifgd K$$$Ifgd kd'$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt z{mdd K$Ifgd kd݌$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt maXX $Ifgd Kedq7~Egd kd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt Yxphhhhhhh_Wedq7~Egd%#S $edq7~EgdrCKedq7~Egd kdI$$Ifedq7~El0y ~& t0644 lalitq7~Epyt (5gh?@AܴxcR:c/jhUhH-KCJOJQJU^JaJ hUhH-KCJOJQJ^JaJ)jhUhH-KCJOJQJU^JaJ$hUh10JCJOJQJ^JaJ/jhUhWCJOJQJU^JaJ hUhWCJOJQJ^JaJ)jhUhWCJOJQJU^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJAIJeuxǴǣtbOǴ> hUhWCJOJQJ^JaJ%hUh1B*CJOJQJaJph#hUh10J15CJOJQJaJhUh1CJOJQJaJhUh\CJOJQJaJ hUhrCCJOJQJ^JaJ hUh\CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ)jhUhH-KCJOJQJU^JaJ$hUhH-K0JCJOJQJ^JaJ!"#*,-.D_m ꮛrꮛcPPPPPPP$hUh10J,CJOJQJ^JaJhUh1CJOJQJaJ/jhUhWCJOJQJU^JaJ hUh1CJOJQJ^JaJ$hUh10JCJOJQJ^JaJ$hUhW0JCJOJQJ^JaJ/j%hUhWCJOJQJU^JaJ hUhWCJOJQJ^JaJ)jhUhWCJOJQJU^JaJ.D K$IfgdfKedq7~EgdLU K$edq7~EgdLUedq7~EgdAEedq7~Egd%#S&IMIJstu}~˸˸˸ˣzg˸VE hUh5UCJOJQJ^JaJ hUh\CJOJQJ^JaJ$hUhH-K0JCJOJQJ^JaJ/j?hUhH-KCJOJQJU^JaJ hUhH-KCJOJQJ^JaJ)jhUhH-KCJOJQJU^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUh"UCJOJQJ^JaJ$hUh"U0J,CJOJQJ^JaJ 59:NRdr9FklǶځp]p]pLp]p7)jhUhWCJOJQJU^JaJ hUha,CJOJQJ^JaJ$hUha,0J,CJOJQJ^JaJ hUha,CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUhfCJOJQJ^JaJ$hUhf0J,CJOJQJ^JaJ hUhfCJOJQJ^JaJ$hUhf0J+CJOJQJ^JaJ$hUh10J1CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJ:me\ K$Ifgda,Kedq7~EgdLUkdБ$$Ifedq7~El40y ~& t0644 lalf4itq7~Epytfyp K$Ifgdf K$$$Ifgdfzkd$$Ifedq7~El4~& t0644 lalf4itq7~Ep yta,l!+PQopq}~¯ž|i|X|i|i|@¯|X/j hUhWCJOJQJU^JaJ hUha,CJOJQJ^JaJ$hUha,0J,CJOJQJ^JaJ hUha,CJOJQJ^JaJ hUhfCJOJQJ^JaJ hUhfCJOJQJ^JaJ$hUha,0JCJOJQJ^JaJ)jhUhWCJOJQJU^JaJ/j$hUhWCJOJQJU^JaJ hUhWCJOJQJ^JaJmaX K$Ifgdf K$$$Ifgdfkd$$Ifedq7~El40~&  t0644 lalf4itq7~EpytfmaX K$Ifgdf K$$$IfgdfkdS$$Ifedq7~El40~&  t0644 lalf4itq7~EpytfmaX K$Ifgdf K$$$Ifgdfkd$$Ifedq7~El40~&  t0644 lalf4itq7~Epytf()=>?N_fﶥziVCV$hUha,0J1CJOJQJ^JaJ$hUha,0J+CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUha,0JCJOJQJ^JaJ/jhUhWCJOJQJU^JaJ hUhWCJOJQJ^JaJ)jhUhWCJOJQJU^JaJ hUha,CJOJQJ^JaJ$hUha,0J,CJOJQJ^JaJ hUha,CJOJQJ^JaJ<=maX K$Ifgdf K$$$Ifgdfkd:$$Ifedq7~El40~&  t0644 lalf4itq7~Epytf=>?gmeYY K$$$Ifgd rMedq7~Egda,kdi$$Ifedq7~El40~&  t0644 lalf4itq7~Epytf| K$Ifgda,zkd$$Ifedq7~El4~& t0644 lalf4itq7~Ep yta,#$%&'/0FI~ͺޖp]$hUh10J+CJOJQJ^JaJ$hUha,0J6CJOJQJ^JaJ$hUha,0J,CJOJQJ^JaJ hUh'CJOJQJ^JaJ$hUha,0J1CJOJQJ^JaJ$hUha,0J+CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUha,CJOJQJ^JaJ hUha,CJOJQJ^JaJ${o K$$$Ifgd rMedq7~Egda,|kd$$Ifedq7~El4~& t0644 lalf4itq7~Ep yt r$%&| K$Ifgda,zkd_$$Ifedq7~El4~& t0644 lalf4itq7~Ep yta,&'(./{of K$Ifgda, K$$$Ifgd rMedq7~Egda,|kd$$Ifedq7~El4~& t0644 lalf4itq7~Ep yt r/01~odX K$$$Ifgd' M$$edq7~Egd rkd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyta,~yp K$Ifgda, K$$$Ifgd rzkdP$$Ifedq7~El4~& t0644 lalf4itq7~Ep yta,maX K$Ifgda, K$$$Ifgda,kd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyta,maXX $Ifgda, Kedq7~Egda,kd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyta,v7Mphhh_WWOWedq7~EgdAEedq7~Egd%#S $edq7~Egd rKedq7~EgdLUkdZ$$Ifedq7~El0y ~& t0644 lalitq7~Epyta,  )-8EQXuvǶudRDhV*LCJOJQJ^JaJ#jhV*LCJOJQJU^JaJ hUhWCJOJQJ^JaJ#hUh10J15CJOJQJaJhUh1CJOJQJaJhUh\CJOJQJaJ hUhnCJOJQJ^JaJ hUh\CJOJQJ^JaJ)hUh1B* CJOJQJ^JaJphG hUh1CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ*+,3567Ų؎yhPy=*y$hUh10JCJOJQJ^JaJ$hUhW0JCJOJQJ^JaJ/jhUhWCJOJQJU^JaJ hUhWCJOJQJ^JaJ)jhUhWCJOJQJU^JaJ hUh1CJOJQJ^JaJ$hV*Lhok10JCJOJQJ^JaJ$h}h10JCJOJQJ^JaJ$h}hW0JCJOJQJ^JaJ#jhV*LCJOJQJU^JaJ)jhV*LCJOJQJU^JaJ7MMNwxyว|kZG6 hUhkXCJOJQJ^JaJ$hUhkX0J+CJOJQJ^JaJ hUh5UCJOJQJ^JaJ hUh\CJOJQJ^JaJ$hUhH-K0JCJOJQJ^JaJ/jhUhH-KCJOJQJU^JaJ hUhH-KCJOJQJ^JaJ)jhUhH-KCJOJQJU^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJhUh1CJOJQJaJSkd$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytkX K$IfgdkX K$edq7~EgdkXedq7~Egd%#S !:N[_`du|~ܵܤܤܤܤܤܤܤܤܤܤ$hUhkX0J+CJOJQJ^JaJ hUhkXCJOJQJ^JaJ&hUhkX5CJOJQJ\^JaJ$hUhkX0J6CJOJQJ^JaJ hUhkXCJOJQJ^JaJ$hUhkX0J,CJOJQJ^JaJ1mdd K$IfgdkXkdc$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytkXmdd K$IfgdkXkd$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytkX mdd K$IfgdkXkdϡ$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytkX !^_mdd K$IfgdkXkd$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytkX_`mdd K$IfgdkXkd;$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytkXmdd K$IfgdkXkd$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytkXmdd K$IfgdkXkd$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytkXmdd K$IfgdkXkd]$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytkXmdd K$IfgdkXkd$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytkXme\ K$IfgdkXKedq7~EgdkXkdɦ$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytkX"()FGHSTYZxɸnVCn$hUhkX0JCJOJQJ^JaJ/jhUhWCJOJQJU^JaJ hUhWCJOJQJ^JaJ)jhUhWCJOJQJU^JaJ$hUhkX0J,CJOJQJ^JaJ hUhkXCJOJQJ^JaJ hUh2CJOJQJ^JaJ hUh2CJOJQJ^JaJ$hUhJxz0J+CJOJQJ^JaJ$hUh10J+CJOJQJ^JaJzq K$IfgdkX K$$IfgdkXzkd$$Ifedq7~El4~& t0644 lalf4itq7~Ep yt2xyz%&'/0348Fv}ҿқwwfNҬқwwwf/jǩhUhWCJOJQJU^JaJ hUhWCJOJQJ^JaJ$hUhkX0J,CJOJQJ^JaJ hUhkXCJOJQJ^JaJ hUhkXCJOJQJ^JaJ$hUhkX0JCJOJQJ^JaJ$hUhW0JCJOJQJ^JaJ)jhUhWCJOJQJU^JaJ/jhUhWCJOJQJU^JaJ23mbY K$IfgdkX K$$IfgdkXkd$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytJxz34mbY K$IfgdkX K$$IfgdkXkdX$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytJxz"0ҿҮxjUxB$h}hkX0JCJOJQJ^JaJ)jhV*LCJOJQJU^JaJhV*LCJOJQJ^JaJ#jhV*LCJOJQJU^JaJ$hUhkX0J,CJOJQJ^JaJ hUhkXCJOJQJ^JaJ hUhkXCJOJQJ^JaJ$hUhkX0JCJOJQJ^JaJ)jhUhWCJOJQJU^JaJ/jhUhWCJOJQJU^JaJmbY K$IfgdkX K$$IfgdkXkd$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytJxzk`W K$IfgdkX K$$Ifgdok1kd=$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt2+2y  '()45678ʹێyf۫UD hUh: eCJOJQJ^JaJ h: eh: eCJOJQJ^JaJ$hV*Lh: e0JCJOJQJ^JaJ)j&hV*LCJOJQJU^JaJhV*LCJOJQJ^JaJh: e6CJOJQJ^JaJh: eCJOJQJ^JaJ hUhkXCJOJQJ^JaJ hUhkXCJOJQJ^JaJ#jhV*LCJOJQJU^JaJ$hV*Lhok10JCJOJQJ^JaJ78mbY K$IfgdkX K$$Ifgd}kdp$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytJxz89maX K$IfgdkX K$$$IfgdkXkd$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytJxz89=KRSpqr}~ ޶ziXiGiii hUh'CJOJQJ^JaJ hUh1CJOJQJ^JaJ hUhkXCJOJQJ^JaJ$hUhkX0JCJOJQJ^JaJ/jUhUhWCJOJQJU^JaJ hUhWCJOJQJ^JaJ)jhUhWCJOJQJU^JaJ$hUhkX0J,CJOJQJ^JaJ hUhkXCJOJQJ^JaJ hUh: eCJOJQJ^JaJmeYP K$IfgdkX K$$$IfgdkXMedq7~EgdkXkdί$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytJxzodX K$$$Ifgd' M$$edq7~EgdkXkd$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytkXyp K$IfgdkX K$$$IfgdkXzkd5$$Ifedq7~El4~& t0644 lalf4itq7~Ep ytkXmaX K$IfgdkX K$$$IfgdkXkdӱ$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytkXmaXX $IfgdkX Kedq7~EgdkXkd$$Ifedq7~El40y ~& t0644 lalf4itq7~EpytkX  @NO[ijv˺yfUBU1 hUh+QCJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ%hUh1B*CJOJQJaJph#hUh10J15CJOJQJaJhUh1CJOJQJaJhUh\CJOJQJaJ hUh,`CJOJQJ^JaJ hUh\CJOJQJ^JaJ hUhkXCJOJQJ^JaJ hUhkXCJOJQJ^JaJ$hUhkX0J6CJOJQJ^JaJ OjJ`ph_WWOWWedq7~EgdAEedq7~Egd%#S $edq7~EgdkXKedq7~EgdkXkd?$$Ifedq7~El0y ~& t0644 lalitq7~EpytkXvwkZBk/$hUh+Q0JCJOJQJ^JaJ/jnhUh+QCJOJQJU^JaJ hUh+QCJOJQJ^JaJ)jhUh+QCJOJQJU^JaJ hUh1CJOJQJ^JaJ$hV*Lhok10JCJOJQJ^JaJ$h}h10JCJOJQJ^JaJ$h}h+Q0JCJOJQJ^JaJ)jhV*LCJOJQJU^JaJhV*LCJOJQJ^JaJ#jhV*LCJOJQJU^JaJ =>?FHIJ`gض؋ضs؋dQ$hUh10J,CJOJQJ^JaJhUh1CJOJQJaJ/jzhUh+QCJOJQJU^JaJ$hUh+Q0JCJOJQJ^JaJ/jhUh+QCJOJQJU^JaJ hUh+QCJOJQJ^JaJ hUh1CJOJQJ^JaJ)jhUh+QCJOJQJU^JaJ$hUh10JCJOJQJ^JaJghꝊyhUD1D$hUh!EE0J,CJOJQJ^JaJ hUh!EECJOJQJ^JaJ$hUh!EE0J+CJOJQJ^JaJ hUh5UCJOJQJ^JaJ hUh\CJOJQJ^JaJ$hUh10J,CJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUhH-K0JCJOJQJ^JaJ/jhUhH-KCJOJQJU^JaJ hUhH-KCJOJQJ^JaJ)jhUhH-KCJOJQJU^JaJ[kd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt!EE K$Ifgd' K$edq7~EgdpI $%&'12348IWYZ[\klmnwxyzܑܑܷܷܷܷܷܷܷܷܷܷ~$hUh10J+CJOJQJ^JaJ$hUh!EE0J,CJOJQJ^JaJ$hUh!EE0J+CJOJQJ^JaJ hUh!EECJOJQJ^JaJ&hUh!EE5CJOJQJ\^JaJ hUh!EECJOJQJ^JaJ$hUh!EE0J6CJOJQJ^JaJ0 mdd K$Ifgd'kd\$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt!EE%&mdd K$Ifgd'kd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt!EE&'23mdd K$Ifgd'kdȸ$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt!EE34Z[mdd K$Ifgd'kd~$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt!EE[\lmmdd K$Ifgd'kd4$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt!EEmnxymdd K$Ifgd'kd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt!EEyzmdd K$Ifgd'kd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt!EEmdd K$Ifgd'kdV$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt!EEmdd K$Ifgd'kd $$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt!EEme\ K$IfgdW,Kedq7~EgdpIkd½$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt!EE,-JKLWXY[\krͺͺͺͥ|iXGͺ͔ hUhW,CJOJQJ^JaJ hUhW,CJOJQJ^JaJ$hUh5p0JCJOJQJ^JaJ/jhUhXbCJOJQJU^JaJ hUhXbCJOJQJ^JaJ)jhUhXbCJOJQJU^JaJ$hUh5p0J,CJOJQJ^JaJ hUh5pCJOJQJ^JaJ hUh2CJOJQJ^JaJ hUh2CJOJQJ^JaJZ[zq K$IfgdW, K$$IfgdW,zkdx$$Ifedq7~El4~& t0644 lalf4itq7~Ep yt2[\mbY K$IfgdW, K$$IfgdW,kd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt2"156STU`abdet{ҿҮyyhhPҿҮyhh/jthUhXbCJOJQJU^JaJ hUhXbCJOJQJ^JaJ$hUh5p0J,CJOJQJ^JaJ hUhW,CJOJQJ^JaJ hUhW,CJOJQJ^JaJ hUh5pCJOJQJ^JaJ$hUhXb0JCJOJQJ^JaJ)jhUhXbCJOJQJU^JaJ/jEhUhXbCJOJQJU^JaJcdmbY K$IfgdW, K$$IfgdW,kd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt2dembY K$IfgdW, K$$IfgdW,kd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt2 '2459@DJKhijҿҮyykZB/jhUhXbCJOJQJU^JaJ hUhXbCJOJQJ^JaJh*CJOJQJ^JaJ$hUh5p0J,CJOJQJ^JaJ hUhW,CJOJQJ^JaJ hUhW,CJOJQJ^JaJ hUh5pCJOJQJ^JaJ$hUhXb0JCJOJQJ^JaJ)jhUhXbCJOJQJU^JaJ/jhUhXbCJOJQJU^JaJ34mbY K$IfgdW, K$$IfgdW,kd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt245xyk_V K$IfgdW, K$$$Ifgdok1kd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt2jtuvwyz~XYvʹs[عJs hUh5pCJOJQJ^JaJ/jhUhXbCJOJQJU^JaJ hUhXbCJOJQJ^JaJ$hUh5p0J,CJOJQJ^JaJ hUhW,CJOJQJ^JaJ hUhW,CJOJQJ^JaJ hUh5pCJOJQJ^JaJhok1CJOJQJ^JaJ)jhUhXbCJOJQJU^JaJ$hUh5p0JCJOJQJ^JaJyzmaX K$IfgdW, K$$$IfgdW,kd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt2maX K$IfgdW, K$$$IfgdW,kd4$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt2vwx$%&'ҿҮ{j{jW{jW{j{D{j$hUh!EE0J6CJOJQJ^JaJ$hUh!EE0J,CJOJQJ^JaJ hUh!EECJOJQJ^JaJ hUh!EECJOJQJ^JaJ hUh1CJOJQJ^JaJ hUh5pCJOJQJ^JaJ hUh5pCJOJQJ^JaJ$hUh5p0JCJOJQJ^JaJ)jhUhXbCJOJQJU^JaJ/jhUhXbCJOJQJU^JaJme\\ K$Ifgd'Medq7~Egd5pkdc$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt2og[ K$$$Ifgd!EEMedq7~Egd!EEkd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt!EEyp K$Ifgd' K$$$Ifgd'zkd$$Ifedq7~El4~& t0644 lalf4itq7~Ep yt!EEmdd K$Ifgd'kdh$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt!EE%&maXX $Ifgd' Kedq7~Egd!EEkd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt!EE&'31ph_WWOGedq7~Egd*edq7~Egd {edq7~Egd { $edq7~Egd*Kedq7~Egd5pkd$$Ifedq7~El0y ~& t0644 lalitq7~Epyt!EE'2379<CFN   ϲn\N9\)jhV*LCJOJQJU^JaJhV*LCJOJQJ^JaJ#jhV*LCJOJQJU^JaJ$hUh {0J,CJOJQJ^JaJ hUh {CJOJQJ^JaJh}0J15CJOJQJaJ h}0J156CJOJQJaJ h {0J156CJOJQJaJh {CJOJQJaJhUh {CJOJQJaJ hUh6;CJOJQJ^JaJ hUh\CJOJQJ^JaJ 1FNȷsbQC4Qh/6CJOJQJ^JaJh/CJOJQJ^JaJ h*h4"CJOJQJ^JaJ h*hI?CJOJQJ^JaJ#h*h {6CJOJQJ^JaJ h*h {CJOJQJ^JaJhUh {CJOJQJaJ#h*h {>*CJOJQJ^JaJ hI?hI?CJOJQJ^JaJ#jhV*LCJOJQJU^JaJ$hV*LhI?0JCJOJQJ^JaJ$hV*Lh {0JCJOJQJ^JaJ $9@IPﾱ}j}W}C}W}&hUh {5CJOJQJ\^JaJ$hUh {0J6CJOJQJ^JaJ$hUh {0J,CJOJQJ^JaJ hUh {CJOJQJ^JaJ$hUh {0J+CJOJQJ^JaJh*h {5CJOJQJaJh {5CJOJQJaJ h/h/CJOJQJ^JaJh4"CJOJQJ^JaJ#hOh4"6CJOJQJ^JaJ hI?h4"CJOJQJ^JaJ Pkd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt { K$Ifgd& $edq7~Egd* 2 & Fedq7~Egdu*Wmdd K$Ifgd&kd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt {!"#$3456?@ABQRST^_`az1ޥޥ︕އyh/CJOJQJ^JaJh {CJOJQJ^JaJh {0J+CJOJQJ^JaJ$hUh {0J,CJOJQJ^JaJ$hUh {0J+CJOJQJ^JaJ$hUh {0J6CJOJQJ^JaJ hUh {CJOJQJ^JaJ hUh {CJOJQJ^JaJ/mdd K$Ifgd&kdo$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt {mdd K$Ifgd&kd%$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt {"#mdd K$Ifgd&kd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt {#$45mdd K$Ifgd&kd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt {56@Amdd K$Ifgd&kdG$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt {ABRSmdd K$Ifgd&kd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt {ST_`mdd K$Ifgd&kd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt {`amdd K$Ifgd&kdi$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt {mcZ K$Ifgd/ Kedq7~Egdok1kd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt {135BOU\]jm    ȹ䚉xggVgggHhok1CJOJQJ^JaJ hUh/CJOJQJ^JaJ hUh/CJOJQJ^JaJ h*h/CJOJQJ^JaJ hUh {CJOJQJ^JaJ hUh {CJOJQJ^JaJh/CJOJQJ^JaJh"U6CJOJQJ^JaJh"UCJOJQJ^JaJh*CJOJQJ^JaJh4"CJOJQJ^JaJh {CJOJQJ^JaJ|| K$Ifgd/zkd$$Ifedq7~El4~& t0644 lalf4itq7~Ep yt {m_QK$Ifgd/oHgK$Ifgd {oHgkds$$Ifedq7~El40W ~& t0644 lalf4itq7~Epyt/m_QK$Ifgd/oHgK$Ifgd {oHgkd)$$Ifedq7~El40W ~& t0644 lalf4itq7~Epyt/m_QK$Ifgd/oHgK$Ifgd {oHgkd$$Ifedq7~El40W ~& t0644 lalf4itq7~Epyt/   md[ K$Ifgd/ K$Ifgd*kd$$Ifedq7~El40W ~& t0644 lalf4itq7~Epyt/    md[ K$Ifgd/ K$Ifgd*kdK$$Ifedq7~El40W ~& t0644 lalf4itq7~Epyt/    m_QK$Ifgd/oHgK$Ifgd {oHgkd$$Ifedq7~El40W ~& t0644 lalf4itq7~Epyt/    m            ? @ S wfwUDUD1$hUh {0J,CJOJQJ^JaJ hUh {CJOJQJ^JaJ hUh {CJOJQJ^JaJ hUh4"CJOJQJ^JaJ hUh4"CJOJQJ^JaJh4"CJOJQJ^JaJh"U6CJOJQJ^JaJh"UCJOJQJ^JaJh*CJOJQJ^JaJh4"5CJOJQJ^JaJ hUh/CJOJQJ^JaJh/CJOJQJ^JaJ hUhok1CJOJQJ^JaJ   m  mcWN K$Ifgd& Mxedq7~Egdok1 Medq7~Egdok1kd$$Ifedq7~El40W ~& t0644 lalf4itq7~Epyt/     }tt K$Ifgd&Medq7~Egd {zkdm$$Ifedq7~El4~& t0644 lalf4itq7~Ep yt4"   ? og[ K$$$Ifgd&Medq7~Egd {kd $$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt {? @ S T yp K$Ifgd& K$$$Ifgd&zkd$$Ifedq7~El4~& t0644 lalf4itq7~Ep yt {S T U v w x                / 3 4 ` 縉vvevT?T)jhUhCJOJQJU^JaJ hUhCJOJQJ^JaJ hUhCJOJQJ^JaJ hUhrCJOJQJ^JaJ hUh-CJOJQJ^JaJ hUh1CJOJQJ^JaJhUhCtCJ"OJQJaJ"$hUh {0J6CJOJQJ^JaJ$hUh {0J,CJOJQJ^JaJ hUh {CJOJQJ^JaJ hUh {CJOJQJ^JaJT U v w mdd K$Ifgd&kdZ$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt {w x y   maXX $Ifgd& Kedq7~Egd {kd$$Ifedq7~El40y ~& t0644 lalf4itq7~Epyt {         ph_SSKKKedq7~Egd%#S edq7~Egdr $edq7~EgdCtKedq7~Egd {kd$$Ifedq7~El0y ~& t0644 lalitq7~Epyt {` a b   n o          !"ҿҮҝҿҮnTnnA$hUhZQA0JCJOJQJ^JaJ3jhUh0JCJOJQJU^JaJ-jhUh0JCJOJQJU^JaJ/jEhUhCJOJQJU^JaJ hUhCJOJQJ^JaJ hUh1CJOJQJ^JaJ$hUh0JCJOJQJ^JaJ)jhUhCJOJQJU^JaJ/j|hUhCJOJQJU^JaJ n   "|}opqr   gdj}   gdi-gdR/edq7~Egd-edq7~Egd%#S"#$|}~ƶƯs왒sfhu*W5B*\^Jph jhu*W5CJU\aJ*hv5\mHnHu* hu*W5\jhu*W5CJU\aJ h)jhu*W hhu*Wjh? hu*W0JYU hu*W0JYjh? hu*W0JYUjhr=Uhr= hv%Lhu*Whu*Wjhv%Lhu*W0J/UaJ"  234GHIJOPVWXY]^ijklmnpqrͽͶ࠙t`\I$hUhZQA0JCJOJQJ^JaJhr='jh@hu*W5U^JmHnHuhu*W5B*\^Jphh6w65\mHnHuhu*W5\mHnHu hu*W5\jhu*W5CJU\aJ h)jhu*W hhu*Wj^h? hu*W0JYU hu*W0JYjh? hu*W0JYUhu*W hj}hu*W'jh@hu*W5U^JmHnHu61h/R :p7. A!n"n#M $4% 61h/R :p7. A!n"n#M $4% 61h/R :p7. A!n"n#M $4% }DyK _Toc462057928}DyK _Toc462057929}DyK _Toc462057930}DyK _Toc462057931}DyK _Toc462057932}DyK _Toc462057933}DyK _Toc462057934}DyK _Toc462057935}DyK _Toc462057936}DyK _Toc462057937}DyK _Toc462057938}DyK _Toc462057939}DyK _Toc462057940}DyK _Toc462057941}DyK _Toc462057942}DyK _Toc462057943}DyK _Toc462057944}DyK _Toc462057945}DyK _Toc462057946}DyK _Toc462057947}DyK _Toc462057948}DyK _Toc462057949}DyK _Toc462057950}DyK _Toc462057951}DyK _Toc462057952}DyK _Toc462057953}DyK _Toc462057954}DyK _Toc462057955}DyK _Toc462057956}DyK _Toc462057957}DyK _Toc462057958}DyK _Toc462057959}DyK _Toc462057960}DyK _Toc462057961}DyK _Toc462057962}DyK _Toc462057963}DyK _Toc462057964}DyK _Toc462057965}DyK _Toc462057966}DyK _Toc462057967}DyK _Toc462057968}DyK _Toc462057969}DyK _Toc462057970}DyK _Toc462057971}DyK _Toc462057972}DyK _Toc462057973}DyK _Toc462057974}DyK _Toc462057975}DyK _Toc462057976}DyK _Toc462057977}DyK _Toc462057978}DyK _Toc462057979}DyK _Toc462057980}DyK _Toc462057981}DyK _Toc462057982}DyK _Toc462057983}DyK _Toc462057984}DyK _Toc462057985}DyK _Toc462057986}DyK _Toc462057987}DyK _Toc462057988}DyK _Toc462057989}DyK _Toc462057990}DyK _Toc462057991}DyK _Toc462057992}DyK _Toc462057993}DyK _Toc462057994}DyK _Toc462057995}DyK _Toc462057996}DyK _Toc462057997}DyK _Toc462057998}DyK _Toc462057999}DyK _Toc462058000}DyK _Toc462058001}DyK _Toc462058002}DyK _Toc462058003}DyK _Toc462058004}DyK _Toc462058005}DyK _Toc462058006}DyK _Toc462058007}DyK _Toc462058008}DyK _Toc462058009}DyK _Toc462058010}DyK _Toc462058011}DyK _Toc462058012}DyK _Toc462058013}DyK _Toc462058014}DyK _Toc462058015}DyK _Toc462058016}DyK _Toc462058017}DyK _Toc462058018}DyK _Toc462058019}DyK _Toc462058020}DyK _Toc462058021}DyK _Toc462058022}DyK _Toc462058023}DyK _Toc462058024}DyK _Toc462058025DyK _Part_D:_Forms_1DyK yK >http://www.consumer.vic.gov.auDyK _1._Definitions_3DyK _Part_B:_Terms$$Ifl!vh#v #v:V l44 t0655 alf4pyt1NDyK _Cooling-off_period_notice_1DyK _Cooling-off_period_notice_2$$Ifl!vh#v #v:V l4 t0655 alf4pyt1NDyK _Part_A:_Check$$Ifl!vh#v #v:V l4 t0655 alf4pyt1NDyK _Part_B:_Terms_1$$Ifl!vh#v #v:V l4 t0655 alf4pyt1NDyK _Part_C:_Legislation_1DyK _Section_37_ _1}DyK _Section_40_ $$Ifl!vh#v #v:V l4 t0655 alf4pyt1NDyK _Document_List_Attachment_1DyK _Document_List_Attachment_2DyK _General_Attachment_1$$Ifl!vh#v #v:V l4 t0655 alf4pyt1N$$Ifl!vh#v #v:V l4 t0655 alf4pyt1N$$Ifl!vh#v #v:V l4 t0655 alf4pyt1NDyK _Prime_Cost_Items_1$$Ifl!vh#v #v:V l4 t0655 alf4pyt1NDyK _Provisional_Sums_Schedule_1$$Ifl!vh#v #v:V l4 t0655 alf4pyt1NDyK _1._Definitions_1Dd.nr  S AvDotted lineDotted line to indicate where to detach lower half of page#"  bHʯ+tem-xy$? nʯ+tem-xyPNG  IHDR = gAMABOPLTE~~~}}}|||{{{zzzyyyxxxwwwvvvuuutttsssrrrqqqpppooonnnmmmlllkkkjjjiiihhhgggfffeeedddcccbbbaaa```___^^^]]]\\\[[[ZZZYYYXXXWWWVVVUUUTTTSSSRRRQQQPPPOOONNNMMMLLLKKKJJJIIIHHHGGGFFFEEEDDDCCCBBBAAA@@@???>>>===<<<;;;:::999888777666555444333222111000///...---,,,+++***)))((('''&&&%%%$$$###"""!!!   pHYs.#.#x?v$tEXtSoftwareQuickTime 7.6.6 (Mac OS X)_tIME -0CI^IDATxm@F@"D `"F`FgTQ%}-2 M3hyZ<0490W/׍ۥ+yͥ/lD"HUFHz9}(%-5*&iHR+ڣu2r?Y*Rfpd~gDC28أ-P̞AO@3dZT,2$A|X4<1zPfcLK22R?+?GHfÈ kdPX;#]wDyK  Clause_8_4uDyK  _FORM_A_ wDyK  Clause_8_4DyK _Section_40_ _2uDyK  _FORM_J_ DyK _Section_40_ _3yDyK  Clause_22_1DyK Table_progress_payments$$Ifedq7~El!vh#v #v :V l4 t065alf4itq7~Ep(yt :$$Ifedq7~El!vh#v #v :V l4 t06+5alf4itq7~Ep(yt :$$Ifedq7~El!vh#v #v :V l4 t06+5alf4itq7~Ep(yt :$$Ifedq7~El!vh#v #v :V l4 t06+5alf4itq7~Ep(yt :$$Ifedq7~El!vh#v #v :V l4 t06+5alf4itq7~Ep(yt :$$Ifedq7~El!vh#v #v :V l4 t06+5alf4itq7~Ep(yt :$$Ifedq7~El!vh#v #v :V l4 t06+5alf4itq7~Ep(yt :$$Ifedq7~El!vh#v #v :V l4 t06+5alf4itq7~Ep(yt :wDyK  Clause_8_4$$Ifedq7~El!vh#v~&:V l4 t065/ alf4itq7~Ep yt2g$$Ifedq7~El!vh#v~&:V l4( t065/ alf4itq7~Ep yt2gDyK _Part_B:_Terms_2DyK _Document_List_Attachment_5DyK _Provisional_Sums_Schedule_3DyK _Document_List_Attachment_6DyK _General_Attachment_3DyK _Document_List_Attachment_7DyK _Document_List_Attachment_8DyK _Part_A:_Check_1$$Ifedq7~El!vh#v~&:V l4 t065alf4itq7~Ep yt&$$Ifedq7~El!vh#v #v:V l4 t0655 alf4itq7~Epyt&$$Ifedq7~El!vh#v #v:V l4S t0655 alf4itq7~EpytKL|$$Ifedq7~El!vh#v #v:V l4 t0655 alf4itq7~Epyt&$$Ifedq7~El!vh#v #v:V l4S t0655 alf4itq7~EpytKL|$$Ifedq7~El!vh#v #v:V l4 t0655 alf4itq7~EpytKL|$$Ifedq7~El!vh#v~&:V l4 t065alf4itq7~Ep ytKL|$$Ifedq7~El!vh#v #v:V l4 t0655 alf4itq7~Epyt4eQ$$Ifedq7~El!vh#v #v:V l4 t0655 alf4itq7~Epyt4eQ$$Ifedq7~El!vh#v #v:V l4 t0655 alf4itq7~Epyt4eQ$$Ifedq7~El!vh#v~&:V l4 t065alf4itq7~Ep ytKL|$$Ifedq7~El!vh#v #v:V l4 t0655 alf4itq7~EpytKL|$$Ifedq7~El!vh#v #v:V l4 t0655 alf4itq7~EpytKL|$$Ifedq7~El!vh#v #v:V l4 t0655 alf4itq7~EpytKL|$$Ifedq7~El!vh#v #v:V l4 t0655 alf4itq7~EpytKL|DyK _Section_30_ _1$$Ifedq7~El!vh#v #v :V l44 t0655alf4itq7~Epytkt$$Ifedq7~El!vh#v #v :V l4 t0655alf4itq7~Epythttp://www.consumer.vic.gov.auyDyK  Clause_12_4{DyK  Clause_12_10uDyK  _FORM_P_ uDyK  _FORM_Q_ uDyK  _FORM_P_ uDyK  _FORM_Q_ yDyK  Clause_12_4{DyK  Clause_12_10DyK _Section_41_ _1DyK _Section_41_ _2yDyK  Clause_38_1{DyK  Section_37_2uDyK  _FORM_P_ uDyK  _FORM_Q_ yDyK  Clause_39_1yDyK  Clause_40_1uDyK  _FORM_P_ uDyK  _FORM_Q_ DyK _39._Builder s_entitlement_1yDyK  Clause_40_1uDyK  _FORM_P_ uDyK  _FORM_Q_ yDyK  Clause_40_1yDyK  Clause_41_3yDyK  Clause_39_1yDyK  Clause_39_2yDyK  Clause_41_4yDyK  Clause_42_1yDyK  Clause_37_5yDyK  Clause_42_1$$Ifedq7~El!vh#ve#v:V l44 t0655alf4itq7~Ep(yt2b$$Ifedq7~El!vh#ve#v:V l4 t0655alf4itq7~Ep(yt2b$$Ifedq7~El!vh#ve#v:V l4 t0655alf4itq7~Ep(yt2b$$Ifedq7~El!vh#ve#v:V l4 t0655alf4itq7~Ep(yt2b$$Ifedq7~El!vh#ve#v:V l4 t0655alf4itq7~Ep(yt2b$$Ifedq7~El!vh#ve#v:V l4 t0655alf4itq7~Ep(yt2b$$Ifedq7~El!vh#ve#v:V l44 t0655alf4itq7~Ep(yt`j$$Ifedq7~El!vh#ve#v:V l4 t06,55alf4itq7~Ep(yt`j$$Ifedq7~El!vh#ve#v:V l4 t0655alf4itq7~Ep(yt`j$$Ifedq7~El!vh#ve#v:V l4 t0655alf4itq7~Ep(yt`j$$Ifedq7~El!vh#ve#v:V l4 t0655alf4itq7~Ep(yt`j$$Ifedq7~El!vh#ve#v:V l4 t0655alf4itq7~Ep(yt`j{DyK  Clause_12_15yDyK  Clause_20_2$$Ifedq7~El!vh#v~&:V l44 t065alf4itq7~Ep yt$$Ifedq7~El!vh#v~&:V l44 t065alf4itq7~Ep yt$$Ifedq7~El!vh#v~&:V l44 t065alf4itq7~Eytl($$Ifedq7~El!vh#v~&:V l44 t065alf4itq7~EytDyK _24._Provisional_Sums_3DyK _4._Contract_Details_13$$Ifedq7~El!vh#ve#v:V l4 t0655alf4itq7~Ep(ytMTm$$Ifedq7~El!vh#ve#v:V l4 t0655alf4itq7~Ep(ytMTm$$Ifedq7~El!vh#ve#v:V l4 t0655alf4itq7~Ep(ytMTm$$Ifedq7~El!vh#ve#v:V l4 t0655alf4itq7~Ep(ytMTm$$Ifedq7~El!vh#ve#v:V l4 t0655alf4itq7~Ep(ytMTm$$Ifedq7~El!vh#ve#v:V l4 t0655alf4itq7~Ep(ytMTm$$Ifedq7~El!vh#ve#v:V l4 t0655alf4itq7~Ep(ytMTm$$Ifedq7~El!vh#ve#v:V l4 t0655alf4itq7~Ep(ytMTm$$Ifedq7~El!vh#ve#v:V l4 t0655alf4itq7~Ep(ytMTm$$Ifedq7~El!vh#ve#v:V l4 t0655alf4itq7~Ep(ytMTm$$Ifedq7~El!vh#ve#v:V l4 t0655alf4itq7~Ep(ytMTm$$Ifedq7~El!vh#ve#v:V l4 t0655alf4itq7~Ep(ytMTm$$Ifedq7~El!vh#ve#v:V l4 t0655alf4itq7~Ep(ytMTm$$Ifedq7~El!vh#ve#v:V l4 t0655alf4itq7~Ep(ytMTm$$Ifedq7~El!vh#ve#v:V l4 t0655alf4itq7~Ep(ytMTm$$Ifedq7~El!vh#ve#v:V l4 t0655alf4itq7~Ep(ytMTmDyK _25._Prime_Cost_3DyK _4._Contract_Details_13$$Ifedq7~El!vh#ve#v:V l4 t06,55alf4itq7~Ep(ytea$$Ifedq7~El!vh#ve#v:V l4 t0655alf4itq7~Ep(ytea$$Ifedq7~El!vh#ve#v:V l4 t0655alf4itq7~Ep(ytea$$Ifedq7~El!vh#ve#v:V l4 t0655alf4itq7~Ep(ytea$$Ifedq7~El!vh#ve#v:V l4 t0655alf4itq7~Ep(ytea$$Ifedq7~El!vh#ve#v:V l4 t0655alf4itq7~Ep(ytea$$Ifedq7~El!vh#ve#v:V l4 t0655alf4itq7~Ep(ytea$$Ifedq7~El!vh#ve#v:V l4 t0655alf4itq7~Ep(ytea$$Ifedq7~El!vh#ve#v:V l4 t0655alf4itq7~Ep(ytea$$Ifedq7~El!vh#ve#v:V l4 t0655alf4itq7~Ep(ytea$$Ifedq7~El!vh#ve#v:V l4 t0655alf4itq7~Ep(ytea$$Ifedq7~El!vh#ve#v:V l4 t0655alf4itq7~Ep(ytea$$Ifedq7~El!vh#ve#v:V l4 t0655alf4itq7~Ep(ytea$$Ifedq7~El!vh#ve#v:V l4 t0655alf4itq7~Ep(ytea$$Ifedq7~El!vh#ve#v:V l4 t0655alf4itq7~Ep(ytea$$Ifedq7~El!vh#ve#v:V l4 t0655alf4itq7~Ep(ytea$$Ifedq7~El!vh#v~&:V l4 t065alf4itq7~Ep yt$$Ifedq7~El!vh#v #v:V l4 t0655 alf4itq7~Epyt$$Ifedq7~El!vh#v #v:V l4 t0655 alf4itq7~Epyt$$Ifedq7~El!vh#v~&:V l4 t065alf4itq7~Ep yt$$Ifedq7~El!vh#v #v:V l4 t0655 alf4itq7~Epyt$$Ifedq7~El!vh#v #v:V l4 t0655 alf4itq7~Epyt$$Ifedq7~El!vh#v #v :V l44 t065alf4itq7~Epyt*r$$Ifedq7~El!vh#v #v :V l4 t06+5alitq7~Epyt*r$$Ifedq7~El!vh#v #v :V l4 t06+5alitq7~Epyt*r$$Ifedq7~El!vh#v #v :V l4 t06+5alitq7~Epyt*r$$Ifedq7~El!vh#v #v :V l4 t06+5alitq7~Epyt*r$$Ifedq7~El!vh#v #v :V l4 t06+5alitq7~Epyt*r$$Ifedq7~El!vh#v #v :V l4 t06+5alitq7~Epyt*r$$Ifedq7~El!vh#v #v :V l4 t06+5alitq7~Epyt*r$$Ifedq7~El!vh#v #v :V l4 t06+5alitq7~Epyt*r$$Ifedq7~El!vh#v #v :V l4 t06+5alitq7~Epyt*r$$Ifedq7~El!vh#v~&:V l4 t065alf4itq7~Ep yt$$Ifedq7~El!vh#v #v:V l4 t0655 alf4itq7~Epyt$$Ifedq7~El!vh#v #v:V l4 t0655 alf4itq7~Epyt$$Ifedq7~El!vh#v~&:V l4 t065alf4itq7~Ep yt$$Ifedq7~El!vh#v #v:V l4 t0655 alf4itq7~Epyt$$Ifedq7~El!vh#v #v:V l4 t0655 alf4itq7~EpytwDyK  Clause_6_2DyK _4._Contract_Details_14$$Ifl!vh#vy #v:V l4 t0655 alf4pyt #$$Ifl!vh#vy #v:V l4 t0655 alf4pyt #$$Ifl!vh#vy #v:V l4 t0655 alf4pyt #$$Ifl!vh#vy #v:V l4 t0655 alf4pyt #$$Ifl!vh#vy #v:V l4 t0655 alf4pyt #$$Ifl!vh#vy #v:V l4 t0655 alf4pyt #$$Ifl!vh#vy #v:V l4 t0655 alf4pyt #$$Ifl!vh#vy #v:V l4 t0655 alf4pyt #$$Ifl!vh#vy #v:V l4 t0655 alf4pyt #$$Ifl!vh#vy #v:V l4 t0655 alf4pyt #$$Ifl!vh#vy #v:V l4 t0655 alf4pyt #$$Ifedq7~El!vh#v#vy :V l4 t065 5alf4itq7~EpytU'N$$Ifedq7~El!vh#v#vy :V l4 t06,5 5alf4itq7~EpytU'N$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epytl$$Ifedq7~El!vh#v~&:V l4 t065 alf4itq7~Ep ytv1$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epytv1$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epytv1$$Ifedq7~El!vh#vy #v:V l t06,55 alitq7~Epyt]yDyK  Clause_12_4DyK _4._Contract_Details_15$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt #$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt #$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt #$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt #$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt #$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt #$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt #$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt #$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt #$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt #$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt #$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt$$Ifedq7~El!vh#v~&:V l4 t065alf4itq7~Ep yt$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~EpytZ-$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~EpytZ-$$Ifedq7~El!vh#vy #v:V l t06,55 alitq7~Epyt]DyK _4._Contract_Details_16DyK _4._Contract_Details_17$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt}$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt}$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt}$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt}$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt}$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt}$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt}$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt}$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt}$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt}$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt}$$Ifedq7~El!vh#v#vy :V l4 t06,5 5alf4itq7~EpytU'N$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt*$$Ifedq7~El!vh#v~&:V l4 t065alf4itq7~Ep yt$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt$$Ifedq7~El!vh#vy #v:V l t06,55 alitq7~EpytDyK _4._Contract_Details_17$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt}$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt}$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt}$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt}$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt}$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt}$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt}$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt}$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt}$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt}$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt}$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt$$Ifedq7~El!vh#v~&:V l4 t065alf4itq7~Ep yt<>$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt $$Ifedq7~El!vh#v~&:V l4 t065alf4itq7~Ep yt $$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt $$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt $$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt $$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt $$Ifedq7~El!vh#vy #v:V l t06,55 alitq7~Epyt DyK _34._Dispute_Resolution_3DyK _4._Contract_Details_17DyK _35._Suspension_of_4DyK _36._Consequences_of_1DyK _4._Contract_Details_17$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epytf$$Ifedq7~El!vh#v~&:V l4 t065alf4itq7~Ep yta,yDyK  Clause_12_4$$Ifedq7~El!vh#v#vy :V l4 t065 5alf4itq7~Epytf$$Ifedq7~El!vh#v#vy :V l4 t065 5alf4itq7~Epytf{DyK  Clause_12_10$$Ifedq7~El!vh#v#vy :V l4 t065 5alf4itq7~Epytf$$Ifedq7~El!vh#v#vy :V l4 t065 5alf4itq7~EpytfyDyK  Clause_36_1$$Ifedq7~El!vh#v#vy :V l4 t065 5alf4itq7~Epytf$$Ifedq7~El!vh#v~&:V l4 t065alf4itq7~Ep yta,$$Ifedq7~El!vh#v~&:V l4 t065alf4itq7~Ep yt r$$Ifedq7~El!vh#v~&:V l4 t065alf4itq7~Ep yta,$$Ifedq7~El!vh#v~&:V l4 t065alf4itq7~Ep yt r$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyta,$$Ifedq7~El!vh#v~&:V l4 t065alf4itq7~Ep yta,$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyta,$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyta,$$Ifedq7~El!vh#vy #v:V l t06,55 alitq7~Epyta,yDyK  Clause_18_6DyK _38._Termination_other_1DyK _4._Contract_Details_17$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~EpytkX$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~EpytkX$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~EpytkX$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~EpytkX$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~EpytkX$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~EpytkX$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~EpytkX$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~EpytkX$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~EpytkX$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~EpytkX$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~EpytkX$$Ifedq7~El!vh#v~&:V l4 t065alf4itq7~Ep yt2yDyK  Clause_12_4{DyK  Clause_12_10$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~EpytJxzDyK _7._Progress_payments_4$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~EpytJxzyDyK  Clause_21_5$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~EpytJxz$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt2yDyK  Clause_18_6$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~EpytJxzyDyK  Clause_18_6$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~EpytJxzyDyK  Clause_36_1$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~EpytJxz$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~EpytkX$$Ifedq7~El!vh#v~&:V l4 t065alf4itq7~Ep ytkX$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~EpytkX$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~EpytkX$$Ifedq7~El!vh#vy #v:V l t06,55 alitq7~EpytkXyDyK  Clause_18_6yDyK  Clause_23_5DyK _38._Termination_other_2DyK _39._Builder s_entitlement_2DyK _4._Contract_Details_17$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt!EE$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt!EE$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt!EE$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt!EE$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt!EE$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt!EE$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt!EE$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt!EE$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt!EE$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt!EE$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt!EE$$Ifedq7~El!vh#v~&:V l4 t065alf4itq7~Ep yt2yDyK  Clause_37_5$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt2yDyK  Clause_37_5$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt2yDyK  Clause_37_5$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt2yDyK  Clause_37_5$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt2$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt2yDyK  Clause_18_5$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt2yDyK  Clause_38_1$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt2yDyK  Clause_38_1$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt2$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt!EE$$Ifedq7~El!vh#v~&:V l4 t065alf4itq7~Ep yt!EE$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt!EE$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt!EE$$Ifedq7~El!vh#vy #v:V l t06,55 alitq7~Epyt!EEyDyK  Clause_18_2$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt {$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt {$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt {$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt {$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt {$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt {$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt {$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt {$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt {$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt {$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt {$$Ifedq7~El!vh#v~&:V l4 t065alf4itq7~Ep yt {$$Ifedq7~El!vh#vW #v':V l4 t0655 alf4itq7~Epyt/$$Ifedq7~El!vh#vW #v':V l4 t0655 alf4itq7~Epyt/$$Ifedq7~El!vh#vW #v':V l4 t0655 alf4itq7~Epyt/$$Ifedq7~El!vh#vW #v':V l4 t0655 alf4itq7~Epyt/$$Ifedq7~El!vh#vW #v':V l4 t0655 alf4itq7~Epyt/$$Ifedq7~El!vh#vW #v':V l4 t0655 alf4itq7~Epyt/$$Ifedq7~El!vh#vW #v':V l4 t0655 alf4itq7~Epyt/$$Ifedq7~El!vh#v~&:V l4 t065alf4itq7~Ep yt4"$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt {$$Ifedq7~El!vh#v~&:V l4 t065alf4itq7~Ep yt {$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt {$$Ifedq7~El!vh#vy #v:V l4 t0655 alf4itq7~Epyt {$$Ifedq7~El!vh#vy #v:V l t06,55 alitq7~Epyt {DyK yK Xhttp://www.consumer.vic.gov.au/yX;H,]ą'cDyK yK Xhttp://www.consumer.vic.gov.au/yX;H,]ą'cDyK yK ^mailto:consumer@justice.vic.gov.auyX;H,]ą'cDyK yK Phttp://consumer.vic.gov.au/yX;H,]ą'c Dd^   S A<4CAV_Brandmark_BLACK 13mm highConsumer Affairs Victoria"`b >a凇]8X9l  n >a凇]8X9l PNG  IHDRR3# pHYs\F\FCAiCCPPhotoshop ICC profilexc``$PPTR~!11 !/?/020|pYɕ4\PTp(%8 CzyIA c HRvA cHvH3c OIjE s~AeQfzFcJ~RBpeqIjng^r~QA~QbIj ^<CU*( >1H.-*%6CF>,ƳLLEXXXYXxئ+opYɵۉO 92~y7턿M%>C"\R\5[(nRjRQQSzNmzF#}:u d >2:ndiYo67lO_0qSsKk[{GEEEeu]S[wD`dxT|tzLAle\s|_¬eIO._@bI{nt^~~kE'(,׮pLQR݇F& ڮN]wDI>K̛zڧ3=ΰ8?-\s|׭ظj5>mfҦƸεQo?q'Ϝ9w¹/sk汹󝳧G?c'O<rݫo 2016-03-15T14:56:15+11:00 2016-03-30T14:07:54+11:00 2016-03-30T14:07:54+11:00 Adobe Photoshop CC 2015 (Macintosh) xmp.iid:d446c971-3373-465d-a995-0d824e04afc8 xmp.did:5A92B6874F2068118ED2E7D848338487 adobe:docid:photoshop:f366274e-36b2-1179-a6a8-8c0580d6e4bd proof:pdf xmp.iid:87197467-7d97-4df4-aa07-b4fe0fd460aa xmp.did:87197467-7d97-4df4-aa07-b4fe0fd460aa xmp.did:5A92B6874F2068118ED2E7D848338487 proof:pdf converted from application/x-indesign to application/pdf Adobe InDesign CC 2014 (Macintosh) / 2015-11-18T15:28:51+11:00 saved xmp.iid:28af550d-9112-4584-9abc-1d54556eac1d 2016-02-24T09:39:56+11:00 Adobe Illustrator CC 2014 (Macintosh) / saved xmp.iid:3e57f33c-95bb-43ec-b90c-7bc3bc4be11d 2016-03-15T14:56:15+11:00 Adobe Illustrator CC 2014 (Macintosh) / converted from application/pdf to application/vnd.adobe.photoshop saved xmp.iid:87197467-7d97-4df4-aa07-b4fe0fd460aa 2016-03-30T14:07:54+11:00 Adobe Photoshop CC 2015 (Macintosh) / converted from application/pdf to image/png derived converted from application/vnd.adobe.photoshop to image/png saved xmp.iid:d446c971-3373-465d-a995-0d824e04afc8 2016-03-30T14:07:54+11:00 Adobe Photoshop CC 2015 (Macintosh) / image/png Adobe PDF Library 11.0 False 1 False False 190.000000 60.000000 Millimeters Black Default Swatch Group 0 Black PROCESS 100.000000 CMYK 0.000000 0.000000 0.000000 100.000000 Document 1 Dot Gain 10% 1 6000000/10000 6000000/10000 2 65535 1106 307 cHRMz%u0`:o_FIDATx]wE=$ݠʚsDŜsq59p%)bN`Z׬k9q3V+͛uﭞoޛ驮pԽ#"""b ]k4O?ɸ?GwZۉPo Z,z ZG~gxWוW@[hsjZeƤάN """Sx*ݐ睩$e.ނ܂i-ߙ .ӮV)B/f/ҟΪuk-V;@|Vw\08rfPTR"""2ơXV`.lРPյ~!QGn{c4R. 4!-v~26 }Gb+6]J[L],~cfVASl)_X;}[{-ZT.Kě륦bΕOSߎI=?" -Wo|ս 8E s6h{U'JABאP;kwaDn_rE *n+^բX"'#2sxi׽;E!oTԀui KI2h婃VAأuZSGvH;1N^W/|r8 rw| x: y“ց jFȜ?EFT0`(R~p,Bu'd^!#EJJDDDD#9狽XdcB! t S-`S=!Hc%twyBm߰JʛJta !0J0z8.g,侎c'vF%i&. NMLՃM̠ﱐr""<Kl2E35:!iP&J $^3{>HR""""&IYchS)_\>SW!luKH'Eg%AA^ bIRBw!pҥjstl% n8Z"IH? uKd܉ LM]8;4r7`7*Xk"%!nῇL >*(ܹX8"ڴʲ<4~@#L')wv9b : \wI~PuTI`䇭w-&jvJ3j2\bYᛄF)DDDDL rv, ϴ]e @ޟzL0-hqWM/A址@n8M8 کЖ" =)G,,+sݭqD1-HZL~8% :I9MxwϫLB"]*$]sy2P 5= (-\>ŷ>kQ9ͦı<ԝcok7ͻS:'fGOFy~O Ր1f#~|՜1{ôCs {@~1iO$( ǽ_Y`*.a= Ԟ"8+f=!q6 kM14|@62HR#]6J.b0NhiavXWy CȤ1~ԙT%rO{ԥ)VêX'}ox_g=}5X]VbÅׇ1랜|.r@5tnޛ>A7]k&M{CedK-QjÄ(ÇQ2{ex -7Lz؍l:/nãnrNpawޙ@7`{q-jޓhwaC; ܽFu+`L [{:#%'<ɏ]|$vvnb*ۮZ<Zٓ}܆o:Xfw6X) `.E$^3tђO0?»x2oۻo^-yؑ5O -t%N)w׽ܸRTiQ۳wF;8'_!A#W>ħ`0k/ 8>s%z%`@n/݆[Mv%aCad܎xXWRN!8QMu,vPX5JBZ@Pt ֪aTt!k"mz )4B. &xb[g͝:-E547 [ҵ0LO GDb(6XY ŨSj#< b$bOԥ&Mn9{Vr!PO!x7}093kGK຿?{Q^ I╟ϤKO!Wx/>#%jЂӽ=Rȹ'FVΆp:F[~H]H-}GT~ۑwƃx7>wE ?$MKkT)7oXJ3"yŸ[_~O%U'7kiO=UoeS'\KU2&gGIJm:!^B~"￬@˔B֤͊Oct>¿0oHdHCvg[%[sC/%m}bYgH{!9q"G*HoNŋR˒GޕY,-e rW"م+itHO'xj=]MnYdҽJIԕk6djI7tO oi-",/,]WwK-{5X ~6{yq2ő>Ej=o[%!uE[ht,T!Z%goDl{ .t$)œ(TDc{ dF쵏ﾡUYV-Ҵ̟+*W]IP?N 7T^ qÅ7],7H iYJA㓍Md ͅ LlOsIR,._ ;&Xtww&er}ѱ0kdj;*kܤ8=TSH+U~jGHџW(1AzӇfO'j$ZvrZ(k\}!xpBEc{2r cӰK|E)zSj j2U啝䷍,Xa$4&izi>?Oj>.XhI$kdk†njS 5]8HL˸p*R*(,f'4ތsAR҄ 26S*IPղJ@V;D]%څEڱ)l5W&̭\l )VL '3CoM=+[9fOjZ`";Vxb{sXӡCJRlBVYD$1].N3=!e_Hb'IDX Np >vw2 t^"Xyw%cAL*+Zc|M7Y*ZC,ٓfe[E%&)|)Vw\4IJˀ':$F{υÎtwZ&X2'`F&udIJʳZ5mFRqȔ$F%U:9dos9 )aWxFU D†$*r俅=J%J&ߊOCrI2WE-v~Rwܖ^_'\@6NJSB.J.I39X;mVEhknٖARڵln2.ߓR{_'q qSm+˳2y>=,GB!/#<"˰#25:Ӧpji`ߪ(EƖB:Rz쭮;4.IIL+w$Sw^\ hp`ډ9|cf`П j)rV~{ߚ^߲ҰV6{yOE8؎ɸ? [FI%EKaGQVnʣsKkH:{r5] 5-nRh39id{Y-B3#ղ?' [~dFOJć!{3Z-r6O=Me.'WPYX [m%A-ϬF$^_=<[n-BQ1 Oz0\0k3ۭjdWgW6F)eir29Uj-UENT#-$Z]QD4yNF9W88$QBx.١|]TPȖU8n5x3چnax{zguh^Y`0djO=6Iޯki1K*藁c}bkb?$,G~t8k줔jٯ T1aCpˏH!tՑ\Xhzv!sf%cTco `}ݰp{q:/U,VQ",vءUDGO(1n<Gc5t^pX ;xmuqzL/<;->.6C-+pE7 .ž`z!+o-5k^WXI.I m>e,Ihݨ艔%,]g= ?pVJt!dRR#O xZV@O=5A̿ng|1VBG=Y9\TmڻYhNƶlمJJ $yd7GԮqVLv]B(g8)vDl,7UdR1k~jVW *4QEQՄERn/2wRh w0 7洆o3oc^|#]=ټ b-|&]]|'pIhcK¬=T'+= g,= 2խj1T, !]Gtƍ2Gxfxr=>dOJFND2E˒*l,u,XK 쮅Z?v *HIthETS'7vZrOOͅqw0Uu:W28b{ŻI7}0ڟz@f̰iVyeW>mm!Ǧ%)Ӄe1,錎e~*lJ\#ZTzAHBYiIٽִZSQ:`D+(Z'#8Kdz厦NX.dCg_C:Å:T\Y#=ba?\jYxR|/}XV[J3pMJsj"Ɏx7/E|S俫k,ld  03,acfE֬R*9"x9y6O&)w{[w#,6k'A+u, zVFȈ< P,/HgtU\#IIѯ75$!0u#] ^Z|- f?϶᚟3TX]lg7Ťiw{bR5tЂ°2dj٭@<5]ߖ޿~}.EBdX /Kq0!L6ig~ mUS^KdMIU.P,U*8rqGR7I+I#驘sv`-K4l>_[P5~ںp:P!} ?MrVR߆S]UEEeEor6O^w{ͳߙ.m)`d<c2wqv6o Yѯ&<]X; gc ΎHog%j-^ړ|o^Q^g=z=ESJE,=fpxh/ N+Oeu-:!R3݊?Ν%yKΓm /e \0Wt ].j nlZ|j9C'Wyja0IIjvp=aS<7;μXvߌ?ֽK{vd{;i3ԑIGʓm'k *)bHh{fajVS ?"(PE޸ `6*\G I0M]dZ~5DrਧgC7bgNMUk[0K%XsJBDžr^O\n',JLF_6yY_VPrcdH3LsS ϴ 8+΋Kr>\MT}qY=4!_dLFQt`葼? V¬+^0`?c*`-^|{7)}99҄ڦԂ,~qQ%-c%Ü\sO&xw`Eu4Bз'kP;+#T<8N-Q&S}to/q%}n>l,pp\s]a(yؕq兰=YႠf4Y챊z'~d {v%1/ab_Vq,wq2H={Uo8J4'?6I%: ;'ҵC.tqA+%urwrXh#TgeAMl!Jދ>oвQ<~Qn;˰v8R#%G_qlqn"/UK:?ަ;*:J U%ŕSi_z$wۘ󚏖uֵ8/Yc]˙ fYW\'Mufm$Ni&=\vg]m&Mc'G)XsA{d PuT57KtJKxơg@O/6@:Q%S[QbDb9YXu)0*٬NkYc=/a7`U!8$}GЍY J/C/F# 7X e`bl6QLMRx-@P·sKIoc/XڴO{:y ޚ&)\b AtQd'x?|P2,p#}糧z ڔG{wW2 eO%C[!2j-PĞ~p/צz="MdI6>s19Nߧ" SkU`4]W˂D<֢2\<H.%Z|8l= gY.""'2EW00xSrfz9tPeN{Zv4U6ӆ5gxbnp<̭]n @z(Z5}0dnUܼ˕D i\'CʃH%kV-b *jT.~:!{Og@U׸fUIV,5JiV,TE٨cUT.Q% ܷ]P XQrk5_ K*9`Wha+܎?%s%֝n)$*:>i@%DNִFߣ(Hm_иGHb!_ohBM[e^^yCr@uX0œ +2;W t %p 9V&SSB`kX^.QJoU szUMs`0t,&Pu2bX-|,G]>)ǫݽY l\;nZ$I"q6(ggY >;C}aLr} *S}n'Z/QH5VB䁰ҐI.xL6~TK(I5xU٫q1| N]]&?{+|س);w|C&0(6s^ JW%^a~z)B|Z#aiZN75HMxH\hTL$S_bPuDdqF&K;oE%pv}b>|+(tUmիhHs=6hVzLRvcܟi!ڃ\i5%a"'Ӻ7hѢFThIN,5h""Imʸxz{*\RDE]kAŠju2V.`2OCy ~t: %k: d$M)_`FnX<2G(T d>e~^])7/ai|7wn9 w gSaƢXOGk-v@] ɡ>',EɊLt72>窓zj'27pjLVB}{".!tI+Ի%N 0<=}jj5qREB3sP3s99 Q>$V@K~bZs+v~@YfK2tr+)&Aj}O`%r\6Rzv`a1pfJ}g7*wkaSUcܒzzʏ WFiM~.{GܟVDM F߻z*g:y=S =GN qDINbԽ-P$ܘ;ok X~bG*X/?$b;$>! 7c ;) Z%|@] XOA{B)}LR5B r2mۙ멚JO&c,)֗8Fzt8lPr_:0dVbt(AL‚K+:{fW&sjA:Xg%E*Ib\͇n-D8kG_ ۗ@$lxxGN(֊uѶZdLiD>O !{}6^ˌ"R &Ay=2,M‰O{ }X44U@X\ӮM63Br7 ƨddb GAĜee!{$O,Z$W7S&i3GC]흿`Mx$d|,i|3֥,_I^tU">hնe۰>?JZj*}R~%!~|v, 㽣(ָ'"}NÒwVQ@8RyRADȨ@mӡwnpD!Io%c֓Lceܐ𴔿CMT%Ȃs!X}F'3XhUW&|"v{RT0Bߴ?-j-Te( !<|/BZBE$M!$,Q Dy+0V*oYΤm,%:,KHjeKc1NAɫp&-9+Z%ץo:dGC2c ܜ`=Hf(M^DD@IkUQSx1Jz7V%ӬAžuR5 /lG6h^-֜u7^ ##w~htr{ufZ"3gP EPՖ!ҍM*x $mb&&VFyP~'p Sm:LJTX~p+&=?\Rbڹ:ӓygoņc-{0x״ I#:Y"MM^1 8I9ej,.pD B6v<'VZDyb˂QN8pΕfb6{_k*XID.:(Som-Tg {僗I(VƇ VRbi7ܖkN?l*$٦B 34p#]TDɈörn Հf6yK< FlC ېOCVrc+uwuPP@3ĸG )rmjJʻ};Io'kc~oC{/HJF^#Sv4ʋ1jYQkP(G*I7:%b2rtǦBS;kީrG|8^#S9D ",V>yrw0".W{2N+7>W|RWm>9H&>kA ;KA6іl{ ;8hcӛ@=D)X?GѲ*eb4^Zޝ}I[a&' #ud?XwIiV,"O OA`/7yNVt}lU{U:PO\@m3XƘdhr.r+񺸦9'fvR64bFY@ÁSi܏q Nhp4'ə#ܨK;䴘N1m%Ѿv5#ճNwvv;%s } M|@6Mb h$yXJez{cA.~Үd2d:1'DB\Ϲk[-Ȯ.)[K%k:Oo).; pDmt.R5ZpOڏIWOڍWQ6ƴocXԔF8M-ݡԿ頁U/%dn:!_n,1Xa%_B ގa]W1W~ b q>ݏn_~Ћc) ԝ lG{.;FD4[/4 4 wt?Y}%Z(.h9"60lV~0N15zdyQ_벞0ϔ2L90Q#N™q(IR6NiOCqJVr}ͼ{;&G̍k=BЮ%/bjAૐc@ AǮoOrNj ̮emRO{!@JՖU1# Vt}9ŋbuOk_H)k3s5 J- 9tވ!m_^U$Iw]=n$)H `/zBR (FM-T.,$J(BRgL/"t o.'lZw˲-*=ȼ=pGn]qFLf,Ob5~MRDfDK[[ ؊'/ͯ"PFV{QDb,k1@)HZSO‹q`KάUE eHh-!Z%~.x:2]̞142S,פ`^]"~-em<,ENxШAq8^OHJtG|ohap|:,D+9{/.I 1X%zge/ϣ'MJ:ޏwu5>ӒVk|ؙ bIq}?(C"弊{Ϧ$&6z^Lae݃~  @ ҁvʾKV6{:Gn }(Sp vV|ykYzJh܈lObbq<4Լ.UiиFERg̢zpGޓ,Ts-=i8^H,9_ۍ4ܗ.YtNMzd~JKE;Uȥ>߇r=/nu=Zkpw.m =6vPX4rff5XL\PImGgѦ:ͣi4Fhq:g_O{- ED%:DA뎤bV~ĶҜ̚Q'&T~MonMC f;|w g ^wv-ޒ\ Fzah̖O`-J!7&={V&r!!|_zGrڬ~ƒ>Hv/#bŦ#d/W(ʘe*ҷ"HH:;7ĴR>,ѡգo'*򱷴جɳ%C/Ъa8]Uzr=T5 A~Kκ!s"S1E1D#g8Mݸ;Y -Dmg"ö.I= oD[{< bxRժykHi{2[MUƯ)/SOkG`榮_+wn{iA[ƻ5H;lVv\iY}[p'pgt-܂y70֚}r)%9MԓUSc3.P>PS_a9nq򆤈 /Z/՗p#]^ y862ƩR&gӸJڙkg,w^e_L&D5bZDDaTꕯc_8]8BA[?Nhq፨[I?Gls<z{-7 ϯCmo$6Do{%Uӛ;b@sŒ@F>)DQr{jseb+=2؅bD  u~Ƹ*j|>v]B4qooh'YפM8_07 "׎rxH#DE lV}`K}xY~VMzʝ/At˦Y[s f,tT£S=kpp2_g*&\`@2ʥt)iE L|g\v#A.*y0|9ϯIٞU+vB CpcQA&B!W3Rb~ ]&ރIèUI+忍W3֡A|^ŷiKDk+6P0J\ ޴3Npǎ3pC69p h]5 ֦0 Ԯ"4L, Nz-q ΐ2boN\Ez@&B֘a n* h@gC@b*5MZDEY0;c2Iٽ|8o"Pܚ6݁fm̧d֑~ OG/iLt26^: [Fw >ÞnJ劽au-Kԫ2nA%3ԃ:/$kx)ӵO Pg?Sgc QSd_vаz})R,"4F<$MuJ:@}R-m2,MilY^Iy'TΫ)eo0&?~p]ǓXZ5r\݈6#vqllz~7g2.Ѡ2=,x}e,^A,vUJQi%h @+$=qUKcH |[ HژF;7D[Nm98y韷eXlؗ5T>%ƵӤJ-͎X³<1 ׶n+UC|H"HbY!-\Jܷ|^ YZ\&eK2h7}JY}휟76Rђa:ߋ߉uf(KJOym%h=T䰎Tu(U>G2DD_BeXU0a)gXh`cF{oݩ+Pus}2nwG&P1IR$ɣq疨ݓ"[ijy%]])c/?jEi&B4*T @лx5U]~Pa. &UTLLł;8*(#يб>VYc0 ibwysBSI7т!>B&p,fAcG4$pw` )U"*pFOk^'.rxlF7$BE,9_fr9ݡK9~q/Ϟ|%!IspR-I\6Yp 3X"́<]_< 2:ڣNMfx]&n,b\vkI]çuW盪B74R8 yg~RKN͆Cl3".yb ]J?濕́<ݛun|\p#DR8~ܸ}:^F6;诘"w᾽=RKϋX-{_+0XboΊ*T06/vsPxl\M7-WdQaJ®+1 rXHXD_Weu!yآ73Bf[iBOLOS-W/G*շ<" QTϚ uv%MvH#& Rq$>./atضeAV3ΊmDI >*ʝn2Uigl}Wfy ߅arW0٘zv:ՙTVNTbfdyZE UF^2MkmlB_A + KWEη]l=Ok[=q^MZ (X-đx _jj^A|q^+:%czˤR'k[EaY(q>M"nBv q=MQHҗڞ Gu}ۈ +DG$#1XRz kgHk~M!TO~߭0oSdξ| qA5,]KT(wƆw/HYUBW}Z#{%w Lf!{2Ȩ. E@I28rN*YV5d#y}`2m gp{6%RoeCw{Y0I6BbJ󤇽S Zm ƟtDVR~< SMr`OI#c>6$MXh!B!IPQ j6MJ~*?"Y}RWlHoD[vؾ_sV}ϯx3 l8ٛndCeH'V//Zf{rWaMnٶ/837LFZR#xJ.P[c{msҴR.xw{Zd Ӈ*SD&_d,xacIU6W"M :`>HsYVˁ2^kOb.$g74" Ձ19f>l^J'ܤ=NF kN>䎤1xIukas~SmnW42wWSky&Q*۷v,&PZ/VC8p%PWkذ{'QT&ɦTSg7j2pǥ2k/; 'fwekM* '6ݖsn[Z]';FZ n;85.FR {Ka82k8Yuq7~_ܸxvg64N>>I f'db`nN 15A *n/T$s>Qw=𖱫#0:˸ڄ1ԡ'Ѳ?@$22թ/>Ӵܰ9?<ӳ O7j%h5}]/L\%3HX.}tφ}LJzHc~gT GZ""ډ@;}p/XsoX7[֝{gy>:)ՓH1|&.p?~_MB jw|sƺanU,n=JhnXMlrvKRNl+1+!v#S,rm'+$GP}Ox{էB-q7<ˉ8;Zʗ 7d(l=R[#Zߴt,̯ $YYRf+<=7Iw[+b`mJ иFTRFX~rrK ~0{w|7>J$퀾X+`YE/{;g8wD:b ly%%ݨ\R$E+/pLFe{_ґf|W-1ݥGe Ϡ4ɒ.%JgmȦ!WA %ݬzC~nY#?FqSǓ9eĞKLMB1UIJ2 Ҽ0u<u8o>(4%ٳP^Џu2twFD1Ӕx3˾hyr%"*!U {YTHtDHk&aRr mPd>\fґi&rPvqľIJDDĬNR3\taUԉV>Tź6Rh*&MC_p= tqxN M}3"HS&RGGlLAĂ(&(2!] B{`bXYN_pNgE]*ldDDDD 3]\y2COe^uhcS2˾k+y3J_k&`[6;F icbDDD pE M%_J_ ҷb/$H 呔ͪp]H3JHSϫAG#igCx>>TiDD%%"""y/ n]nʿz_vsdl(G)lHk9YR!xTASgI}/p ]>SO!y,}2"Jmz|bRXe MՊ Lzc_U Ѣ죟P, >a2IAm̖{dD$)-K*cK@pi EK U.Y/D#4@Pa#ia#""IT#p~FB MS^PL'YLRƃѕQ&/I 7p 7F1:`~bK$)Z荅hAdx<}Z!Q0jCztE|{mO*4"9!FkLJ:Vl bq,UfKnSE`ʫ( JMb a7[ NX%PH0նbEou=" m]t!`M-n6{&RW-5wL1Gz/=VvjP{ "IdEzHr"8!X 'FyA|}MWK?aP'Zk].~ß%m8l(#٩_qb!͌:´{26YSHL*-,61V0r X|zzQ6IXr*P7߁OӞmaJH7jP)Цv4 yx=\Aw-Z|Bor`;kC76xk,&EX= Z 6w{%G[(obۉ ] -H>)6󲵫ʟ}g(i'>ΟQ H̄#˅nI]>׬hd &rPZ[J[=JGe{ :INAK|kiL@{{X0E_=`^>ђ%\ﱫ<> - v$oQVG2c62'Aݠ/0<~VP1};$z])#>{^(`u$$=[7G\]'[ {!aNi{7d jwo:*dp̓"Ih =ؽ=VB#{m~ d̩! O$s:M !qgh8!IJېI\90B Ҹ蛣pKO94|[1`{hwظ~禸w!@4-$ bsjS-͓R#r9<30boi,c[ZDo jL,M]6Ur>$mP#IW2H6l¹ ZHK &_#b+wR ImTRdHŊKJ O?r11&aX auQ/EY1 6󵽅|Ex.w_N+wvi/L߰;HM#+!Sᴒ-Ͷ̒KjqD#fG%*dl"N 6gw,Hz VHKunU."IhZ:Z2T(@?|ELl+\a e[lJ6*)i75ޯ|IYN #e/sbODZb@W[sWLf[Q=^X'; <vpwgFq dž<$N Q A<*?Iz.lּ:u|$[d@ƾvpzdnz&)Is}Al,Qju9 tFeQ޺~xل7V]˒\r^:2"bޖ!bNM*W6]OUtZTcIH!9#.SoU4UUp?#3bQ Ԣ䱷R±dղx>Rgmjjc`t=U3Z%'>I* "2Ot}c kl\ZB$Y3;=E~:zJSq/,mO5wبlCZkޒޔcU:J,'sѣkEӅS/`/ܔw‡HU-l#x>+COD~6aU I͢2ԔƋwbg壋ze"riLu4uNhỊMYO|^9&m]8 0O PkVQ#ظH!mdn մ#'c'")ڷwg'%UgdZ>I.?9;۲(Ḏ&sҦҿ<]E`E˶ @&^ g݊H"DV2%22_N"䳊a{aGĴ4a&3+QZ%<R@oжOS`ha󰧈2PNcZtY(zVs ~qpS򭐝; \2&H&oyYlr۞m?+ΰ@y\ ?CsJfc':-yڰQbvCw<D2{ƥ :~qCz.W~ֱ:^4S-#*#Zm3>V\^Vmg1>ӨrW"U}sXwTl w -Гn=W>ee:Y^wO{e,Ni Wh 'D &j) }}UEc f}+Rfr.r%G wv6&+_g\e,%;9'"&l^\_z֖}B~=gh[(wh&<",~f%kSIIJ0 Np Gɏ1)3 =/tiVI6k~aA|uXNSG7vhCWK7iTpAwZk0]̛Q*;_J2c/CQKQ{\qjw8$E!Hާ;*UV"2G:5tvšx7=,5o,]4 BӑEƊ3Z3hmCIwsQ 5˗rec9KhNk:Mq_YK7ޖEإO$efQSMRI֦[rtm d\g[,D 26o-Efnѓ=\jY *Tz^!ZM:N'=r81)mӴ*QO(yç p#ptH'-l[8L/dUKR=`ԡ{עMYIQn>:" ;nPRj7xφW׌I̠̽9ZmzMC7B?aԞ(~ï*a#xtŶG!Qb $7xvUPՔ%ҹZxg_KɁ \spJW㴔*[{GN襶ߜqP8NW(HݍW~v?9'_;0be p_7~e͛Q5l,EElSWM7$eVQ:cRRp@K}O#NL m.<ݖ\ڢ[4>a2R9,)>< ʉN<2}&Ɓ(KNݫa&u9,&Co,(_w4ys'Cܧ!)60vC2HGsuՓp:}XT[' & D}{zfO*m`6H])Iʌ= `vj. >]S9,3'hSUMٓӱZ,܆Kji0a~ExLA^Sj`ަYŎϫchg_@RC pq!=ߣ*cLF-PmvRVk1 vv[. UiFvjl1ĕMU6 Ǵa;\c&~J"H*?-[hPմn Y(=:U2gd'|SiM0?aWG];6'^HHIfnP_~0d?Ywfo$0^֙\A\Ea{r;G8z Q|r= ]"5>椠-$2oM'p0V:ВYΡo˪r~D {auY &3kTfZJ$)38hkko0T_ӫL{h+M5+lK9}Da6I(E> :Tį+h=ߤ)MS淽\.?RMI7֓lmB;G, AI{̞,Ke'_ ۋ flw͛8A>IJ*䳢ոW0>Ʋ-դD3jO k!GnO`L}SU#KPpj5LLÁkƫO.S؜_~8ԩt0K Jl.;(v)=tO9*9l?eaњeO֦p- J?X=d,Խ$S9f5yu 'H#HRfzk E٥rݵzZkr%AN+3I6l K(;*?ZIRub+҄5̵)GBC% sXtv](H:݌::P}䷼;NHG=tjl=-TV.o2}i[%߸ /CbkiIk췰zbU#F+r%8= .#õ0%!TU5%&8=<^WHmUbH6f# F2ǔn$Á[,r&/pG*caw6i;2aK +9uwxr-Վ[Yɷb&w5ذPF-BF;p=ՖG fx3Oۋ(+m+-Jxނ+ji»QMF2iHSYm~ #gZjqH RR"Iu;?9VǮ긴jŚU@_Huu:2Tۺk֜{~~AtVR |0(9~x!+vq7>K5Uu;ǽQ\8cԽ!xd_7W3ȣ*2[ߓeIŀ8'׿eEV{wA깇O{k f 9&"4.< Ƥ aGyj4ϑiHRfn b!~xXЫ {#n#n)N|P|$QDBb#Wo!~͊ 5։\^by8 KKˉ&+oʴ_itzfki)T۬lQ<ֺ۬DǛYRlyMl[8ʦgX+:Ӌ4@7d^{޸_(ˌtY# Ѽ犕,2/ E5+1PJ]$eQždy $4%U_7 kfE_; XG-EZk|VDM~hXZԄT{r{Һ_nrJ@^*2H}Zy*MSy]X0j.UYxɷmdΉD$xQ.ְF_0/`OzAf+@*hUr \9K}HP?T{ﭜ;`!K{qIMu9|4X( 5|WV.rBOyBk@][1*52bw&#27U}WE!:WJ R|=2bZ Jxݾ]0>fcr,Ԣԋ.OoK{N~ oJٱV%ߴgk QĒ &ӏ[[^Zͻ UȜvͱB-/a,f̨:8h2U/x)}5ʹL~z( qK((\^'W6=fB-sY}`_/%*}wVyݕjE74!,^Mw] o~^Y|=98];Jk+Ӆm)ЕܴBϳձsy=ܰTɜ;>"<;-V-/e{}npV }+\ڧ`G2`-dp%֟$*M2{puouR/]{۲^u|"xV60*sok@F m^̷5"HZ![cRVK4rH# y52O^PfBJY/14?JK6Q]=5ohѳ8jRe4sZt;TFx<% ]C @bKud {KV,ttַ}珼<ʟW5jFE2c<4},_kX2sd gQחoNjj:;Ur_( ReD `YSp+KK_ÙZ2˅ovd:mH .J8GsH̸P-ېQěK~*J˘7).2Iʌt@*<9S_w|AF~ByZ@X6\To[@gLimH@7xŎj<;M\Va޹tޢ|$No{ {}4J8]eB,$`Β4j6=<&ጺѰBrMH]={| @ LMʁ#sAd7?aN 1Ŝ|oe菣퍏w`5$ a ރ9w1A/䟰]ߴJy$PYQU!DV?%?!/FNOjr(߆*!&cCdh5-`. H9n#׋Xg]Ky3Kl s{Y1NJ_YE*x'23*ڍbii'$ӷˍUBSWcrᚚX:Y= ׬*2շmKWg@s^Ne^%]" <$dn;ue7XBX%1Eqfa*֍Ayd*啪&+Ga,p,AA=zbyTz==] ϖZ< }e/ІG|\$)3ui?D;ҏ"kJȒ^l7A۹#t@';9[' #!5yZ I}2d[Y]hg2Q׃O)X [׃sY7s0;KeȆytm8sZ)ZZk l]7a7O^ݭc.G;Vv?]gS *_>W1Sڋ'xr:Wֲa%?< NMΫOCK^Sq)3Qï;_z Ył\jx#%W`FQ :i/R>UϯO]yDj-{ߍD o ǶgGqx'%?0sM#2>Ҏ\H-yKZB~ʦ28k)SP"֘J Lf]9XؔiK2^W5p?{ߜN+7[[q)(X3R!gYɵ .PO tY.L;mR, ^lv0 9d@Vd"[T'D;ki}x&Xͪ/<1$W$yI`lRIOg¯7mdS"Ž}E8q#{tvl#/ldhEBun:Qvbn١[ <(WnzWҾ7FFYfd|{Hk#?M^_"lHd0_ VڀT8l[U5ԝPffΧ*MhX^%Y^O_ÊR3Uw?=v߉$eF@`Z9B]K;e37e2q \02 ܛ.`Ǜh>S@-=pU6ZcGV&TVبƶt6l#9 ԝ;=hehJ,\FT{r:ZIJ8D+ e#XMNcT3jLiiZ^EhP\_[/=t)1J?'s{ښ oD}2 9YXoxFSjݞm+}g%N1-&Ex@c*Gd xͤϹG[7^Kn·S$[+2/"]EĦ) #ZJ@zuU<i Wv81^⮲{VST2OI|(4Ǣd߂Mm-_Rָv^DnC?. B`*=NѾEA98DpOhW5wx{MU8PWtAvd΢yZzrcPVuKM/ ҕVlQ:ue՛ҧfu͆tdciyN.NeVIWJ,cYz h:JO;!? CLH]FӉFAO`v"(HzѡZ=2dT 1keU#/CRt<0$w iP?ꄲ+lP|LmC=S˒mg[kP{c'[֏a[P65#Q]:G?żiw?=mmρ8QS6ĐQ7fBb|t]8VdR嵃S H:@)@e'?PXtqn= յiE);=};G7.Md[$5+VμV: c|_S*>O(*}tkJ^9ioO&bJCj$+zAH^?M?VTk^s&@6!;UztJƭll|5=OlnVi]Ҏ8%HmI,zE8sO7]iHٶqeT0ɦy(?PX|2 %/mgG2(]hx<'5 .u;YI2h6΍' sap7^=-OZEjpٖ!W4 a ˽ lE{N5dptcraCz{0\{ъa]z" v͇>۪R,!?%KHAͣ0epNvN'U@ǯ82[KKqIcD64MQtz]>(60x`=tύt&Mѻk/;JsSaeJ؅JV#Z_'>^IOJ[9Q2b[ied C9-="meOgC9A.K׎$eEҁ\=ma.dr,6T%b4 v$MOf[u''wwd]qZJz0v^v-`zcpğݤi7&8r6 H䵋2}g]8^Gd,WnlD[P6~c//QzX}`p7 q?cCף_ Ƚzq/4o>.m K/Rˁ:r$v?"s!E2~GK*Cv! I_Ԝ狴O2_SjSV0ԐC ?'O(V&opK'2@cO,Y*oU-.-%YgW#ѨdǤs?·Hr ^Z//yhZVsp'ݟܸk(%fF@0dX{2݊%eMJ+E茓܄233&d87n#ܺ/irgٞ,aP@Vv˝{f AO-YG~!-ȝ1 -az%>IjmM-mt19M>@Nh7ssnt[D;`.#;=kUB[PGgHR3s]񏺵7p I @M&dJKy%NGq|\I8~LGrwZo~F1l͆6 oa Ϧg5>-&ׂW8;J̍chm&HRf8$l$2l,d B_rr64HU<5bcc6hay6*aɡݘH:bidb(m/92=}S9kj~}/s6^k>w tom僪R4ba?TԨMrݻi >FZ"rv}y{Zc[Ewa#(p\cez%-Ѽt"+׏ȜQQwKb}k 1S}q_.Zv9-]ns_ T1{P0_08\ÊV(jֆGIt.pe[dm9DDa?:1}L.YJ7 >GP φ+3%cmָ ST\'Xij͋YͯܫWPlD{8)͟3X'L*׏2/M-#W@K93  ؚsz58\I2<Q&ϑ-D8'{ޢ`ufdڝBGR6l%L;a'٘ܔWDMmur-%W)3e˖if#{57`T^ u߿˖S0XZֽGw"kqOܙO,C|[EϞiJG8HlH3)$e`ޗTXҗÙeOჍ lr~ 'lǰ)qGvE˔h֭n7XRu t^$?\وaHGB4[x UV2:g9 QaWW;]~El[kg[U \_]=5]pY" 9ShAWLnTd($갟H^yO$)32'._;nR7KmvB^5q4Io>.!/f{ }S)ha )hzJR#SFG}p`8w`fw/]Wi6&^,Fz )Ri:@SPJ,F2v6$'6&ĽQ; gn({4?RT0Ď^%qHԐaX. )]C@Lp.J7p ?ƭ '^ghmUDF%ACXd:zIِ@)E"{6.f04ďïHʮʆlShce e.uZOzdw L4nh+k^B-[؊Y [ףnK(ݔ Jܨb%JLd ZѪ8& Wf},sY4vmL:JeZ W?uih&4]Mhh|b]دVQ:#uB=n뺟(JJU>Ljαܴ937#<.( *xY @Axlzȩ\Vc2-lOA'γn'LvWOƹ4:'l&(Jw|g2"W?|{]GrWsROf}J3\<7{[N?f貰<ۤ}C\J@xȈ|;*>ҜzB g9}~#F"|eY(Bj&AZZVce4P7' =dߤ\4]0k-+V)͆s٦IL 6nrGasIqX4w~wy% .%73UdZs'+ZZl6 -[\Ug܀/BޑzL:J' D$;[8έ U'Z<_T{Y;EO4&1`^"\upi0\YH~P}Ptn`=i7&|L>UzW؍L5[GIUGa2 + ֧bx> _zg.R-P_ .K*R5Ou@-D\ lT|#2kڏй(CI#Ǧب S"Qdh7,lƉ4ݔqNi)`d{v~m@e,k}#j* $A;л;)J.G KVv4]pw>$sUİ$>NڒfV]2W]kTm%լ* :\]I. 61]>_ϭd8SdCz2=sg8 &_>3˜"ǎU璦>.+.sZR܄5F[ k}[ȑ Xs;rr2ښ'h>VkTqd%N&in bh2Mx=_ 3k7} *_HmHҋȵ%q׸VV?`Q.PЀqjr&v]dUx˗6LYT 5Vujs]H4_k\W쁂 )L?],K+ sFK[i*ڦ3#"""b)`u,2X2~Ƴꦺzn%r ; lؽ^DcG@o`wfE+^Ǎx/_k'=h}ޒvĂr75϶Hȃz]~3 [;k OwaY~? )!^XN6η>LFW [>kS?j!#IV;\]+~DcupbJwPP٠CZK粪oE- x}q4IJgCo͋XpPXތuh9,űfi?s|x_~rB$)Ŭ29Zsa,@22L0wr'OyF&L'GDDDDZ喪tB2u=EᰚxqRzLF>+?kUz=>1+ 3cefVH) ~i>q[̈HQ""In&i:.õSMs8m I)*T.?2N܆lHR"""".7n5Bun y'k}*#+|PYEq>*" JT(H]02"".dAUkU/ 'O%Z $ɫZ5rA]j1>bB PH{b4ϡB_aP s0^w6>=򯳾=/KܷҳLjJٶٶٸ#::'OA<`"8w=hI{ųDLJJDDDt| Y32D;JM uz+5e3G k15nl[O M /#BJR3}Ȩ,Ӛ٨u~ (7a"Y1dWj"#X8P+0V3n8GD1" j@uk=&HO8U{]> 2>߳D""""$,ޒBĐU:j|-갪ŽՙSq.k;ħ1=S􂈈vޑ'bDTR""""pϦ͋d> S)p DOdE4^pc"^0:sUN%bzETR"""" n`hoZtFǷ p}gRH7|m63u]3ZM9bDTR"""" H^ji(D {eIĔiR3ŽI8B}Iq$V2Ό%bETR"""" H+GNBοª*'uqnso(%E܏GLJJDDDD1nûUz,>%,Pdk6#?I^6-Ͳ8/RQIt\΅G.ő%!C6Y # ˲A#h?a!]|DDDD̸$  To ~>:TvN ~n}b.|Lw\|DDDD4hkzVt>Uj>@N=¦%$,>6"IBcxN=MU*(b"BRG$sAܟԵ.q'IJDDD OS[bP]ѕ2wxX0NV#"T0rs$%"""b')=Slï@%tDYg#l+?jD$)3M!@Zń HXqU>wd~W+XֻUW3$%"""b )⣦ǜBf1ni}?tvEg]_A{:>шHR""""f2"Ec'&0E}IW#J ;0{<>ψHR""""f(>@GGBB@~hg3t'Suu҅?9k{#%lO`n4#"I\M{"kI|z ùNEp4v@8PHW㳌$%"""bBitaRh3k eE],r Zũ?b@,0Q`'x_a:wɊ,G4rh,L )D(JJDDDDH3V1rďW?JޖthڂISpV>p>Dk|3Qܳ؈㰆l{X(.˳ q$ OhN"EanNAūt>|I-k0e*EF(JJDDDD]p/)y`XB8\Cy툣xCxCgq2ſS쳲HQ"f D%%"""N$2.>hfj:T-7=T1 /QV>hΰ1t>|HR""""f~r4c9&ҍ8=ߟl@GQ;/T>_U$,>-"$9eFG$ bzgq$V(~C5.yc$(_ZD$)M68[k(K;Z?СTƼ\N|fDDDDHzҧ<;9@|z5as: 2Q!9ڶ'B2XD$) ҡ(p\}؟(w +'"""IeKkE͸.໳),G~2o!h}"Z6O+"Y >~~ׁi1=vlaPPQ,1XɦYED1K!Y᫲礃Пk>A_td!Nv˽yf|RDDDDD ]Gbc +&-!٠K4n{mDD1K#L𑴮V> ȃ-~I-;M&bD,02Q? u Ӭf?>6%ڰF1"*)%(Q>,<1iKQIhndlT-#-m 9!"gIJDDDDj }DK h,^AFNO3tcS$%""""D AHS.9t'5Cҝ<,>HR"""""p)_٠T@- A^tw6[f Up}q| DDDDD܏8+ &US}r?)9|\QT13 EDDD4i/C|"aYVovBF̀DDDD4{m,WH THG,"fD%%"""aH'k!Bfh }IT,pƏs'1s *) #IIKk 9!EM!Ur[<Q"fD%%"""HhGYF XI_H^l"fD%%"""pp3 S7ߓ'*XG?-* y5tBS3y"YA&%gV'}ܔ "fD%%"""^{|'эSi12N%bfBTR""""t=||ږ1pQ(DDDDDayz! "G2|#{.EL\h<"r/EhRG7\`|VylHR"""""JM3(t(B[p'DDDDD]Dդg$4,hɹwܘIJDDDDDiq~3Oc9% +\:b&%19"""O[>X&@|ݽn3'npxFt T/DŦTpJl爙QIhG #tλÕ?O)|!p㈙ϱ¤Kݦٯ}#ڰ%%"""^"3< EGH%/)J̍DDDD; h )\rY?"X9SEcF̈JJDDDD=g!Pm!$HS7 Ί%bfGTR""""q[U}*J>6%1k̍DDDDL]f1WRmXxD&*)S^tCE 7M#fvD%%"""bFip=Q+-i~-.%"!8~V$3"-DzOIt e]>ٶٶٶٶ2>;‚y{Rl؊ 1%DLJn> jT؆1U.ģЙ,?9GW*>[3`ĬDDDDLUOZ_EA?\BDRJJDDDTF ELE 4x ;7/bATR""""2;H޿LDZJJDDDTG:甒'$VAcxv1^bXuKaUnG;,RY QIH7C-$ea0k,n1 b?#E$%""""b^DJK1g$%""""bBGZBe: Fq""I*pS08桼%tvlHR"""""Z|LGsDi[g[+"W k#~1Aov2mIJDDDDeusLJaOPDDDDDLU grJJN*[DDD4Dғ>W»3!ĬDٶٶٳp4<9QĬDDDDLS$s'蚧'򂏹b E̺JJDDD4E%.qGitUbE+n:21>TMCV9%MĬDDDDLs 1i9}ܔ621>5RYQIg: F]"fmD%%"""b:{MHQ""1] 5E܏M"fuD%%"""b/HQ"""I~p #""=bcDDD1MM3b[DD1p6"""b:Bp;4DDtM1MLOc;DD4a凇]8X9l c n >a凇]8X9l PNG  IHDRR3# pHYs\F\FCAiCCPPhotoshop ICC profilexc``$PPTR~!11 !/?/020|pYɕ4\PTp(%8 CzyIA c HRvA cHvH3c OIjE s~AeQfzFcJ~RBpeqIjng^r~QA~QbIj ^<CU*( >1H.-*%6CF>,ƳLLEXXXYXxئ+opYɵۉO 92~y7턿M%>C"\R\5[(nRjRQQSzNmzF#}:u d >2:ndiYo67lO_0qSsKk[{GEEEeu]S[wD`dxT|tzLAle\s|_¬eIO._@bI{nt^~~kE'(,׮pLQR݇F& ڮN]wDI>K̛zڧ3=ΰ8?-\s|׭ظj5>mfҦƸεQo?q'Ϝ9w¹/sk汹󝳧G?c'O<rݫo 2016-03-15T14:56:15+11:00 2016-03-30T14:07:54+11:00 2016-03-30T14:07:54+11:00 Adobe Photoshop CC 2015 (Macintosh) xmp.iid:d446c971-3373-465d-a995-0d824e04afc8 xmp.did:5A92B6874F2068118ED2E7D848338487 adobe:docid:photoshop:f366274e-36b2-1179-a6a8-8c0580d6e4bd proof:pdf xmp.iid:87197467-7d97-4df4-aa07-b4fe0fd460aa xmp.did:87197467-7d97-4df4-aa07-b4fe0fd460aa xmp.did:5A92B6874F2068118ED2E7D848338487 proof:pdf converted from application/x-indesign to application/pdf Adobe InDesign CC 2014 (Macintosh) / 2015-11-18T15:28:51+11:00 saved xmp.iid:28af550d-9112-4584-9abc-1d54556eac1d 2016-02-24T09:39:56+11:00 Adobe Illustrator CC 2014 (Macintosh) / saved xmp.iid:3e57f33c-95bb-43ec-b90c-7bc3bc4be11d 2016-03-15T14:56:15+11:00 Adobe Illustrator CC 2014 (Macintosh) / converted from application/pdf to application/vnd.adobe.photoshop saved xmp.iid:87197467-7d97-4df4-aa07-b4fe0fd460aa 2016-03-30T14:07:54+11:00 Adobe Photoshop CC 2015 (Macintosh) / converted from application/pdf to image/png derived converted from application/vnd.adobe.photoshop to image/png saved xmp.iid:d446c971-3373-465d-a995-0d824e04afc8 2016-03-30T14:07:54+11:00 Adobe Photoshop CC 2015 (Macintosh) / image/png Adobe PDF Library 11.0 False 1 False False 190.000000 60.000000 Millimeters Black Default Swatch Group 0 Black PROCESS 100.000000 CMYK 0.000000 0.000000 0.000000 100.000000 Document 1 Dot Gain 10% 1 6000000/10000 6000000/10000 2 65535 1106 307 cHRMz%u0`:o_FIDATx]wE=$ݠʚsDŜsq59p%)bN`Z׬k9q3V+͛uﭞoޛ驮pԽ#"""b ]k4O?ɸ?GwZۉPo Z,z ZG~gxWוW@[hsjZeƤάN """Sx*ݐ睩$e.ނ܂i-ߙ .ӮV)B/f/ҟΪuk-V;@|Vw\08rfPTR"""2ơXV`.lРPյ~!QGn{c4R. 4!-v~26 }Gb+6]J[L],~cfVASl)_X;}[{-ZT.Kě륦bΕOSߎI=?" -Wo|ս 8E s6h{U'JABאP;kwaDn_rE *n+^բX"'#2sxi׽;E!oTԀui KI2h婃VAأuZSGvH;1N^W/|r8 rw| x: y“ց jFȜ?EFT0`(R~p,Bu'd^!#EJJDDDD#9狽XdcB! t S-`S=!Hc%twyBm߰JʛJta !0J0z8.g,侎c'vF%i&. NMLՃM̠ﱐr""<Kl2E35:!iP&J $^3{>HR""""&IYchS)_\>SW!luKH'Eg%AA^ bIRBw!pҥjstl% n8Z"IH? uKd܉ LM]8;4r7`7*Xk"%!nῇL >*(ܹX8"ڴʲ<4~@#L')wv9b : \wI~PuTI`䇭w-&jvJ3j2\bYᛄF)DDDDL rv, ϴ]e @ޟzL0-hqWM/A址@n8M8 کЖ" =)G,,+sݭqD1-HZL~8% :I9MxwϫLB"]*$]sy2P 5= (-\>ŷ>kQ9ͦı<ԝcok7ͻS:'fGOFy~O Ր1f#~|՜1{ôCs {@~1iO$( ǽ_Y`*.a= Ԟ"8+f=!q6 kM14|@62HR#]6J.b0NhiavXWy CȤ1~ԙT%rO{ԥ)VêX'}ox_g=}5X]VbÅׇ1랜|.r@5tnޛ>A7]k&M{CedK-QjÄ(ÇQ2{ex -7Lz؍l:/nãnrNpawޙ@7`{q-jޓhwaC; ܽFu+`L [{:#%'<ɏ]|$vvnb*ۮZ<Zٓ}܆o:Xfw6X) `.E$^3tђO0?»x2oۻo^-yؑ5O -t%N)w׽ܸRTiQ۳wF;8'_!A#W>ħ`0k/ 8>s%z%`@n/݆[Mv%aCad܎xXWRN!8QMu,vPX5JBZ@Pt ֪aTt!k"mz )4B. &xb[g͝:-E547 [ҵ0LO GDb(6XY ŨSj#< b$bOԥ&Mn9{Vr!PO!x7}093kGK຿?{Q^ I╟ϤKO!Wx/>#%jЂӽ=Rȹ'FVΆp:F[~H]H-}GT~ۑwƃx7>wE ?$MKkT)7oXJ3"yŸ[_~O%U'7kiO=UoeS'\KU2&gGIJm:!^B~"￬@˔B֤͊Oct>¿0oHdHCvg[%[sC/%m}bYgH{!9q"G*HoNŋR˒GޕY,-e rW"م+itHO'xj=]MnYdҽJIԕk6djI7tO oi-",/,]WwK-{5X ~6{yq2ő>Ej=o[%!uE[ht,T!Z%goDl{ .t$)œ(TDc{ dF쵏ﾡUYV-Ҵ̟+*W]IP?N 7T^ qÅ7],7H iYJA㓍Md ͅ LlOsIR,._ ;&Xtww&er}ѱ0kdj;*kܤ8=TSH+U~jGHџW(1AzӇfO'j$ZvrZ(k\}!xpBEc{2r cӰK|E)zSj j2U啝䷍,Xa$4&izi>?Oj>.XhI$kdk†njS 5]8HL˸p*R*(,f'4ތsAR҄ 26S*IPղJ@V;D]%څEڱ)l5W&̭\l )VL '3CoM=+[9fOjZ`";Vxb{sXӡCJRlBVYD$1].N3=!e_Hb'IDX Np >vw2 t^"Xyw%cAL*+Zc|M7Y*ZC,ٓfe[E%&)|)Vw\4IJˀ':$F{υÎtwZ&X2'`F&udIJʳZ5mFRqȔ$F%U:9dos9 )aWxFU D†$*r俅=J%J&ߊOCrI2WE-v~Rwܖ^_'\@6NJSB.J.I39X;mVEhknٖARڵln2.ߓR{_'q qSm+˳2y>=,GB!/#<"˰#25:Ӧpji`ߪ(EƖB:Rz쭮;4.IIL+w$Sw^\ hp`ډ9|cf`П j)rV~{ߚ^߲ҰV6{yOE8؎ɸ? [FI%EKaGQVnʣsKkH:{r5] 5-nRh39id{Y-B3#ղ?' [~dFOJć!{3Z-r6O=Me.'WPYX [m%A-ϬF$^_=<[n-BQ1 Oz0\0k3ۭjdWgW6F)eir29Uj-UENT#-$Z]QD4yNF9W88$QBx.١|]TPȖU8n5x3چnax{zguh^Y`0djO=6Iޯki1K*藁c}bkb?$,G~t8k줔jٯ T1aCpˏH!tՑ\Xhzv!sf%cTco `}ݰp{q:/U,VQ",vءUDGO(1n<Gc5t^pX ;xmuqzL/<;->.6C-+pE7 .ž`z!+o-5k^WXI.I m>e,Ihݨ艔%,]g= ?pVJt!dRR#O xZV@O=5A̿ng|1VBG=Y9\TmڻYhNƶlمJJ $yd7GԮqVLv]B(g8)vDl,7UdR1k~jVW *4QEQՄERn/2wRh w0 7洆o3oc^|#]=ټ b-|&]]|'pIhcK¬=T'+= g,= 2խj1T, !]Gtƍ2Gxfxr=>dOJFND2E˒*l,u,XK 쮅Z?v *HIthETS'7vZrOOͅqw0Uu:W28b{ŻI7}0ڟz@f̰iVyeW>mm!Ǧ%)Ӄe1,錎e~*lJ\#ZTzAHBYiIٽִZSQ:`D+(Z'#8Kdz厦NX.dCg_C:Å:T\Y#=ba?\jYxR|/}XV[J3pMJsj"Ɏx7/E|S俫k,ld  03,acfE֬R*9"x9y6O&)w{[w#,6k'A+u, zVFȈ< P,/HgtU\#IIѯ75$!0u#] ^Z|- f?϶᚟3TX]lg7Ťiw{bR5tЂ°2dj٭@<5]ߖ޿~}.EBdX /Kq0!L6ig~ mUS^KdMIU.P,U*8rqGR7I+I#驘sv`-K4l>_[P5~ںp:P!} ?MrVR߆S]UEEeEor6O^w{ͳߙ.m)`d<c2wqv6o Yѯ&<]X; gc ΎHog%j-^ړ|o^Q^g=z=ESJE,=fpxh/ N+Oeu-:!R3݊?Ν%yKΓm /e \0Wt ].j nlZ|j9C'Wyja0IIjvp=aS<7;μXvߌ?ֽK{vd{;i3ԑIGʓm'k *)bHh{fajVS ?"(PE޸ `6*\G I0M]dZ~5DrਧgC7bgNMUk[0K%XsJBDžr^O\n',JLF_6yY_VPrcdH3LsS ϴ 8+΋Kr>\MT}qY=4!_dLFQt`葼? V¬+^0`?c*`-^|{7)}99҄ڦԂ,~qQ%-c%Ü\sO&xw`Eu4Bз'kP;+#T<8N-Q&S}to/q%}n>l,pp\s]a(yؕq兰=YႠf4Y챊z'~d {v%1/ab_Vq,wq2H={Uo8J4'?6I%: ;'ҵC.tqA+%urwrXh#TgeAMl!Jދ>oвQ<~Qn;˰v8R#%G_qlqn"/UK:?ަ;*:J U%ŕSi_z$wۘ󚏖uֵ8/Yc]˙ fYW\'Mufm$Ni&=\vg]m&Mc'G)XsA{d PuT57KtJKxơg@O/6@:Q%S[QbDb9YXu)0*٬NkYc=/a7`U!8$}GЍY J/C/F# 7X e`bl6QLMRx-@P·sKIoc/XڴO{:y ޚ&)\b AtQd'x?|P2,p#}糧z ڔG{wW2 eO%C[!2j-PĞ~p/צz="MdI6>s19Nߧ" SkU`4]W˂D<֢2\<H.%Z|8l= gY.""'2EW00xSrfz9tPeN{Zv4U6ӆ5gxbnp<̭]n @z(Z5}0dnUܼ˕D i\'CʃH%kV-b *jT.~:!{Og@U׸fUIV,5JiV,TE٨cUT.Q% ܷ]P XQrk5_ K*9`Wha+܎?%s%֝n)$*:>i@%DNִFߣ(Hm_иGHb!_ohBM[e^^yCr@uX0œ +2;W t %p 9V&SSB`kX^.QJoU szUMs`0t,&Pu2bX-|,G]>)ǫݽY l\;nZ$I"q6(ggY >;C}aLr} *S}n'Z/QH5VB䁰ҐI.xL6~TK(I5xU٫q1| N]]&?{+|س);w|C&0(6s^ JW%^a~z)B|Z#aiZN75HMxH\hTL$S_bPuDdqF&K;oE%pv}b>|+(tUmիhHs=6hVzLRvcܟi!ڃ\i5%a"'Ӻ7hѢFThIN,5h""Imʸxz{*\RDE]kAŠju2V.`2OCy ~t: %k: d$M)_`FnX<2G(T d>e~^])7/ai|7wn9 w gSaƢXOGk-v@] ɡ>',EɊLt72>窓zj'27pjLVB}{".!tI+Ի%N 0<=}jj5qREB3sP3s99 Q>$V@K~bZs+v~@YfK2tr+)&Aj}O`%r\6Rzv`a1pfJ}g7*wkaSUcܒzzʏ WFiM~.{GܟVDM F߻z*g:y=S =GN qDINbԽ-P$ܘ;ok X~bG*X/?$b;$>! 7c ;) Z%|@] XOA{B)}LR5B r2mۙ멚JO&c,)֗8Fzt8lPr_:0dVbt(AL‚K+:{fW&sjA:Xg%E*Ib\͇n-D8kG_ ۗ@$lxxGN(֊uѶZdLiD>O !{}6^ˌ"R &Ay=2,M‰O{ }X44U@X\ӮM63Br7 ƨddb GAĜee!{$O,Z$W7S&i3GC]흿`Mx$d|,i|3֥,_I^tU">hնe۰>?JZj*}R~%!~|v, 㽣(ָ'"}NÒwVQ@8RyRADȨ@mӡwnpD!Io%c֓Lceܐ𴔿CMT%Ȃs!X}F'3XhUW&|"v{RT0Bߴ?-j-Te( !<|/BZBE$M!$,Q Dy+0V*oYΤm,%:,KHjeKc1NAɫp&-9+Z%ץo:dGC2c ܜ`=Hf(M^DD@IkUQSx1Jz7V%ӬAžuR5 /lG6h^-֜u7^ ##w~htr{ufZ"3gP EPՖ!ҍM*x $mb&&VFyP~'p Sm:LJTX~p+&=?\Rbڹ:ӓygoņc-{0x״ I#:Y"MM^1 8I9ej,.pD B6v<'VZDyb˂QN8pΕfb6{_k*XID.:(Som-Tg {僗I(VƇ VRbi7ܖkN?l*$٦B 34p#]TDɈörn Հf6yK< FlC ېOCVrc+uwuPP@3ĸG )rmjJʻ};Io'kc~oC{/HJF^#Sv4ʋ1jYQkP(G*I7:%b2rtǦBS;kީrG|8^#S9D ",V>yrw0".W{2N+7>W|RWm>9H&>kA ;KA6іl{ ;8hcӛ@=D)X?GѲ*eb4^Zޝ}I[a&' #ud?XwIiV,"O OA`/7yNVt}lU{U:PO\@m3XƘdhr.r+񺸦9'fvR64bFY@ÁSi܏q Nhp4'ə#ܨK;䴘N1m%Ѿv5#ճNwvv;%s } M|@6Mb h$yXJez{cA.~Үd2d:1'DB\Ϲk[-Ȯ.)[K%k:Oo).; pDmt.R5ZpOڏIWOڍWQ6ƴocXԔF8M-ݡԿ頁U/%dn:!_n,1Xa%_B ގa]W1W~ b q>ݏn_~Ћc) ԝ lG{.;FD4[/4 4 wt?Y}%Z(.h9"60lV~0N15zdyQ_벞0ϔ2L90Q#N™q(IR6NiOCqJVr}ͼ{;&G̍k=BЮ%/bjAૐc@ AǮoOrNj ̮emRO{!@JՖU1# Vt}9ŋbuOk_H)k3s5 J- 9tވ!m_^U$Iw]=n$)H `/zBR (FM-T.,$J(BRgL/"t o.'lZw˲-*=ȼ=pGn]qFLf,Ob5~MRDfDK[[ ؊'/ͯ"PFV{QDb,k1@)HZSO‹q`KάUE eHh-!Z%~.x:2]̞142S,פ`^]"~-em<,ENxШAq8^OHJtG|ohap|:,D+9{/.I 1X%zge/ϣ'MJ:ޏwu5>ӒVk|ؙ bIq}?(C"弊{Ϧ$&6z^Lae݃~  @ ҁvʾKV6{:Gn }(Sp vV|ykYzJh܈lObbq<4Լ.UiиFERg̢zpGޓ,Ts-=i8^H,9_ۍ4ܗ.YtNMzd~JKE;Uȥ>߇r=/nu=Zkpw.m =6vPX4rff5XL\PImGgѦ:ͣi4Fhq:g_O{- ED%:DA뎤bV~ĶҜ̚Q'&T~MonMC f;|w g ^wv-ޒ\ Fzah̖O`-J!7&={V&r!!|_zGrڬ~ƒ>Hv/#bŦ#d/W(ʘe*ҷ"HH:;7ĴR>,ѡգo'*򱷴جɳ%C/Ъa8]Uzr=T5 A~Kκ!s"S1E1D#g8Mݸ;Y -Dmg"ö.I= oD[{< bxRժykHi{2[MUƯ)/SOkG`榮_+wn{iA[ƻ5H;lVv\iY}[p'pgt-܂y70֚}r)%9MԓUSc3.P>PS_a9nq򆤈 /Z/՗p#]^ y862ƩR&gӸJڙkg,w^e_L&D5bZDDaTꕯc_8]8BA[?Nhq፨[I?Gls<z{-7 ϯCmo$6Do{%Uӛ;b@sŒ@F>)DQr{jseb+=2؅bD  u~Ƹ*j|>v]B4qooh'YפM8_07 "׎rxH#DE lV}`K}xY~VMzʝ/At˦Y[s f,tT£S=kpp2_g*&\`@2ʥt)iE L|g\v#A.*y0|9ϯIٞU+vB CpcQA&B!W3Rb~ ]&ރIèUI+忍W3֡A|^ŷiKDk+6P0J\ ޴3Npǎ3pC69p h]5 ֦0 Ԯ"4L, Nz-q ΐ2boN\Ez@&B֘a n* h@gC@b*5MZDEY0;c2Iٽ|8o"Pܚ6݁fm̧d֑~ OG/iLt26^: [Fw >ÞnJ劽au-Kԫ2nA%3ԃ:/$kx)ӵO Pg?Sgc QSd_vаz})R,"4F<$MuJ:@}R-m2,MilY^Iy'TΫ)eo0&?~p]ǓXZ5r\݈6#vqllz~7g2.Ѡ2=,x}e,^A,vUJQi%h @+$=qUKcH |[ HژF;7D[Nm98y韷eXlؗ5T>%ƵӤJ-͎X³<1 ׶n+UC|H"HbY!-\Jܷ|^ YZ\&eK2h7}JY}휟76Rђa:ߋ߉uf(KJOym%h=T䰎Tu(U>G2DD_BeXU0a)gXh`cF{oݩ+Pus}2nwG&P1IR$ɣq疨ݓ"[ijy%]])c/?jEi&B4*T @лx5U]~Pa. &UTLLł;8*(#يб>VYc0 ibwysBSI7т!>B&p,fAcG4$pw` )U"*pFOk^'.rxlF7$BE,9_fr9ݡK9~q/Ϟ|%!IspR-I\6Yp 3X"́<]_< 2:ڣNMfx]&n,b\vkI]çuW盪B74R8 yg~RKN͆Cl3".yb ]J?濕́<ݛun|\p#DR8~ܸ}:^F6;诘"w᾽=RKϋX-{_+0XboΊ*T06/vsPxl\M7-WdQaJ®+1 rXHXD_Weu!yآ73Bf[iBOLOS-W/G*շ<" QTϚ uv%MvH#& Rq$>./atضeAV3ΊmDI >*ʝn2Uigl}Wfy ߅arW0٘zv:ՙTVNTbfdyZE UF^2MkmlB_A + KWEη]l=Ok[=q^MZ (X-đx _jj^A|q^+:%czˤR'k[EaY(q>M"nBv q=MQHҗڞ Gu}ۈ +DG$#1XRz kgHk~M!TO~߭0oSdξ| qA5,]KT(wƆw/HYUBW}Z#{%w Lf!{2Ȩ. E@I28rN*YV5d#y}`2m gp{6%RoeCw{Y0I6BbJ󤇽S Zm ƟtDVR~< SMr`OI#c>6$MXh!B!IPQ j6MJ~*?"Y}RWlHoD[vؾ_sV}ϯx3 l8ٛndCeH'V//Zf{rWaMnٶ/837LFZR#xJ.P[c{msҴR.xw{Zd Ӈ*SD&_d,xacIU6W"M :`>HsYVˁ2^kOb.$g74" Ձ19f>l^J'ܤ=NF kN>䎤1xIukas~SmnW42wWSky&Q*۷v,&PZ/VC8p%PWkذ{'QT&ɦTSg7j2pǥ2k/; 'fwekM* '6ݖsn[Z]';FZ n;85.FR {Ka82k8Yuq7~_ܸxvg64N>>I f'db`nN 15A *n/T$s>Qw=𖱫#0:˸ڄ1ԡ'Ѳ?@$22թ/>Ӵܰ9?<ӳ O7j%h5}]/L\%3HX.}tφ}LJzHc~gT GZ""ډ@;}p/XsoX7[֝{gy>:)ՓH1|&.p?~_MB jw|sƺanU,n=JhnXMlrvKRNl+1+!v#S,rm'+$GP}Ox{էB-q7<ˉ8;Zʗ 7d(l=R[#Zߴt,̯ $YYRf+<=7Iw[+b`mJ иFTRFX~rrK ~0{w|7>J$퀾X+`YE/{;g8wD:b ly%%ݨ\R$E+/pLFe{_ґf|W-1ݥGe Ϡ4ɒ.%JgmȦ!WA %ݬzC~nY#?FqSǓ9eĞKLMB1UIJ2 Ҽ0u<u8o>(4%ٳP^Џu2twFD1Ӕx3˾hyr%"*!U {YTHtDHk&aRr mPd>\fґi&rPvqľIJDDĬNR3\taUԉV>Tź6Rh*&MC_p= tqxN M}3"HS&RGGlLAĂ(&(2!] B{`bXYN_pNgE]*ldDDDD 3]\y2COe^uhcS2˾k+y3J_k&`[6;F icbDDD pE M%_J_ ҷb/$H 呔ͪp]H3JHSϫAG#igCx>>TiDD%%"""y/ n]nʿz_vsdl(G)lHk9YR!xTASgI}/p ]>SO!y,}2"Jmz|bRXe MՊ Lzc_U Ѣ죟P, >a2IAm̖{dD$)-K*cK@pi EK U.Y/D#4@Pa#ia#""IT#p~FB MS^PL'YLRƃѕQ&/I 7p 7F1:`~bK$)Z荅hAdx<}Z!Q0jCztE|{mO*4"9!FkLJ:Vl bq,UfKnSE`ʫ( JMb a7[ NX%PH0նbEou=" m]t!`M-n6{&RW-5wL1Gz/=VvjP{ "IdEzHr"8!X 'FyA|}MWK?aP'Zk].~ß%m8l(#٩_qb!͌:´{26YSHL*-,61V0r X|zzQ6IXr*P7߁OӞmaJH7jP)Цv4 yx=\Aw-Z|Bor`;kC76xk,&EX= Z 6w{%G[(obۉ ] -H>)6󲵫ʟ}g(i'>ΟQ H̄#˅nI]>׬hd &rPZ[J[=JGe{ :INAK|kiL@{{X0E_=`^>ђ%\ﱫ<> - v$oQVG2c62'Aݠ/0<~VP1};$z])#>{^(`u$$=[7G\]'[ {!aNi{7d jwo:*dp̓"Ih =ؽ=VB#{m~ d̩! O$s:M !qgh8!IJېI\90B Ҹ蛣pKO94|[1`{hwظ~禸w!@4-$ bsjS-͓R#r9<30boi,c[ZDo jL,M]6Ur>$mP#IW2H6l¹ ZHK &_#b+wR ImTRdHŊKJ O?r11&aX auQ/EY1 6󵽅|Ex.w_N+wvi/L߰;HM#+!Sᴒ-Ͷ̒KjqD#fG%*dl"N 6gw,Hz VHKunU."IhZ:Z2T(@?|ELl+\a e[lJ6*)i75ޯ|IYN #e/sbODZb@W[sWLf[Q=^X'; <vpwgFq dž<$N Q A<*?Iz.lּ:u|$[d@ƾvpzdnz&)Is}Al,Qju9 tFeQ޺~xل7V]˒\r^:2"bޖ!bNM*W6]OUtZTcIH!9#.SoU4UUp?#3bQ Ԣ䱷R±dղx>Rgmjjc`t=U3Z%'>I* "2Ot}c kl\ZB$Y3;=E~:zJSq/,mO5wبlCZkޒޔcU:J,'sѣkEӅS/`/ܔw‡HU-l#x>+COD~6aU I͢2ԔƋwbg壋ze"riLu4uNhỊMYO|^9&m]8 0O PkVQ#ظH!mdn մ#'c'")ڷwg'%UgdZ>I.?9;۲(Ḏ&sҦҿ<]E`E˶ @&^ g݊H"DV2%22_N"䳊a{aGĴ4a&3+QZ%<R@oжOS`ha󰧈2PNcZtY(zVs ~qpS򭐝; \2&H&oyYlr۞m?+ΰ@y\ ?CsJfc':-yڰQbvCw<D2{ƥ :~qCz.W~ֱ:^4S-#*#Zm3>V\^Vmg1>ӨrW"U}sXwTl w -Гn=W>ee:Y^wO{e,Ni Wh 'D &j) }}UEc f}+Rfr.r%G wv6&+_g\e,%;9'"&l^\_z֖}B~=gh[(wh&<",~f%kSIIJ0 Np Gɏ1)3 =/tiVI6k~aA|uXNSG7vhCWK7iTpAwZk0]̛Q*;_J2c/CQKQ{\qjw8$E!Hާ;*UV"2G:5tvšx7=,5o,]4 BӑEƊ3Z3hmCIwsQ 5˗rec9KhNk:Mq_YK7ޖEإO$efQSMRI֦[rtm d\g[,D 26o-Efnѓ=\jY *Tz^!ZM:N'=r81)mӴ*QO(yç p#ptH'-l[8L/dUKR=`ԡ{עMYIQn>:" ;nPRj7xφW׌I̠̽9ZmzMC7B?aԞ(~ï*a#xtŶG!Qb $7xvUPՔ%ҹZxg_KɁ \spJW㴔*[{GN襶ߜqP8NW(HݍW~v?9'_;0be p_7~e͛Q5l,EElSWM7$eVQ:cRRp@K}O#NL m.<ݖ\ڢ[4>a2R9,)>< ʉN<2}&Ɓ(KNݫa&u9,&Co,(_w4ys'Cܧ!)60vC2HGsuՓp:}XT[' & D}{zfO*m`6H])Iʌ= `vj. >]S9,3'hSUMٓӱZ,܆Kji0a~ExLA^Sj`ަYŎϫchg_@RC pq!=ߣ*cLF-PmvRVk1 vv[. UiFvjl1ĕMU6 Ǵa;\c&~J"H*?-[hPմn Y(=:U2gd'|SiM0?aWG];6'^HHIfnP_~0d?Ywfo$0^֙\A\Ea{r;G8z Q|r= ]"5>椠-$2oM'p0V:ВYΡo˪r~D {auY &3kTfZJ$)38hkko0T_ӫL{h+M5+lK9}Da6I(E> :Tį+h=ߤ)MS淽\.?RMI7֓lmB;G, AI{̞,Ke'_ ۋ flw͛8A>IJ*䳢ոW0>Ʋ-դD3jO k!GnO`L}SU#KPpj5LLÁkƫO.S؜_~8ԩt0K Jl.;(v)=tO9*9l?eaњeO֦p- J?X=d,Խ$S9f5yu 'H#HRfzk E٥rݵzZkr%AN+3I6l K(;*?ZIRub+҄5̵)GBC% sXtv](H:݌::P}䷼;NHG=tjl=-TV.o2}i[%߸ /CbkiIk췰zbU#F+r%8= .#õ0%!TU5%&8=<^WHmUbH6f# F2ǔn$Á[,r&/pG*caw6i;2aK +9uwxr-Վ[Yɷb&w5ذPF-BF;p=ՖG fx3Oۋ(+m+-Jxނ+ji»QMF2iHSYm~ #gZjqH RR"Iu;?9VǮ긴jŚU@_Huu:2Tۺk֜{~~AtVR |0(9~x!+vq7>K5Uu;ǽQ\8cԽ!xd_7W3ȣ*2[ߓeIŀ8'׿eEV{wA깇O{k f 9&"4.< Ƥ aGyj4ϑiHRfn b!~xXЫ {#n#n)N|P|$QDBb#Wo!~͊ 5։\^by8 KKˉ&+oʴ_itzfki)T۬lQ<ֺ۬DǛYRlyMl[8ʦgX+:Ӌ4@7d^{޸_(ˌtY# Ѽ犕,2/ E5+1PJ]$eQždy $4%U_7 kfE_; XG-EZk|VDM~hXZԄT{r{Һ_nrJ@^*2H}Zy*MSy]X0j.UYxɷmdΉD$xQ.ְF_0/`OzAf+@*hUr \9K}HP?T{ﭜ;`!K{qIMu9|4X( 5|WV.rBOyBk@][1*52bw&#27U}WE!:WJ R|=2bZ Jxݾ]0>fcr,Ԣԋ.OoK{N~ oJٱV%ߴgk QĒ &ӏ[[^Zͻ UȜvͱB-/a,f̨:8h2U/x)}5ʹL~z( qK((\^'W6=fB-sY}`_/%*}wVyݕjE74!,^Mw] o~^Y|=98];Jk+Ӆm)ЕܴBϳձsy=ܰTɜ;>"<;-V-/e{}npV }+\ڧ`G2`-dp%֟$*M2{puouR/]{۲^u|"xV60*sok@F m^̷5"HZ![cRVK4rH# y52O^PfBJY/14?JK6Q]=5ohѳ8jRe4sZt;TFx<% ]C @bKud {KV,ttַ}珼<ʟW5jFE2c<4},_kX2sd gQחoNjj:;Ur_( ReD `YSp+KK_ÙZ2˅ovd:mH .J8GsH̸P-ېQěK~*J˘7).2Iʌt@*<9S_w|AF~ByZ@X6\To[@gLimH@7xŎj<;M\Va޹tޢ|$No{ {}4J8]eB,$`Β4j6=<&ጺѰBrMH]={| @ LMʁ#sAd7?aN 1Ŝ|oe菣퍏w`5$ a ރ9w1A/䟰]ߴJy$PYQU!DV?%?!/FNOjr(߆*!&cCdh5-`. H9n#׋Xg]Ky3Kl s{Y1NJ_YE*x'23*ڍbii'$ӷˍUBSWcrᚚX:Y= ׬*2շmKWg@s^Ne^%]" <$dn;ue7XBX%1Eqfa*֍Ayd*啪&+Ga,p,AA=zbyTz==] ϖZ< }e/ІG|\$)3ui?D;ҏ"kJȒ^l7A۹#t@';9[' #!5yZ I}2d[Y]hg2Q׃O)X [׃sY7s0;KeȆytm8sZ)ZZk l]7a7O^ݭc.G;Vv?]gS *_>W1Sڋ'xr:Wֲa%?< NMΫOCK^Sq)3Qï;_z Ył\jx#%W`FQ :i/R>UϯO]yDj-{ߍD o ǶgGqx'%?0sM#2>Ҏ\H-yKZB~ʦ28k)SP"֘J Lf]9XؔiK2^W5p?{ߜN+7[[q)(X3R!gYɵ .PO tY.L;mR, ^lv0 9d@Vd"[T'D;ki}x&Xͪ/<1$W$yI`lRIOg¯7mdS"Ž}E8q#{tvl#/ldhEBun:Qvbn١[ <(WnzWҾ7FFYfd|{Hk#?M^_"lHd0_ VڀT8l[U5ԝPffΧ*MhX^%Y^O_ÊR3Uw?=v߉$eF@`Z9B]K;e37e2q \02 ܛ.`Ǜh>S@-=pU6ZcGV&TVبƶt6l#9 ԝ;=hehJ,\FT{r:ZIJ8D+ e#XMNcT3jLiiZ^EhP\_[/=t)1J?'s{ښ oD}2 9YXoxFSjݞm+}g%N1-&Ex@c*Gd xͤϹG[7^Kn·S$[+2/"]EĦ) #ZJ@zuU<i Wv81^⮲{VST2OI|(4Ǣd߂Mm-_Rָv^DnC?. B`*=NѾEA98DpOhW5wx{MU8PWtAvd΢yZzrcPVuKM/ ҕVlQ:ue՛ҧfu͆tdciyN.NeVIWJ,cYz h:JO;!? CLH]FӉFAO`v"(HzѡZ=2dT 1keU#/CRt<0$w iP?ꄲ+lP|LmC=S˒mg[kP{c'[֏a[P65#Q]:G?żiw?=mmρ8QS6ĐQ7fBb|t]8VdR嵃S H:@)@e'?PXtqn= յiE);=};G7.Md[$5+VμV: c|_S*>O(*}tkJ^9ioO&bJCj$+zAH^?M?VTk^s&@6!;UztJƭll|5=OlnVi]Ҏ8%HmI,zE8sO7]iHٶqeT0ɦy(?PX|2 %/mgG2(]hx<'5 .u;YI2h6΍' sap7^=-OZEjpٖ!W4 a ˽ lE{N5dptcraCz{0\{ъa]z" v͇>۪R,!?%KHAͣ0epNvN'U@ǯ82[KKqIcD64MQtz]>(60x`=tύt&Mѻk/;JsSaeJ؅JV#Z_'>^IOJ[9Q2b[ied C9-="meOgC9A.K׎$eEҁ\=ma.dr,6T%b4 v$MOf[u''wwd]qZJz0v^v-`zcpğݤi7&8r6 H䵋2}g]8^Gd,WnlD[P6~c//QzX}`p7 q?cCף_ Ƚzq/4o>.m K/Rˁ:r$v?"s!E2~GK*Cv! I_Ԝ狴O2_SjSV0ԐC ?'O(V&opK'2@cO,Y*oU-.-%YgW#ѨdǤs?·Hr ^Z//yhZVsp'ݟܸk(%fF@0dX{2݊%eMJ+E茓܄233&d87n#ܺ/irgٞ,aP@Vv˝{f AO-YG~!-ȝ1 -az%>IjmM-mt19M>@Nh7ssnt[D;`.#;=kUB[PGgHR3s]񏺵7p I @M&dJKy%NGq|\I8~LGrwZo~F1l͆6 oa Ϧg5>-&ׂW8;J̍chm&HRf8$l$2l,d B_rr64HU<5bcc6hay6*aɡݘH:bidb(m/92=}S9kj~}/s6^k>w tom僪R4ba?TԨMrݻi >FZ"rv}y{Zc[Ewa#(p\cez%-Ѽt"+׏ȜQQwKb}k 1S}q_.Zv9-]ns_ T1{P0_08\ÊV(jֆGIt.pe[dm9DDa?:1}L.YJ7 >GP φ+3%cmָ ST\'Xij͋YͯܫWPlD{8)͟3X'L*׏2/M-#W@K93  ؚsz58\I2<Q&ϑ-D8'{ޢ`ufdڝBGR6l%L;a'٘ܔWDMmur-%W)3e˖if#{57`T^ u߿˖S0XZֽGw"kqOܙO,C|[EϞiJG8HlH3)$e`ޗTXҗÙeOჍ lr~ 'lǰ)qGvE˔h֭n7XRu t^$?\وaHGB4[x UV2:g9 QaWW;]~El[kg[U \_]=5]pY" 9ShAWLnTd($갟H^yO$)32'._;nR7KmvB^5q4Io>.!/f{ }S)ha )hzJR#SFG}p`8w`fw/]Wi6&^,Fz )Ri:@SPJ,F2v6$'6&ĽQ; gn({4?RT0Ď^%qHԐaX. )]C@Lp.J7p ?ƭ '^ghmUDF%ACXd:zIِ@)E"{6.f04ďïHʮʆlShce e.uZOzdw L4nh+k^B-[؊Y [ףnK(ݔ Jܨb%JLd ZѪ8& Wf},sY4vmL:JeZ W?uih&4]Mhh|b]دVQ:#uB=n뺟(JJU>Ljαܴ937#<.( *xY @Axlzȩ\Vc2-lOA'γn'LvWOƹ4:'l&(Jw|g2"W?|{]GrWsROf}J3\<7{[N?f貰<ۤ}C\J@xȈ|;*>ҜzB g9}~#F"|eY(Bj&AZZVce4P7' =dߤ\4]0k-+V)͆s٦IL 6nrGasIqX4w~wy% .%73UdZs'+ZZl6 -[\Ug܀/BޑzL:J' D$;[8έ U'Z<_T{Y;EO4&1`^"\upi0\YH~P}Ptn`=i7&|L>UzW؍L5[GIUGa2 + ֧bx> _zg.R-P_ .K*R5Ou@-D\ lT|#2kڏй(CI#Ǧب S"Qdh7,lƉ4ݔqNi)`d{v~m@e,k}#j* $A;л;)J.G KVv4]pw>$sUİ$>NڒfV]2W]kTm%լ* :\]I. 61]>_ϭd8SdCz2=sg8 &_>3˜"ǎU璦>.+.sZR܄5F[ k}[ȑ Xs;rr2ښ'h>VkTqd%N&in bh2Mx=_ 3k7} *_HmHҋȵ%q׸VV?`Q.PЀqjr&v]dUx˗6LYT 5Vujs]H4_k\W쁂 )L?],K+ sFK[i*ڦ3#"""b)`u,2X2~Ƴꦺzn%r ; lؽ^DcG@o`wfE+^Ǎx/_k'=h}ޒvĂr75϶Hȃz]~3 [;k OwaY~? )!^XN6η>LFW [>kS?j!#IV;\]+~DcupbJwPP٠CZK粪oE- x}q4IJgCo͋XpPXތuh9,űfi?s|x_~rB$)Ŭ29Zsa,@22L0wr'OyF&L'GDDDDZ喪tB2u=EᰚxqRzLF>+?kUz=>1+ 3cefVH) ~i>q[̈HQ""In&i:.õSMs8m I)*T.?2N܆lHR"""".7n5Bun y'k}*#+|PYEq>*" JT(H]02"".dAUkU/ 'O%Z $ɫZ5rA]j1>bB PH{b4ϡB_aP s0^w6>=򯳾=/KܷҳLjJٶٶٸ#::'OA<`"8w=hI{ųDLJJDDDt| Y32D;JM uz+5e3G k15nl[O M /#BJR3}Ȩ,Ӛ٨u~ (7a"Y1dWj"#X8P+0V3n8GD1" j@uk=&HO8U{]> 2>߳D""""$,ޒBĐU:j|-갪ŽՙSq.k;ħ1=S􂈈vޑ'bDTR""""pϦ͋d> S)p DOdE4^pc"^0:sUN%bzETR"""" n`hoZtFǷ p}gRH7|m63u]3ZM9bDTR"""" H^ji(D {eIĔiR3ŽI8B}Iq$V2Ό%bETR"""" H+GNBοª*'uqnso(%E܏GLJJDDDD1nûUz,>%,Pdk6#?I^6-Ͳ8/RQIt\΅G.ő%!C6Y # ˲A#h?a!]|DDDD̸$  To ~>:TvN ~n}b.|Lw\|DDDD4hkzVt>Uj>@N=¦%$,>6"IBcxN=MU*(b"BRG$sAܟԵ.q'IJDDD OS[bP]ѕ2wxX0NV#"T0rs$%"""b')=Slï@%tDYg#l+?jD$)3M!@Zń HXqU>wd~W+XֻUW3$%"""b )⣦ǜBf1ni}?tvEg]_A{:>шHR""""f2"Ec'&0E}IW#J ;0{<>ψHR""""f(>@GGBB@~hg3t'Suu҅?9k{#%lO`n4#"I\M{"kI|z ùNEp4v@8PHW㳌$%"""bBitaRh3k eE],r Zũ?b@,0Q`'x_a:wɊ,G4rh,L )D(JJDDDDH3V1rďW?JޖthڂISpV>p>Dk|3Qܳ؈㰆l{X(.˳ q$ OhN"EanNAūt>|I-k0e*EF(JJDDDD]p/)y`XB8\Cy툣xCxCgq2ſS쳲HQ"f D%%"""N$2.>hfj:T-7=T1 /QV>hΰ1t>|HR""""f~r4c9&ҍ8=ߟl@GQ;/T>_U$,>-"$9eFG$ bzgq$V(~C5.yc$(_ZD$)M68[k(K;Z?СTƼ\N|fDDDDHzҧ<;9@|z5as: 2Q!9ڶ'B2XD$) ҡ(p\}؟(w +'"""IeKkE͸.໳),G~2o!h}"Z6O+"Y >~~ׁi1=vlaPPQ,1XɦYED1K!Y᫲礃Пk>A_td!Nv˽yf|RDDDDD ]Gbc +&-!٠K4n{mDD1K#L𑴮V> ȃ-~I-;M&bD,02Q? u Ӭf?>6%ڰF1"*)%(Q>,<1iKQIhndlT-#-m 9!"gIJDDDDj }DK h,^AFNO3tcS$%""""D AHS.9t'5Cҝ<,>HR"""""p)_٠T@- A^tw6[f Up}q| DDDDD܏8+ &US}r?)9|\QT13 EDDD4i/C|"aYVovBF̀DDDD4{m,WH THG,"fD%%"""aH'k!Bfh }IT,pƏs'1s *) #IIKk 9!EM!Ur[<Q"fD%%"""HhGYF XI_H^l"fD%%"""pp3 S7ߓ'*XG?-* y5tBS3y"YA&%gV'}ܔ "fD%%"""^{|'эSi12N%bfBTR""""t=||ږ1pQ(DDDDDayz! "G2|#{.EL\h<"r/EhRG7\`|VylHR"""""JM3(t(B[p'DDDDD]Dդg$4,hɹwܘIJDDDDDiq~3Oc9% +\:b&%19"""O[>X&@|ݽn3'npxFt T/DŦTpJl爙QIhG #tλÕ?O)|!p㈙ϱ¤Kݦٯ}#ڰ%%"""^"3< EGH%/)J̍DDDD; h )\rY?"X9SEcF̈JJDDDD=g!Pm!$HS7 Ί%bfGTR""""q[U}*J>6%1k̍DDDDL]f1WRmXxD&*)S^tCE 7M#fvD%%"""bFip=Q+-i~-.%"!8~V$3"-DzOIt e]>ٶٶٶٶ2>;‚y{Rl؊ 1%DLJn> jT؆1U.ģЙ,?9GW*>[3`ĬDDDDLUOZ_EA?\BDRJJDDDTF ELE 4x ;7/bATR""""2;H޿LDZJJDDDTG:甒'$VAcxv1^bXuKaUnG;,RY QIH7C-$ea0k,n1 b?#E$%""""b^DJK1g$%""""bBGZBe: Fq""I*pS08桼%tvlHR"""""Z|LGsDi[g[+"W k#~1Aov2mIJDDDDeusLJaOPDDDDDLU grJJN*[DDD4Dғ>W»3!ĬDٶٶٳp4<9QĬDDDDLS$s'蚧'򂏹b E̺JJDDD4E%.qGitUbE+n:21>TMCV9%MĬDDDDLs 1i9}ܔ621>5RYQIg: F]"fmD%%"""b:{MHQ""1] 5E܏M"fuD%%"""b/HQ"""I~p #""=bcDDD1MM3b[DD1p6"""b:Bp;4DDtM1MLOc;DD4*B*OJQJmH phsH FV F @+0FollowedHyperlink >*B*phV`V `OpTOC 1 % <<*$5OJQJ_HmH sH tH Z`Z `OpTOC 2 % <<*$^OJQJ_HmH sH tH .. `OTOC 3 7^7T T 0Header  %*$ CJOJQJ_HaJmH sH tH B/B 10 Header CharCJOJQJaJtH V `V 0Footer  %*$ CJOJQJ_HaJmH sH tH B/B 10 Footer CharCJOJQJaJtH `>`` !lTitle $$*$@&*5CJ(OJQJ\^J_HaJ(mH sH tH J/J 1 Title Char5CJ(OJQJ\^JaJ(tH Z) !Z Page Number,Header/FooterCJOJQJo(~3~ nd Table GridD:V0a|4#OJQJ\0`B\ \0 List Bullet$ & F*$m$OJQJ_HaJmH sH tH l6`Rl \ List Bullet 2% & F8*$^8`OJQJ_HaJmH sH tH `1`b` < List Number& & Fm$OJQJ_HaJmH sH tH R: rR A7 List Number 2'OJQJ_HaJmH sH tH :;: ^7 List Number 3(m$DYD *`O0 Document Map)CJOJQJ^JR/R )`O0Document Map CharCJOJQJ^JaJtH *W`* \`Strong5\.X`. _~@Emphasis6]x`x .R/0 Footnote Text -$<<*$^`$CJOJPJQJ_HaJmH sH tH X/X -R/0Footnote Text CharCJOJPJQJaJmH sH L&`L 10Footnote ReferenceCJH*OJQJhh 10Medium Grid 210$ & F*$@&m$CJPJmH sH tH 4o4 (% Bold Italic56FO"F 32` Body indent 127^7`<O1< 22`Body indent 1 Char@OB@ 5.Body indent 1A 47^7>Q> 4.Body indent 1A Char.oa. u Underline>*B' qB  Comment ReferenceCJaJ88 9 Comment Text8CJN/N 8 Comment Text CharCJOJQJaJtH HjH ; Comment Subject:5CJ\aJZ/Z : Comment Subject Char5CJOJQJ\aJtH H H 0Revision<OJQJ_HaJmH sH tH PP > Balloon Text =CJOJQJ^JaJR/R = Balloon Text CharCJOJQJ^JaJtH .. pTOC 4 ?X^XROR AJ$W Body indent 2@ 7s^`sm$<O< @J$WBody indent 2 CharJO"J CY Body indent 3BQs^Q`sm$<O1< BYBody indent 3 CharLO!BL E\yBody indent 1 unspacedDm$N2QN D\yBody indent 1 unspaced Char.. pTOC 5 F ^ .. pTOC 6 G^.. pTOC 7 H^.. pTOC 8 Ix^x.. pTOC 9 J@^@@O@ Le J Table TextK 7PP66 Ke JTable Text CharJoJ NN Spacer paraMOJQJ_HmH sH tH D/D MN Spacer para Char OJQJtH 8/8 EjrListO^`m$<2< EjrList 2P6^6`m$<3< EjrList 3QQ^Q`m$$L$ SEjrDateR:/1: REjr Date CharOJQJaJtH FDBF Ejr List ContinueTx^m$JERJ EjrList Continue 2U6x^6m$4"4 EjrCaptionV 5\aJNrN X3eBody Text FormsWll]l^laJX/X W3eBody Text Forms CharOJQJaJmH sH tH 4o4 j} Footer URLCJaJnOn Question Help TextZ 7B*CJOJQJ^JaJphcccPK![Content_Types].xmlN0EH-J@%ǎǢ|ș$زULTB l,3;rØJB+$G]7O٭VvnB`2ǃ,!"E3p#9GQd; H xuv 0F[,F᚜K sO'3w #vfSVbsؠyX p5veuw 1z@ l,i!b I jZ2|9L$Z15xl.(zm${d:\@'23œln$^-@^i?D&|#td!6lġB"&63yy@t!HjpU*yeXry3~{s:FXI O5Y[Y!}S˪.7bd|n]671. tn/w/+[t6}PsںsL. J;̊iN $AI)t2 Lmx:(}\-i*xQCJuWl'QyI@ھ m2DBAR4 w¢naQ`ԲɁ W=0#xBdT/.3-F>bYL%׭˓KK 6HhfPQ=h)GBms]_Ԡ'CZѨys v@c])h7Jهic?FS.NP$ e&\Ӏ+I "'%QÕ@c![paAV.9Hd<ӮHVX*%A{Yr Aբ pxSL9":3U5U NC(p%u@;[d`4)]t#9M4W=P5*f̰lk<_X-C wT%Ժ}B% Y,] A̠&oʰŨ; \lc`|,bUvPK! ѐ'theme/theme/_rels/themeManager.xml.relsM 0wooӺ&݈Э5 6?$Q ,.aic21h:qm@RN;d`o7gK(M&$R(.1r'JЊT8V"AȻHu}|$b{P8g/]QAsم(#L[PK-![Content_Types].xmlPK-!֧6 0_rels/.relsPK-!kytheme/theme/themeManager.xmlPK-!R%theme/theme/theme1.xmlPK-! ѐ' theme/theme/_rels/themeManager.xml.relsPK] 2rZ]&>r'z '8z 'pz   ,cR:`O{ F""=(;-5.)/145689=??7@BDFbG'IIKMPRY]b`bc_emghmnrtYyėΈɊlTߏKɗ1 ١{dw1Ӭ9F.apklU9 s Il*qz&{,>x   { cKt R!"#&&(+`-/25&6;> @@BGD E~GHJORVW:YZ]1aTc?ef8ij+npqs|vxxyw{#}$<V*ݑ`<ot֫ER2^Cd?j_==(n   [b"~  "-**0g5A:AAGKQW]u`aabwcXegVhpi>jDl^mInoptuw~xy{I|}~~i}wԋeCENPRfy7n)*Y>32eY4>+WcHAl7x8 vgjv' 1 S ` "r  $%&'(*+,-./12346=EPZdjt}     "#$%&')*+,-./12345678:;<=>?&,.0<DEGHRVaghjtx| &)1245AGHTZ]imz  (059;<Nap'.1G346w89<=?ADFFFFNI}Yh(rzX{k||@}} ~U~~Y€)k݁3؂0/B`܆ڇ4ވ׊1e8?B7ȗЗ%'o$@OY`i=ELU/>HOX=ELU)Wsiqx4kRn}u}HXk=;Zln./:lt#M+159=AEIMp*TfyI  F Z b o    K O S W [ _ c g k o j&(T-/3&6</>@+O])p .Z_dinoq $3 !*z**,//\344455(5U5g5{557A'B1B EKKKZOW^a(a:aGahazaaaaadbbbNcYcucce9hKhWhihvhhhhhhiiij#j1j-mrm~mmmmmmmm:nmovooooo?qttttuu,u8uJuWuuuNvYvuvvvv~x{{{{ ||)|;|H||||}}.}=}G}N}W}}}~"~>~S~v~~Ȁ؁+=I[h?}ۄwh֋ Ɍ^ҍ׎/:Vd$ڑAJђߒ#L8Mp~wy؝ΞOZv9q AO +8YkwէBDsugrKWivwӮ{ {Ʊ #Ų3Jaô9G /=5ڽe&8E)xDVbta =O[mz ,>J\i$2;MYkxBr~t}02;s >Iez=$&/~ _38&3[my[d4y&#5AS`     ? T w   r    !"#)05789:;<>?@ABCDFGHIJKLMNOQRSTUVWXY[\]^_`abcefghiklmnopqrsuvwxyz{|~ !(09DLSZahmt}      !"#$%'()*+-/123456789:;=>?@ABCFIJKLMNOPQSTUWXYZ[\]^_`bcdefiklmnopqrsuvwyz{}~     !"#$%'(*+,-./036789:;<=>?@BCDEFIJKLMNOPQRSUVWXY[\^_`abcdefghjklnopqrstuvwxy{|}~    !"#$%&')*+,-./1234678:)LVrt!#0LN8TV6RTu 9UXv8;l-IL`|%ADQmp9<Uqt  " 4 P S   R n q ( + C _ b s > Z ] @ \ _ t Hdg-0ZvyHdg7SVk;>VruEad|"%Okn#&i+.r$@C`|/3Xtx!=Av+GK[w{ > E ;%i%%%& &4&V&]&&'('(())))H+l+s+,,,--. .?.X..../02080a0t0A5h556*7f7777@(AJARAzAA C-CiCEEEHHIDZZZ]B]K]P_n_y_eeegfffjjjlClLl~~~=\h!πڀTr}ցȂӂtԄkυ6Ua׆ l݈h-LX 4>)38[rĎUzܖ JSřЙ (4O|֛d$YxҞߟ#2<բ`(2ȤӤ8gƨR}a ,8 *@J!GlvLq{'DK8Va}Y|9d=IS)Py%Tm "b       ; G &CJ 4Sb@J*++-6-B----888:::\<{<<<< =}???@@@JJJMNNNOOPPP:QYQeQVVVZZZ6[U[a[^^^7aVaba/bWbabMdjdqd{hhhhhhhhiiiijkkop4pJpgpnpq7qUq2rUrsr~sss$xCxJxy=yPyVzzzOnzǃމזǙ-9ԛۛz&EQRq}2Q]c%,ź;oHel{(EL)Lb&#Ss !>ETqx(GV,IPm7C(l$0C c p v      !LUY~iUUUtXXX]]]___bbbddd kKkTkppppppqrr4s_shsvw#wwww7ybyky}~~~6~B~H~g~s~DkuȂт@Jaܒ0Sq"(GSeТΤפ(S]ʪgİԹ޹/Zc5Ahg@I",It}kPp}(+5Mx(GSYy&/ (4Rq}v>Hg,KW5T`JitXw 3an r %%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%%XXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXXAU]dglx|X!X!@ @H 0(  0(  B S  ?} _Toc462057928 _Toc462057929 _Hlt211247546_What_does_this _Toc462057930_Cooling-off_period_notice_Cooling-off_period_notice_1_Cooling-off_period_notice_2 _Toc462057931 _Toc462057932 _Toc462057933 _Toc462057934 _Hlt460333383 _Hlt460333384 _Toc462057935 _Toc462057936 _Toc462057937 _6._Deposit _Toc462057938 _Toc462057939 _Toc462057940 _Hlt460403020 _Toc462057941 _Toc462057942 _Toc462057943 _Toc462057944 _Toc462057945_Part_A:_Check_Part_A:_Check_1 _Toc462057946 _Toc462057947 _Toc462057948_Checklist_for_the_Checklist_for_the_1_Is_the_contract _Toc462057949_Part_B:_Terms_Part_B:_Terms_1_Part_B:_Terms_2 _Toc462057950_1._Definitions_1._Definitions_1_1._Definitions_2_1._Definitions_3 _Toc462057951 _Hlt460334699_2._Interpretation _Toc462057952_3._Communication_between _Toc462057953 Clause_3_1_4._Contract_Details_4._Contract_Details_1_4._Contract_Details_2_4._Contract_Details_3_4._Contract_Details_4_4._Contract_Details_5_4._Contract_Details_6_4._Contract_Details_7_4._Contract_Details_8_4._Contract_Details_9_4._Contract_Details_10_4._Contract_Details_11_4._Contract_Details_12_4._Contract_Details_13_4._Contract_Details_14_4._Contract_Details_15_4._Contract_Details_16_4._Contract_Details_17 _Toc462057954 _Hlt460419296 _Hlt460424323 _Hlt460424324 _Hlt460420368_5._Contract_Price_5._Contract_Price_1_5._Contract_Price_2 _Toc462057955 Clause_5_1 Clause_5_2 Clause_5_3 _Toc462057956 Clause_6_1 Clause_6_2_7._Progress_payments_7._Progress_payments_1_7._Progress_payments_2_7._Progress_payments_3_7._Progress_payments_4 _Toc462057957_8._Domestic_Building_8._Domestic_Building_1_8._Domestic_Building_2 _Toc462057958 Clause_8_1 Clause_8_4_9._Obligations_of _Toc462057959 Clause_9_3_10._Contract_documents_10._Contract_documents_1 _Toc462057960 Clause_10_3_11._Signatures_11._Signatures_1 _Toc462057961_12._General_conditions _Toc462057962 Clause_12_2 Clause_12_4 _Hlt460336254 Clause_12_10 Clause_12_12 Clause_12_13 Clause_12_15_13._Commencement_of_13._Commencement_of_1 _Toc462057963 Clause_13_1 _Hlt460419283_14._Finish_Date_14._Finish_Date_1 _Toc462057964 Clause_14_4 Clause_14_5 _15._Loss_or _Toc462057965 Clause_15_1_16._Purpose_of_16._Purpose_of_1 _Toc462057966 Clause_16_1_17._Builder s_warranties_17._Builder s_warranties_1 _Toc462057967 Clause_17_1 Clause_17_3_18._Permits,_prescribed _Toc462057968 Clause_18_1 Clause_18_2 _Hlt460419396 Clause_18_3 Clause_18_4 Clause_18_5 Clause_18_6 _Hlt460407588 _Hlt460408038 Clause_18_7 Clause_18_8_19._Loan_approvals_19._Loan_approvals_1_19._Loan_approvals_2_19._Loan_approvals_3_19._Loan_approvals_4 _Toc462057969 Clause_19_5 Clause_19_6 _Hlt460419319 Clause_19_7 Clause_19_8 _Toc462057970 Clause_20_2_21._Access_to_21._Access_to_1 _Toc462057971 Clause_21_3 Clause_21_4 Clause_21_5_22._Extension_of_22._Extension_of_1_22._Extension_of_2_22._Extension_of_3 _Toc462057972 Clause_22_1 Clause_22_2 Clause_22_3 Clause_22_6_23._Variations_23._Variations_1_23._Variations_2_23._Variations_3_23._Variations_4_23._Variations_5_23._Variations_6_23._Variations_7 _Toc462057973 Clause_23_5_24._Provisional_Sums_24._Provisional_Sums_1_24._Provisional_Sums_2_24._Provisional_Sums_3_24._Provisional_Sums_4 _Toc462057974 Clause_24_3 Clause_24_4_25._Prime_Cost_25._Prime_Cost_1_25._Prime_Cost_2_25._Prime_Cost_3_25._Prime_Cost_4 _Toc462057975 Clause_25_3 Clause_25_4_26._Evidence_of _Toc462057976_27._Effect_of _Toc462057977 Clause_27_2_28._Final_Completion _Toc462057978 Clause_28_2_29._Building_Owner s_29._Building_Owner s_1_29._Building_Owner s_2 _Toc462057979 Clause_29_2_30._Lender_payment_30._Lender_payment_1 _Toc462057980_31._Completion_of _Toc462057981_32._Completion_notifications_32._Completion_notifications_1_32._Completion_notifications_2 _Toc462057982 Clause_32_1 Clause_32_2 Clause_32_3_a_33._Rectification_period_33._Rectification_period_1 _Toc462057983_34._Dispute_Resolution_34._Dispute_Resolution_1_34._Dispute_Resolution_2_34._Dispute_Resolution_3 _Toc462057984_35._Suspension_of_35._Suspension_of_1_35._Suspension_of_2_35._Suspension_of_3_35._Suspension_of_4 _Toc462057985_36._Consequences_of_36._Consequences_of_1 _Toc462057986 Clause_36_1_37._Termination_after _Toc462057987 Clause_37_1 Clause_37_5_38._Termination_other_38._Termination_other_1_38._Termination_other_2 _Toc462057988 Clause_38_1_39._Builder s_entitlement_39._Builder s_entitlement_1_39._Builder s_entitlement_2 _Toc462057989 Clause_39_1 Clause_39_2_40._Consequences_of _Toc462057990 Clause_40_1_41._Consequences_of _Toc462057991 Clause_41_3 Clause_41_4_42._Insurance _Toc462057992 Clause_42_1_43._Copyright _Toc462057993_Document_List_Attachment_Document_List_Attachment_1_Document_List_Attachment_2_Document_List_Attachment_3_Document_List_Attachment_4_Document_List_Attachment_5_Document_List_Attachment_6_Document_List_Attachment_7_Document_List_Attachment_8 _Toc462057994_General_Attachment_General_Attachment_1_General_Attachment_2_General_Attachment_3 _Toc462057995_Provisional_Sums_Schedule_Provisional_Sums_Schedule_1_Provisional_Sums_Schedule_2_Provisional_Sums_Schedule_3_Provisional_Sums_Schedule_4 _Toc462057996_Prime_Cost_Items_Prime_Cost_Items_1_Prime_Cost_Items_2_Prime_Cost_Items_3 _Toc462057997_Part_C:_Legislation_Part_C:_Legislation_1_Part_C:_Legislation_2 _Toc462057998 _Toc462057999domestic_building_disputeprime_cost_itemprovisional_sum _Toc462058000 _Section_40_ _Section_40_ _1_Section_40_ _2_Section_40_ _3Table_progress_payments _Toc462058001 _Section_30_ _Section_30_ _1 _Toc462058002 _Section_26_ _Toc462058003 _Section_37_ _Section_37_ _1_Section_37_ _2_Section_37_ _3_Section_37_ _4_Section_37_ _5_Section_37_ _6 Section_37_2 _Section_38_ _Section_39_ _Toc462058004 _Section_41_ _Section_41_ _1_Section_41_ _2_Part_D:_Forms_Part_D:_Forms_1 _Toc462058005 _FORM_A_ _Toc462058006 _FORM_B_ _Toc462058007 _FORM_C_ _Toc462058008 _FORM_D_ _Toc462058009 _FORM_E_ _Toc462058010 _FORM_F_ _Toc462058011 _FORM_G_ _Toc462058012 _Hlt211445334 _FORM_H_ _Toc462058013 _FORM_I_ _Toc462058014 _FORM_J_ _Toc462058015 _FORM_K_ _Toc462058016 _FORM_L_ _Toc462058017 _FORM_M_ _Toc462058018 _FORM_N_ _Toc462058019 _Toc462058020 _FORM_P_ _FORM_P_ _1 _Toc462058021 _Hlt460419819 _Hlt460408067 _Hlt460412291 _FORM_Q_ _FORM_Q_ _1 _Toc462058022 _Form_R_ _Toc462058023 _Hlt460408680 _Toc462058024 _Toc462058025 *C &&7777>?5EIIJ MkN%Q%QJRCSZ'[eejOloooop}}}}hhhhh/^^%%%%%%%%%%%%%%%%%%%&;;;UZtIW G3K 1Gj###$V&b&b&&C,<6<66X7899;;???@+G+G+G+G+G+GK MNNUPhQRUUUW!YY;];];];];]]dbdioooooooooRv}y}y}y}y}y}yB} l4܍܍}}``֣֣fs```߷߷߷߷߷??ddddPPPPv;JJJJJJJJJJ     r ~ ~ ~ ~ ~ '3333 !""""4,---7W799999999<dCqLOROROROUUU!U!UT]T]>b>bhh,p,pvv~~̂yy33  2233s@ @ @@ !"#$%&'()*+,-@./0123456789:;<=>?@ABCDEF@G@H@I@JKLMNOPQRSTUVWXYZ[\]^_`abcdefghijklmn@opqrstuvw@xyz{|}~@@@@      !"#$%&'()*+,-./0123456789:;<=>?@ABCDEFGHIJKLMNOPQRSTUVWXYZ[\]^_@`abcdefghijklmnopqr@s@t@uvwxyz@{|(=D &&7778?6?WEIIJ&MN%Q/QdRfSZE[9e f'jjlooop@p}}}I}8hhhhv0^o;%%%%%%%%%%%%%%%%%%8';;LUZ"tIW &G3K 1G j*###$V&b&z&&C,<6z66\7899;;???@+G+G+G+G+G=GK MNNUPQRUU2UW!YY;];];];]P]]dbdioooooooooRv}y}y}y}y}yyB} l4܍}`֣fs``߷߷߷߷?fdddPPPxv;JJJJJJJJJb    ( r ~ ~ ~ ~  '333L  """""4,---V7W799999999<dCqLQOROROROUU U!UHUT]]>bxbhh,pWpvv~͂.֛y*3d +2LN3s1~~~~~~~ ~!~"~#~$~%~&~'~(~)~*~+~,~-~.~/~0~1~2~3~4~5~6~7~8~9~:~;~<~=~>ʆ?ʆʆʆʆʆٴʆʆʆҴʆʆʆ::''888**333<66ooݴݴPP??GGP~~::C[[[>u>uys      !"#$%&'()*+,-./0BB''#8\8\82[;[;[;DD>>xxVVEEOXXBKK[[[DuDus   !"#$%&'()*+,-./08*urn:schemas-microsoft-com:office:smarttagsCity90*urn:schemas-microsoft-com:office:smarttagsplace91*urn:schemas-microsoft-com:office:smarttagsState=-*urn:schemas-microsoft-com:office:smarttags PlaceType=/*urn:schemas-microsoft-com:office:smarttags PlaceNameB*urn:schemas-microsoft-com:office:smarttagscountry-region '10/0-10-10/0-/0-101000000/0-0/0-/0-/0-006!"|}OY]lpsd$h$99 >> MMMM____``^bebcdddMpOp"#$+{|bd}~!"|}OY]lops3333333333333333333333 > ^ @ ` t Hh1ZzHh7Wk?VvEe|&Oo'i/r$D`4Xy!Bv+L[|""}}OY]lops > ^ @ ` t Hh1ZzHh7Wk?VvEe|&Oo'i/r$D`4Xy!Bv+L[|""|}}OY]lops`S!䥆"Ly$CZ -#:5d47^7`OJQJo(hHo 7^7`o(hH.^`OJQJo(hHh^`OJQJo(hHh^`OJQJ^Jo(hHoh^`OJ QJ o(hHhr ^r `OJQJo(hHhB^B`OJQJ^Jo(hHoh^`OJ QJ o(hHh^`OJQJo(hHh^`OJQJ^Jo(hHoh^`OJ QJ o(hHh8^8`OJQJ^Jo(hHoh^`OJQJ^Jo(hHoh ^ `OJ QJ o(hHh ^ `OJQJo(hHhx^x`OJQJ^Jo(hHohH^H`OJ QJ o(hHh^`OJQJo(hHh^`OJQJ^Jo(hHoh^`OJ QJ o(hH-#CZ         —T{@9q7~Eq7~Exw8O 4 ],`iafe}&'6TH%368XbkpH}U=<> -:b#s*7_t L N %^ ^ k I0 5 F z C T b c { u x *UNuHgMVv|~*y((K5S`sy-EhF~$'+:2;bF~2gjq?.>Vac8 Z!B"uv}@bv/.bsk=>H2DV$ =T%X w!4 Da`iIpYzc r&t  | 5 < !2Q!V!c!ue!X0"4"5A"\7#F#W#Z# $P$$K($ F$O$QP$Q%%'%+%=<%?%{k%~%&E&`&''o"'$'/'A'I'f['x'{'((f(}))V.)A[)h)**+B+w+",+G,K,WT,W,D^,t,--Q-Z-y-&...M.k~.~.//B1/R/d/0*50i@1g1ok1i2I2212]F2u3$3;*3J3, 4&4&48@4#535S5_5h66I6.e66w67>7^7_b7 8B8]8o8~9.9>9N9Z9j9 : ::gB:Q:x:$;);*;b6;6;O;e;+m;t;w;(,<=v7===h=t=>4 >y/>p<>nB>I>Q> @Z@_@@q@ AZQAB BI9BMsBxC CrCyMCQC aCdCHpC1EAE!EE FXFFIGRGcHHH+HnHpIIKINIe J0J]1J!a{y{H |5|KL|Y|Df|R }W}N}Q}j}V~_~$03D]} &0A7Y],";hkv{ @+1Nz,L9pOz0`Y]C|XJF\ +DK_T]pvo#-+Q68\t:!4EZa;?OmAsx ' #'@EQcMz53e I#/BSY zS{#B.nd!I?APYNs#(%0 MM2Y3<[lu[ry_7$FUsX*^*rTq tKJ\ ^dh(`4r: DZvIV\pt MQf&e3S]j-24YBJN|F5Nh2 &")6I Y3[hg} E ;v>`?^g K ma,Ng%V@GjHOXyyc|e19@o:rvJ Zm%<c}u}H%.@{} A>z+#<IfvS.5?MfTukz<)@ADEQygLo LVz%-hi;IoR`jjk#u8`Xv66Dnr %vQ`=D+g**+3G`kG AG\ VZrXc>AE MO I,eZ/"\*3T6B]k{"$@r8@Unknown Adam Collins G.Cx Times New Roman5Symbol3. *Cx Arial1" Helv7@Cambria7.@CalibriG=  jMS Mincho-3 fgcPLucida GrandeTimes New Roman?= *Cx Courier New;WingdingsA$BCambria Math"NhHgI'Hg ss}s}nM 4 2qHXb#`2! xx Building contract for new homesBuilding and renovatingConsumer Affairs VictoriaDaniel Craddock      Oh+'0 $8 P\ |    Building contract for new homesBuilding and renovatingConsumer Affairs ɫƵ Normal.dotmDaniel Craddock10Microsoft Office Word@r@CO@ Clause_18_6; Clause_36_1-"8 Clause_12_105 Clause_12_4^2_4._Contract_Details_17/_36._Consequences_of_1ii,_35._Suspension_of_4^)_4._Contract_Details_17~3&_34._Dispute_Resolution_3~3#_34._Dispute_Resolution_2^ _4._Contract_Details_17 X_33._Rectification_period_1 Clause_32_1^_4._Contract_Details_178m _32._Completion_notifications_2^_4._Contract_Details_17. _29._Building_Owner s_2n/ _25._Prime_Cost_4@_24._Provisional_Sums_4^_4._Contract_Details_17!,_7._Progress_payments_3^_4._Contract_Details_17 Clause_25_3 Clause_24_3Z $_Section_37_ _5Z $_Section_37_ _4^_4._Contract_Details_17S!_23._Variations_7in_35._Suspension_of_3^_4._Contract_Details_17 T_22._Extension_of_3 Clause_19_8 Clause_19_7 Clause_19_6^_4._Contract_Details_17^_4._Contract_Details_17T _19._Loan_approvals_4^_4._Contract_Details_17^_4._Contract_Details_17-! Clause_12_13-  Clause_12_12^_4._Contract_Details_17^_4._Contract_Details_17^_4._Contract_Details_16^_4._Contract_Details_15 Clause_12_4^_4._Contract_Details_14qx Clause_6_2^_4._Contract_Details_13n/_25._Prime_Cost_3^_4._Contract_Details_13@_24._Provisional_Sums_3 Clause_20_2-' Clause_12_15 Clause_42_1 Clause_37_5 Clause_42_1 Clause_41_4 Clause_39_2 Clause_39_1 Clause_41_3 Clause_40_1, _FORM_Q_ - _FORM_P_ ~ Clause_40_14 S{_39._Builder s_entitlement_1,x _FORM_Q_ -u _FORM_P_ r Clause_40_1o Clause_39_1,l _FORM_Q_ -i _FORM_P_ {$f Section_37_2c Clause_38_1\ #`_Section_41_ _2\ #]_Section_41_ _1-"Z Clause_12_10W Clause_12_4,T _FORM_Q_ -Q _FORM_P_ ,N _FORM_Q_ -K _FORM_P_ -"H Clause_12_10E Clause_12_46kB http://www.consumer.vic.gov.au/3? _FORM_N_ 0< _FORM_M_ 19 _FORM_L_ /O6Clause_32_3_a3 Clause_32_20 Clause_32_2- Clause_21_3* Clause_29_26' _FORM_K_ $ Clause_15_1! Clause_15_1[_30._Lender_payment_1. _29._Building_Owner s_1 Clause_25_44 _FORM_I_ {u_Prime_Cost_Items_3 Clause_24_44  _FORM_I_ 3~ _Provisional_Sums_Schedule_4G{_Section_39_ ? K _FORM_Q_ _1Z $_Section_37_ _3Z $_Section_37_ _3Z $_Section_37_ _35 _FORM_H_ Z $_Section_37_ _3 Clause_22_6 Clause_14_4 Clause_22_6 Clause_22_3 Clause_22_2: _FORM_G_ io_35._Suspension_of_2 Clause_22_2 Clause_14_4 Clause_21_5 Clause_21_4-' Clause_12_15 Clause_19_7 Clause_19_6 Clause_19_6 Clause_19_7; _FORM_F_ Hz_Section_26_ > K _FORM_P_ _1 Clause_18_2 Clause_18_2q{ Clause_5_2/ _Form_R_ ol_21._Access_to_1 Clause_17_1y'_16._Purpose_of_1 Clause_14_4 T_22._Extension_of_2 Clause_13_1^_4._Contract_Details_128 _FORM_E_ 9 _FORM_D_  Clause_37_1il_35._Suspension_of_1 Clause_12_4> _FORM_C_ ? _FORM_B_ ] $_Section_30_ _1 ;_Part_A:_Check_1xl|_Document_List_Attachment_8xly_Document_List_Attachment_7 =v_General_Attachment_3xls_Document_List_Attachment_63yp_Provisional_Sums_Schedule_3xlm_Document_List_Attachment_5 j_Part_B:_Terms_2qpg Clause_8_4PIdTable_progress_paymentsa Clause_22_1] #^_Section_40_ _37[ _FORM_J_ ] #X_Section_40_ _2qpU Clause_8_4<R _FORM_A_ qpO Clause_8_4Z $L_Section_37_ _6S!I_23._Variations_6F Clause_27_2S!C_23._Variations_5n/@_25._Prime_Cost_2@=_24._Provisional_Sums_2: Clause_25_47 Clause_24_4S!4_23._Variations_41 Clause_18_1. Clause_18_2-+_18._Permits,_prescribedT (_19._Loan_approvals_3% Clause_13_1" Clause_13_1^_4._Contract_Details_17q~ Clause_3_1^_4._Contract_Details_11 =_General_Attachment_2xl_Document_List_Attachment_4uS_1._Definitions_2qv  Clause_9_3S! _23._Variations_3nSprovisional_sumGWprime_cost_item8m _32._Completion_notifications_1^_4._Contract_Details_10RK_Part_C:_Legislation_2N{_Section_30_  Clause_13_1 Clause_28_2qu Clause_8_19.domestic_building_dispute~3_34._Dispute_Resolution_1 Clause_17_1q{ Clause_5_2V_4._Contract_Details_9#]_31._Completion_ofC%_11._Signatures_1!,_7._Progress_payments_2] #_Section_40_ _1W_4._Contract_Details_8S!_23._Variations_2Z $_Section_37_ _2T _19._Loan_approvals_2X_4._Contract_Details_7 Clause_17_3 Clause_16_1 Clause_15_1 Clause_14_5 Clause_14_4 Clause_13_1Y_4._Contract_Details_6 Clause_20_2-' Clause_12_15 Clause_12_2xl_Document_List_Attachment_3 Clause_10_3qx Clause_6_2qx Clause_6_2q{ Clause_6_1qp Clause_8_4qv Clause_9_3qz Clause_5_3q{ Clause_5_2qx Clause_5_1Z_4._Contract_Details_5 Clause_13_1[_4._Contract_Details_4^}_4._Contract_Details_1^z_4._Contract_Details_17j [w_17._Builder s_warranties_1+yt_42._Insuranceqpq Clause_8_4*$n_8._Domestic_Building_1![kMhttp://www.vba.vic.gov.au/consumers/building-for-consumers/building-surveyorappointing_a_building_surveyorovhhttp://www.vba.vic.gov.au/ovehttp://www.vba.vic.gov.au/!b_Is_the_contractD__Checklist_for_the_1F\)http://consumer.vic.gov.au/buildingguideuSY_1._Definitions_13{V_Provisional_Sums_Schedule_1{uS_Prime_Cost_Items_1 =P_General_Attachment_1xlM_Document_List_Attachment_2xlJ_Document_List_Attachment_1N|G_Section_40_ Z $D_Section_37_ _1RHA_Part_C:_Legislation_1 #>_Part_B:_Terms_1 ;_Part_A:_Checkhh8_Cooling-off_period_notice_2hk5_Cooling-off_period_notice_12_Part_B:_TermsuS/_1._Definitions_36k, http://www.consumer.vic.gov.au/,1)_Part_D:_Forms_1ok http://consumer.vic.gov.au/okhttp://consumer.vic.gov.au/CD/16/363641  TAM, Halina DG/12/51257 TAM, Halina26 July, 2016$Services & Support Division (CAV) XTemplate - Master template - Building and renovating - Building contract for new homes  !"#$%&'()*+,-./0123456789:;<=>?@ABCDEFGHIJKLMNOPQRSTUVWXYZ[\]^_`abcdefghijklmnopqrstuvwxyz{|}~      !"#$%&'()*+,-./0123456789:;<=>?@ABCDEFGHIJKLMNOPQRSTUVWXYZ[\]^_`abcdefghijklmnopqrstuvwxyz{|}~      !"#$%&'()*+,-./0123456789:;<=>?@ABCDEFGHIJKLMNOPQRSTUVWXYZ[\]^_`abcdefghijklmnopqrstuvwxyz{|}~      !"#$%&'()*+,-./0123456789:;<=>?@ABCDEFGHIJKLMNOPQRSTUVWXYZ[\]^_`abcdefghijklmnopqrstuvwxyz{|}~      !"#$%&'()*+,-./0123456789:;<=>?@ABCDEFGHIJKLMNOPQRSTUVWXYZ[\]^_`abcdefghijklmnopqrstuvwxyz{|}~      !"#$%&'()*+,-./0123456789:;<=>?@ABCDEFGHIJKLMNOPQRSTUVWXYZ[\]^_`abcdefghijklmnopqrstuvwxyz{|}~      !"#$%&'()*+,-./0123456789:;<=?@ABCDEFGHIJKLMNOPQRSTUVWXYZ[\]^_`abcdefghijklmnopqrstuvwxyz{|}~      !"#$%&'()*+,-./0123456789:;<=>?@ABCDEFGHIJKLMNOPQRSTUVWXYZ[\]^_`abcdefghijklmnopqrstuvwxyz{|}~      !"#$%&'()*+,-./0123456789:;<=>?@ABCDEFGHIJKLMNOPQRSTUVWXYZ[\]^_`abcdefghijklmnopqrstuvwxyz{|}~                           ! " # $ % & ' ( ) * + , - / 0 1 2 3 4 5 7 8 9 : ; < = > ? @ A B C D E F G H I J K L M N O P Q R S T U V W X Y Z [ \ ] ^ _ ` a b c d e f g h i ~  Root Entry F8, Data >1Table WordDocument z SummaryInformation(. DocumentSummaryInformation86 gMsoDataStore4,8,10UWBXGPOA==24,8,Item  PropertiesUCompObj r    F Microsoft Word 97-2003 Document MSWordDocWord.Document.89q